SPRING 2016 VOLUME 95 • ISSUE 1 TQI Progress Report 10 We Build Futures 18 What does your post Act-89 workforce look like? 12 Constructing a SKILLED & DIVERSIFIED Workforce
SPRING 2016VOLUME 95 • ISSUE 1
TQI Progress Report 10 We Build Futures 18 What does your post Act-89 workforce look like? 12
Constructing a SKILLED & DIVERSIFIED Workforce
Asphalt Shingle Grinding Service, LLC
It’s Just Right!
ONE PASS PROCESSING100% Passing 3/895% Passing #490% Passing #8
Average Sieve Analysis
Recycled Asphalt Shingles(RAS/RAP)Production
SalesManufacturers Waste
Tear-OffsNationwide Mobile GrindingAsphalt & Concrete Crushing
ODOT Approved Supplier for Manufacturers Waste Shingles
We Sell Equipment Too!
It’s More Than Fine...
877-679-5708ShingleGrinding.com
Squirrel Hill Tunnel RehabilitationPittsburgh, Pennsylvania
2016 Honor Award, ACEC/PA
800.233.1055 • www.gannettfl eming.com • Offi ces Worldwide
Award-Winning Engineering
2016_HighwayBuilder_Spring_4C_7.25x5.indd 1 3/11/2016 7:51:33 AM
3www.paconstructors.org
1www.paconstructors.org
TOTAL PRECAST STRUCTURE: SHERMAN VALLEY RUN BRIDGE PADOT District 9-0 • Accelerated Bridge Construction Project
New Enterprise Stone and Lime Co., Inc. erected the Sherman Valley Run Bridge, located in Bedford County on State Route 1020, in July 2012 as their first total precast concrete accelerated bridge system. The EADS Group of Altoona designed the bridge under the direction of the District 9-0 Bridge Engineer, Ralph DeStefano. Newcrete Products, a division of New Enterprise Stone and Lime Co., Inc. detailed, fabricated and delivered the precast substructure units and the prestressed adjacent slab beams for the project.
TEKLA Structures 3D MODEL FINISHED STRUCTURE
The precast components included footings, abutments, wing walls, scour cut off walls and moment approach slabs. The bridge was successfully completed and open to traffic within the required three (3) week PADOT schedule starting at detour implementation. Newcrete utilized the building information modeling (BIM) application TEKLA Structures, a Trimble Company, to model the bridge in 3D and create the framing plan and shop drawings for the project. During the detailing phase, Newcrete combined several of the substructure units reducing the total number of precast elements to eighteen (18) from thirty eight (38). The substructure elements were “match casted” and partially assembled at the plant to ensure all the pieces fit together well.
The goals and benefits of accelerated bridge construction were completely achieved, and New Enterprise Stone & Lime Co., Inc. extends a sincere thank you to District 9-0, the EADS Group and all others who contributed to the success of this unique project.
A division of New Enterprise Stone & Lime Co., Inc.
Reliability • Resources • Results
OFFICE: 814-224-2121 • www.newcrete.com Corporate Office: (814) 766-2211 � www.nesl.comPA H.I. Contractors Lic. #PA037617
� Blacktop
� Crushed Stone
� Ready-MixConcrete
� Lime
� Free Estimates
� No Job Too Big or Too Small
Serving Commercial& ResidentialCustomers Since 1924
New EnterpriseStone & Lime Co., Inc.
With Allan Myers, we designed a temporary Support of Excavation to aid in the
reconstruction of the Arcola Road Bridge in Collegeville, PA.
www.witmanengineers.com
4 Spring 2016HIGHWAY BUILDER
Columns7 Executive Vice President Column Transportation Quality Initiative Seeks to Build Quality Workforce by Robert E. Latham, CAE APC Executive Vice President
26 Legal Examining A+BX Bidding by James W. Kutz, Esquire McNees, Wallace & Nurick LLC
31 Industry Briefs
SPRING 2016VOLUME 95 • ISSUE 1
Features8 Central PA Diversity Enhanced by PA Turnpike CEO Fellows Program for Diverse Groups by Myneca Y. Ojo, Director of Diversity and Inclusion, Pennsylvania Turnpike Commission
10 Leadership Group Seeks to Move TQI from the C-Suite to the Project
12 Hire, Train, Motivate, Retain APC Members Adapt to a Post-Act 89 Workforce by Jerry Marks, TriAd Marketing & Media
18 We Build Futures 19 Earn While You Learn by Michael P. Welsh, Council Representative, Keystone + Mountain + Lakes Regional Council of Carpenters
20 Connecting With Pennsylvania College of Technology by Marc E. Bridgens, Dean, School of Construction and Design Technologies, Pennsylvania College of Technology
24 Don’t Get Stuck in a Cubicle! Embrace a Career in Heavy and Highway Construction by Steven D. Columbus, Administrative Manager, Western Pennsylvania Operating Engineers, Joint Apprenticeship & Training Program
Highway Builder is published for the Associated Pennsylvania Constructors. Circulation covers highway and heavy constructors in Pennsylvania and surrounding states. Miscellaneous coverage throughout United States. Circulation also includes engineers, public officials, suppliers, equipment dealers, and others allied with the highway industry.
800 North Third Street • Harrisburg, PA 17102 phone: 717.238.2513 • fax: 717.238.5060
a shortage of skilled workers? How do we hold onto and grow our most valuable asset? APC members share their strategies for sustaining a well-trained and diversified workforce. Page 12
5www.paconstructors.org
Dynamic Load Testing on any type of deep foundation evaluates:Total bearing capacity by CAPWAP®
Capacity at time of test by Case Method or iCAP® For driven piles, monitors driving stresses, integrity and hammer performanceAsk about remote testing with SiteLink®to lower costs and ease scheduling
testing with SiteLink®to lower costs and ease scheduling
www.GRLengineers.com/PDA [email protected]
Dynamic Load Testing
by the Foundation Testing Experts
PDA Services
Quick response,results you can trustPennsylvania ..... 610.459.0278Central Offi ce .... 216.831.6131
Other offi ces nationwide
Years of testing d
eep foundations
UPSIDE SOLUTIONS FOR YOUR SURETY NEEDS Does your surety:
Give you the capacity to bid the size and scope of jobs you want?
Provide highly competitive rates to help you win jobs?
Make you comfortable with the indemnity obligations you have in place? If you can’t answer “yes” — it’s time for a new surety partner.
WWW.GUNNMOWERY.COM
LEMOYNE | LANCASTER| DILLSBURG | STATE COLLEGE
Contact Heather Hall, Director of Surety, to see how easy it is to access Gunn Mowery’s upside solutions.
[email protected] | 761-4600 x3050
6 Spring 2016HIGHWAY BUILDER
EDITOR – Cynthia K. Sells [email protected] PUBLICATION PREPARATION – TriAd Marketing & Media371 County Line Rd. W. • Westerville, Ohio 43082Janine Robinson, Vice President of Creative Services LAYOUT & DESIGN – TriAd Marketing & Media ADVERTISING SALES – Mark Wolf 866.679.9340 or [email protected] PRINTER – Haman Midwest
OFFICIAL PUBLICATION OF THE ASSOCIATED PENNSYLVANIA CONSTRUCTORS
2016 Officers and Directors
PresidentCraig A. Hoogstraten
Vice PresidentMax J. Hempt
TreasurerCharles J. Niederriter
Executive Vice PresidentRobert E. Latham, CAE
DISTRICT VICE PRESIDENTSOwen J. McCormickMichael HawbakerJames R. ParsonsWayne M. SchugDominic P. GirondoRicke FosterMark S. EckmanS. Scott GrannasMichael A. PaloCharles J. NiederriterClayton Stahl
BOARD OF DIRECTORSGreg Andricos Steven M. BussanmasMatthew CummingsPaul I. Detwiler, III Michael J. Driscoll, Jr.Mark S. EckmanBarry A. Epley Ricke C. Foster Michael B. Glezer S. Scott Grannas Michael HawbakerMax J. HemptAlbert HoffmanCraig A. HoogstratenBruce G. HottleKevin L. Johnson John R. Kibblehouse, Jr.Patrick A. KinsleyJeffrey C. Lamb Robert E. LathamThomas E. LawsonKevin LoftusDennis A. Luzier Joseph M. Martosella, Jr.Owen J. McCormickGeorge E. MezeyJohn M. MillsSeth Myers Charles J. NiederriterWilliam J. O’ConnorJames R. ParsonsDavid Patterson
Frank Piedimonte Scott L. Rocuskie Mark W. SchugMatthew R. ShorbMark SnyderClayton StahlRobert N. Striewig, Jr. Andrew Swank Fred Thompson James W. Van BurenThomas Westrom Kent WibleR. Wayne Willey Kenneth L. Wolf
LIFE DIRECTORSRobert R. BuckleyGeoffrey W. ClarkeTimothy J. CrottyWilliam J. CummingsDavid L. DillonCyril C. Dunmire, Jr.James F. EckmanDominic P. GirondoDaniel R. HawbakerJohn R. Kibblehouse, Sr.John J. McCormick, Jr.James D. Morrissey, Jr.Stephen M. Muck Michael A. Palo Bruce B. Rambo Wayne M. SchugKevin R. SchultzRichard E. Wagman
ASSOCIATED PENNSYLVANIA CONSTRUCTORS
7www.paconstructors.org
EVP Column
There is a need to recruit and retain qualified and experienced employees at all levels into the highway construction and design industry in order to provide the public with safe, quality-driven projects.
Contributing to improving the quality of transportation products (bridges, pavements, ancillary work) and services can be achieved by establishing a coordinated effort that will enhance the skills and expertise of all individuals responsible for the construction of transportation projects.
The Transportation Quality Initiative Workforce Groups is developing a joint marketing plan to promote available careers in the Pennsylvania Transportation Industry resulting from the funding provided by Act 89. We will solicit support (financial and administrative) for the marketing plan from the Governor, Secretary of Transportation, Turnpike Commission, Secretary of Education and Industry Associations.
Also, we need to initiate public outreach efforts with the Governor, Departments of Transportation and Education, PA Turnpike Commission and PHIA to educate the public about career opportunities in the PA Transportation Industry. Networking with academia will produce curriculums that focus on providing the appropriate skills sets to potential employees.
This issue features some private efforts by contracting and engineering firms and trades that can serve as models for future efforts.
We also note that the Pennsylvania Turnpike’s CEO Internship Program is introducing our industry to minority students to promote diversity in the industry. Explore this issue and learn how these organizations are shaping the future transportation problem solvers.
Keep Highway Users Money for Intended PurposeHow does the public feel about diverting resources from the Motor License Fund for non-transportation uses? Last spring, a year and a half after passage of Act 89, we asked the following question in a public opinion poll of registered voters:
“In 2013, Pennsylvania increased gasoline taxes and license and registration fees to pay for transportation improvements. Would you favor or oppose using some of this money to fund other non-transportation items in the state budget?”
Not surprisingly, 80 percent opposed diverting the money, with 61 percent of them strongly opposed.
I want to be very clear on the following point: This is not about whether State Police operations need to be funded. Of course they should. And this is not about whether the proposed level of State Police funding is appropriate. We presume that it is, and in any event, it’s up to the General Assembly and administration to make that determination.
This is about how much Motor License Fund revenue should support State Police activities, given the State Constitution.
Recently the Keystone Transportation Funding Coalition passed a resolution calling for the Legislative Budget and Finance Committee to conduct a study of this issue, to determine the appropriate and justifiable level of support for State Police from the Motor License Fund, given the Pennsylvania Constitution. The industry supports that request.
We ask also that there be no more increases in money diverted from the Motor License Fund to support State Police until we have determined what the appropriate and justifiable level of support is, and that the funding be maintained at that justifiable level in the spirit of Pennsylvania’s Constitution.
Robert Latham
7www.paconstructors.org
Transportation Quality Initiative Seeks to Build QUALITY Workforce
by Robert E. Latham, CAE, APC Executive Vice President
8 Spring 2016HIGHWAY BUILDER
Based on the book by Colin Woodard, Washington Post writer Reid Wilson of the recent article entitled “Which of the 11 American Nations do you Live in?” identifies Pennsylvania as traversing three regions made up of several “nations.” Those regions include the following: “The Midlands (southern Central to Southeast) are pluralistic and organized around the middle class, and ethnic and ideological purity isn’t a priority;” “Greater Appalachia (Southwest to West) where Irish, English, and Scottish settlers value individual liberties;” and “Yankeedom (northern part of the state from East to West) founded by Puritans where they value education and the common good more than any other region.”
According to Wilson, Woodard states that the “nations rival each other in tradition and values.” However, I believe it serves to show the diversity of a state that is often looked at politically as one that is a “swinging” pendulum.
However, this pendulum, especially in the Central Pennsylvania Region, has seen an upswing in young professionals making a decision to either move to or remain in the area. According to then Deputy Editor Heather Long in a July 23, 2011, Patriot News article, “the 2010 census figures actually show slight increases in the numbers of young professionals – ages 24 to 35 – in Cumberland and Dauphin counties compared to 2000, the 20-29 age group remains due to relatively low cost of living, civic involvement, family ties, and the plentiful professional jobs in the Harrisburg region.”
While the Central Pennsylvania area has stabilized the “brain drain,” and many young professionals remain in the area (53 percent of the
Feature
Central PA Diversity Enhan
ced
by PA Turnpike CEO
Fellows Program for
Diverse Groupsby Myneca
Y. Ojo, Director of Dive
rsity and Inclusion,
Pennsylvania Turnpike Co
mmission
9www.paconstructors.org
Harrisburg Young Professionals are from Central Pennsylvania), the perception that cultural and racial diversity does not exist in the area – and certainly not in comparison to nearby economic markets such as Baltimore, Philadelphia, Pittsburgh, and Washington, D.C. – is a reality that impacts retention. Central Pennsylvania has struggled to sustain diverse populations of people who would contribute greatly to the cultural landscape.
Those attracted to the bright lights of major cities often overlook the opportunities to enjoy on a much-smaller and less-crowded scale, all the amenities of an area such as Harrisburg, Lancaster, or York with its affordable living, solid night life, arts, and ample dining options. As Long states in her article, “it’s a place where you can immediately be a big fish in a small pond.”
As stated earlier, the Commonwealth is made up of three “nation states,” and Central Pennsylvania remains true to not making one group or tradition a priority. This is evident especially where you may commonly see 10 different teams represented at any given time at a Central PA sports bar. The Central Pennsylvania Region is often compared to the same standard as those larger, nearby economic markets, however, understated is the message of the commitment to education, middle-class values, and pluralism that enhances diversity and inclusion. This is a message that must be heard by professionals we are attracting or working to retain in this area.
As a major employer in the region, the Pennsylvania Turnpike Commission recognized the challenge and developed the CEO Intern Fellows Program for Diverse Groups. It is a program designed to introduce high-achieving college juniors, seniors, and recent college graduates from all disciplines to careers in transportation through a summer-long fellowship held primarily at the Turnpike’s Central Office in Middletown.
The fellowship includes working and maintaining individual responsibility in a department, as well as being part of a team that collaboratively works to find a solution to high-level issues within the Commission.
The Fellows program has significant oversight by the Chief Executive Officer who personally selects applicants from across the region to participate in the 12-week program. While there is an emphasis on the STEM (Science, Technology, Engineering and Math), all academic disciplines are welcome.
The pipeline to accessing diverse talent must include working directly with colleges and universities, community organizations, and business associations. Connecting community, academia, and employers to the Commission’s commitment to a diverse workforce is vital in helping to make the CEO Intern Fellows program a success.
Programs such as this are key to capitalizing on an existing pool of available talent by ensuring they are provided with real work experiences that will eventually motivate them to see why the Central Pennsylvania Region can be a viable employer.
By addressing recruitment and retention objectives with consistent messaging and ongoing commitment from academic institutions, major employers, and the community that supports the diversity of the Commonwealth, Central Pennsylvania can serve as the “ideal place to live and work.”
Myneca Y. Ojo is the director of Diversity and Inclusion with the Pennsylvania Turnpike Commission, where she leads the efforts to promote diversity and inclusion employment and contracting. Prior to the position at the Turnpike,
Ms. Ojo was the manager of Diversity and Special Initiatives with the Maryland Department of
Transportation State Highway Administration. She has also served as the project director for the U.S. Department of Commerce Minority Business Development Center’s Texas Minority Business Opportunity Committee, which served historically underutilized businesses in the Austin-Waco-Central Texas area with business training and certification services.
SALES-RENTAL-SERVICE-PARTS
Project Management Construction Management Construction Inspection Dispute Resolution 610-992-9090 www.jbcassociates.com D/WBE
10 Spring 2016HIGHWAY BUILDER
Feature
Leadership Group Seeks to Move TQI from the C-Suite to the Project
10 Spring 2016HIGHWAY BUILDER
The TQI Joint Leadership Team met in March to begin the implementation phase of elevating quality in performance throughout the industry. The questions we are trying to answer are:• How do we make TQI matter on the jobsites across the state?• How do we make it real?
We need access to the people on the jobsites through their organizations to deliver the message that “quality is important.” The budget stalemate set the TQI effort back several months, what with the travel ban and uncertainty of the program. Meanwhile, some progress has been made in terms of implementing programs such as percent-within tolerance, reduction in mix designs, and implementing the escalation matrix. Now needed is the job of integrating TQI with the Innovation Council and engrain the concepts in our day-to-day operations.
The partnering process may provide a job-by-job access to those involved to deliver the message from leadership directly to the field. Partnering is not a one size fits all. Each project should look at specific partnering needs and tailor the process to those needs.
One issue the group struggled with is how to “free up” decision-making at the project level. APC representatives question whether auditors are stifling the decision process that is needed for corrections in the field. A possible result is reduced quality or longevity of product due to reluctance to address work not included within the original contract. No one wants to be second guessed. This is becoming more of an issue within the industry because things change on jobs, and when they do they need to be effectively addressed.
The Workforce Team is set to promote careers in the industry. A task is to identify various positions and map out possible career paths so these can be shared with interested individuals.
We all need to enhance recruitment processes. For example, the Workforce Team has applied for a grant from FHWA’s “Ladders to Opportunity” program. This grant could fund a statewide version of the CAWP construction app for high school students to gain interest in construction careers. Additionally, integration with STIC can bring a closer connection with our “university connection” through the many Pennsylvania universities involved in engineering and transportation.
The Technical Team would like to add requirements in pilot projects for contractors to hire a quality control person, independent from the production side of the business and focused solely on the quality side. This would provide the contractor with their own inspector to work with.
Finally, the Joint Leadership Team agreed to reconvene in June to review further progress and to continue to seek industry and agency feedback as to whether we continue to make advancements toward quality.
workforce
process technical
transportation quality initiative
Leadership culture
11www.paconstructors.org
Lindy PavingTrumbull
Gulisek
FULL SERVICE CONSTRUCTION FOR HEAVY HIGHWAY
225 North Shore Drive, Pittsburgh, PA 15212
412.807.2000www.trumbullcorp.com
703 913 7858 www.neelco.com I-95 Girard Ave. Interchange Reconstruction Project Philadelphia, PA
T-WALL provided a value-engineered solution that eliminated deep foundation improvements for over 1600 LF of retaining walls.
Contact us to discuss an innovative T-WALL solution for your project needs.
12 Spring 2016HIGHWAY BUILDER
Feature
12 Spring 2016HIGHWAY BUILDER
by Jerry Marks, TriAd Marketing & Media
13www.paconstructors.org
as the third highway construction season since the passage of Act 89 begins in Pennsylvania, “opportunity” and “infusion of work” is being met with “workforce gaps” and “limited numbers of qualified candidates.”
Associated Pennsylvania Constructors' members agree that the outlook for transportation construction in Pennsylvania is brighter since the signing of Act 89 in November 2013, but the bill has also spotlighted the dim reality facing many contracting groups: the need for skilled workers.
“Act 89 has enabled many of Pennsylvania’s heavy civil contractors to take advantage of shovel-ready infrastructure and breathe new life into their business,” said H&K Group’s Anthony Jeremias. However, the Skippack-based company’s public relations/marketing director said the
ability to take advantage of the influx of work comes with its own set of issues. “Like many other companies in our business
sector, The H&K Group continues to see a decline in available, qualified/skilled labor capable of
performing much of the heavy-civil infrastructure work in the project pipeline.”
RETTEW’s Jeffrey Case, P.E., and Mary Ellen Eshelman, SPHR, also provide the glass-
half-full-half-empty dilemma of Act 89, which is expected to provide
the Commonwealth with its biggest increase in transportation funding in decades. “Act 89 identified new, and strengthened existing, funding sources for
transportation projects,” said Case, RETTEW’s director of
Transportation Services. “As a result, monies began to flow to projects; allowing
both heavy construction and design firms, like RETTEW, to see an uptick in jobs available.”
However, what Eshelman is seeing at the Lancaster-based design and
consulting firm as RETTEW’s director of Human Resources, is similar to
what H.R. personnel are seeing throughout the state: “A limited number
of qualified candidates exist, with both the experience and technical skills
to keep transportation projects at every level – municipal, county, state, and
federal – moving forward strongly,” she said.
According to the Pennsylvania Department of Labor & Industry
and the U.S. Department of Labor’s Bureau of Labor Statistics,
Pennsylvania began 2016 with a 4.6 percent unemployment rate. That
is a good barometer of how much the Commonwealth’s economy has
rebounded since the Great Recession’s 8.7 percent unemployment rate
in April 2010. While it’s a positive sign that Pennsylvania has added
73,000 workers across all market sectors in the past 70 months, it
also demonstrates why the state’s heavy-civil construction industry is
waving a red flag. Employment projections by the PA Dept. of Labor &
Industry have the state’s highway building industry adding more than
4,300 employees annually through 2022.
“The challenge is finding a skilled workforce that really wants to
become involved in our industry,” said Oldcastle Materials Mid-Atlantic
Region President Mark Snyder. “That has been a challenge that has been
going on for several years, but certainly has been highlighted the last
couple of years.
“It is becoming increasingly more difficult to find good quality people to
work in the fields in our industry. That goes for subcontractors, DBE and
MBE contractors as well.” Pennsy Supply is a subsidiary of Oldcastle
Materials’ Mid-Atlantic Region, which is headquartered in Harrisburg.
The views of APC members mirror the findings of AGC of America’s
2016 Construction Outlook Survey for Pennsylvania, released last
December. Of respondents across all construction sectors, 46 percent
believe it will continue to be hard or harder to find and hire qualified
construction professionals in 2016 compared to 2015. With 46 percent
of respondents “unsure,” only 8 percent believe it will continue to be easy
or easier to find and hire qualified construction professionals this year
compared to last.
With revenue from Act 89 continuing to build toward 2018’s projected
$2.3-billion amount in additional annual transportation infrastructure,
companies involved in the state’s transportation construction industry are
diligently working to ensure they have the needed amount of personnel
to perform the work.
the challenge is finding a skilled workforce that really wants to become involved in our industry.
act 89 has enabled many of Pennsylvania’s heavy
civil contractors to take advantage of shovel-ready
infrastructure and breathe new life into their business.
14 Spring 2016HIGHWAY BUILDER
“Demand for talented engineers with solid infrastructure experience is beginning to increase. To win the talent war, we focus resources on recruiting and retention of the best talent,” said The Burns Group’s Matt Burns. The president/CEO of the Philadelphia-based engineering design and management consulting services group added, “This is the top strategic goal for everyone at Burns. Attracting new employees is really about convincing top talent – who have choices – that Burns is their best choice.”
With so many companies seeking skilled and talented employees, APC members are conducting recruiting initiatives ranging from having full-time recruiters on staff, utilizing external sourcing methods, job fairs, and looking to hire from within their own company.
“An internal sourcing method that has been particularly successful for us is our Employee Referral Program, which engages our current workforce in the hiring process and offers a generous referral bonus,” Eshelman said. “… Each week, all staff receive an employee update with a list of open positions; the same information is discussed at meetings throughout all levels of the company.”
“Supervisors play a critical role in identifying employee potential and coaching team members to the next level,” Snyder said. “This involves regular and honest feedback and a development plan that identifies job skills, gap training and rotational opportunities to build value. We also
conduct employee surveys to measure the level of employee engagement, so we can be continuously improving.”
When it comes to external recruiting, companies rely on job fairs, such as The H&K Group’s career event held in mid-March that attracted 186 applicants. Companies are also focusing on providing more internships in areas where there is future employment need, and partnering with vendors so employees can receive information and operating instruction on equipment.
“There has been a better focus on employee retention and hiring practices, and looking for good quality employees since Act 89, no question” Snyder said. “We realized we need to have a solid workforce, and we continue to develop our own workforce as well …”
It’s Not Just About NumbersAlong with APC members and other transportation construction businesses vying for the best talent and putting their best foot forward in attracting new employees, companies also want to make sure the candidate is a good fit for their company.
“The challenge is to maintain our culture with new employees,” said Wagman Inc. Sr. V.P. of Human Resources Bill McCrudden. “We don’t want to compromise our values, or change the family company atmosphere. At Wagman, we’re fortunate to have a lot of employees that have spent the majority of their careers with us. Consequently we ask
apc members are conducting recruiting initiatives ranging from having full-time recruiters on staff, utilizing external sourcing methods, job fairs, and
looking to hiring from within their own company.
there has been a better focus on employee retention and hiring practices, and looking for good quality
employees since Act 89.
15www.paconstructors.org
them to help us with new employees, whether it’s mentoring or instilling our values and culture.”
Companies such as Wagman, based in York, have increased their workforce by up to 35 percent over the past 18 months – due in part to Act 89’s passage. “We are seeing a lot of opportunities in all of our markets, including the Heavy Civil Group, Geotechnical Group and Grooving & Grinding Operations,” McCrudden said.
While some companies and construction areas – such as bridge construction – are benefitting already from Act 89, other groups, have yet to see the insurgence of expected work. Snyder said the passage of Act 89 has provided “peace of mind” and “stability” for the transportation construction industry, however, he said it hasn’t reached all areas of the state and industry. “We’re looking forward to a good solid future,” he said. “To date, it hasn’t had a lot of impact on us … In some of the districts you’ve seen a significant increase, but in most of the places that we work it has been pretty stable the last several years. So it hasn’t changed much.”
“Act 89 holds promise for our industry and firm,” added Burns. “… Specifically we’ve seen SEPTA launch their ‘Decade of Investment’ to rebuild public transportation after years of under-investment (and) PennDOT signaled it would be restarting some previously shelved projects. But progress has been much slower than anticipated for highway work.”
Still, as groups like Pennsy Supply, Burns Group and others are waiting for an insurgence of work in their individual areas, they remain proactive in readying their Post-Act 89 workforce.
ADVANCEDTIMBER PILE
UPLIFT ANCHORSAND POINTS
PO Box 688 • Franklin Lakes, NJ 07417-0688201-337-5748 • fax: 201-337-9022 • www.pileline.com
Hard cutting timber pilepoints help make any jobrun more smoothly anddependably.
Timber pile points protectpile tips from failure. Pointswill help drive through rubbleand other tough conditionswithout undermining thestrength of the pile. Pointsare made in one piece of1/4" low-alloy cast steel.
Our TP-807 timberanchors are made fromTUFLOY cast steel (90 ksi tensile, 60 ksiyield) and are galvanized.Quick assembly in thefield with just holes drilled through the pile. DFP casts integral teethinto each uplift anchor to provide extra “bite” into the timber pile.
A full set is needed for30 ton uplift and 1/2 setfor 15 ton uplift.
Uplift Resistance Anchors
TP-337
TP-807
Timber Pile Points
Editor’s note: Thank you to the following APC members for contributing to this article:
Anthony Jeremias, The H&K GroupMark Snyder, Pennsy Supply Inc.Bill McCrudden, Wagman Inc.Matt Burns, The Burns Group
Jeffrey Case and Mary Ellen Eshelman, RETTEW
16 Spring 2016HIGHWAY BUILDER
Equipment Corporation of America (ECA) was founded in 1918 as a provider of construction, industrial and material handling equipment. Today, ECA focuses primarily on providing the latest technology available to service the Foundation Industry. Through an exclusive partnership with Bauer Machine Group, ECA is the only partner company in the world to offer authorized sales, rental and service solutions for Bauer equipment.
S E R V I C E S & T E C H N O L O G I E S
➭ New and Used Equipment Sales and Rentals➭ Large Diameter Drill Rigs➭ Earth Retention & Micropile Drills➭ Fixed and Telescopic Mast Mobile Piling Rigs➭ Pile Driving Equipment - Diesel - Hydraulic Impact - Free Hanging Vibratory Hammers - Excavator Mounted Vibratory Hammers - Excavator Mounted Side Grip Vibratory
Hammers - Soil Mixing and Slurry Wall Equipment
➭ Drilling Tools and Accessories - Rock Augers - Core Barrels - Digging Buckets➭ Overburden Drilling Systems➭ Sectional Casing Systems➭ Equipment Service and Rebuilding➭ Welding and Fabricating➭ Field Service Fleet➭ Replacement Drill Teeth➭ Parts and Accessories
WE ARE the CORNERSTONE of the FOUNDATION INDUSTRY.
Find out how we can build a foundation together. 1.800.PILE-USA -or- www.ecanet.com
EQUIPMENT CORPORATION OF AMERICA
➭ PITTSBURGH 412.264.4480
➭ WISCONSIN 262.345.5715
➭ PHILADELPHIA 610.626.2200
➭ NY/NJ 732.888.5477
➭ WASHINGTON, D.C. 301.599.1300
➭ GREENSBORO 336.854.1220
➭ TORONTO 800.760.0925
➭ BOSTON 508.821.4450
➭ JACKSONVILLE 904.284.1779AUTHORIZED DEALER:
B U I L D I N G F O U N D A T I O N S S I N C E 1 9 1 8
ECA-Ad-HBMag-17x11.indd 1 3/23/16 2:30 PM
17www.paconstructors.org
Equipment Corporation of America (ECA) was founded in 1918 as a provider of construction, industrial and material handling equipment. Today, ECA focuses primarily on providing the latest technology available to service the Foundation Industry. Through an exclusive partnership with Bauer Machine Group, ECA is the only partner company in the world to offer authorized sales, rental and service solutions for Bauer equipment.
S E R V I C E S & T E C H N O L O G I E S
➭ New and Used Equipment Sales and Rentals➭ Large Diameter Drill Rigs➭ Earth Retention & Micropile Drills➭ Fixed and Telescopic Mast Mobile Piling Rigs➭ Pile Driving Equipment - Diesel - Hydraulic Impact - Free Hanging Vibratory Hammers - Excavator Mounted Vibratory Hammers - Excavator Mounted Side Grip Vibratory
Hammers - Soil Mixing and Slurry Wall Equipment
➭ Drilling Tools and Accessories - Rock Augers - Core Barrels - Digging Buckets➭ Overburden Drilling Systems➭ Sectional Casing Systems➭ Equipment Service and Rebuilding➭ Welding and Fabricating➭ Field Service Fleet➭ Replacement Drill Teeth➭ Parts and Accessories
WE ARE the CORNERSTONE of the FOUNDATION INDUSTRY.
Find out how we can build a foundation together. 1.800.PILE-USA -or- www.ecanet.com
EQUIPMENT CORPORATION OF AMERICA
➭ PITTSBURGH 412.264.4480
➭ WISCONSIN 262.345.5715
➭ PHILADELPHIA 610.626.2200
➭ NY/NJ 732.888.5477
➭ WASHINGTON, D.C. 301.599.1300
➭ GREENSBORO 336.854.1220
➭ TORONTO 800.760.0925
➭ BOSTON 508.821.4450
➭ JACKSONVILLE 904.284.1779AUTHORIZED DEALER:
B U I L D I N G F O U N D A T I O N S S I N C E 1 9 1 8
ECA-Ad-HBMag-17x11.indd 1 3/23/16 2:30 PM
18 Spring 2016HIGHWAY BUILDER
There are many avenues to follow in choosing a career path. Some individuals are led toward a construction degree program,
while others gravitate to hands-on vocational-technical training.
Whether deciding to build a career in engineering, construction management and technology, or as a
skilled tradesperson, the industry offers challenging work and unlimited potential.
Read on for a sampling of the vast opportunities available
for building a career in construction.
The future is wide open.
18 Spring 2016HIGHWAY BUILDER
Feature we build futures
19www.paconstructors.org
The Heavy and Highway Carpenters Apprenticeship Program, made possible through a partnership with the Constructors Association of Western Pennsylvania, offers individuals an opportunity to receive training in Concrete Carpentry. Apprentices complete a rigorous four-year program including 576 hours of hands-on and classroom instruction and a minimum of 4,000 hours on-the-job training.
The Heavy and Highway Apprentice Training Program makes choosing a career as a carpenter easy. The minimum application requirements are a high school diploma or GED equivalent and a driver’s license. Then there is a four-step process:1. Complete the application and pay the $25 application fee.2. Take an aptitude test that also includes basic carpentry math skills.3. Participate in an interview with a panel of carpenters and contractors. Their selection decision is based on the test score, construction experience and the future apprentice’s attitude and willingness to work. 4. A four-week PreJob to include: a. Instruction on safety, safety and more safety on our jobsites. b. Basic concepts of bridge construction. c. Drug test. d. Lift test.
Following completion of PreJob, the apprentice receives an instructor rating and is available for hire at the appropriate apprentice rate (first-year apprentice is $20.17 plus benefits). They are sent out to work according to rank and location. Whichever contractor calls in first receives the number one apprentice or our “first-round draft pick” to work on their team.
Apprentices are required to complete four weeks of training each year. We do our best to offer the training in the slower-paced winter months. Training consists of skills, safety and certifications. Basic carpentry, formwork, blueprint reading, math and layout are a few of the many skills taught to our apprentices. Safety cannot be overemphasized for Heavy and Highway Carpenters, and each skill taught includes a
safety lesson. This includes OSHA, Construction Fall Protection, hand and power tool safety, and many other safe construction practices. All apprentices receive certification by third parties for both welding AWS 1.5 structural bridge and rigging, and signaling.
ContinuingEducation
Journeyman Carpenters are encouraged to maintain and advance their skills throughout their careers. Our training facility offers journeyman skill enhancements and upgrade classes in scaffolding, welding, rigging, and signaling, Bidwell, and ADA ramp construction. Safety classes include OSHA 10, OSHA 30, construction fall protection, and confined space.
All Heavy and Highway Carpenters are also given the opportunity to continue their education at the Community College of Allegheny County, offering two Associates Degree programs – Construction Supervision and Construction Estimating. All upgrade classes, including those at CCAC, are offered at no cost.
We strive to provide our signatory contractors with the BEST trained Heavy and Highway Carpenters in the industry. Our four-year apprenticeship program and our continuing education classes provide our contractors with an advantage over the competition by employing skilled, educated, and safe carpenters. The majority of our companies’ foremen and superintendents have progressed through our apprentice program.
If you are looking to choose a career as a carpenter and have $25 to invest in your future, a good attitude, and the desire to learn a trade, check out our website at www.kmlcarpenters.org. There are three training centers in Pennsylvania: Pittsburgh, Altoona, and Lebanon.
Please contact us at:Heavy and Highway Carpenters650 Ridge Road • Pittsburgh, PA 15205 • 412-922-6210Mike Welsh: 412-292-3070Jay Johnson: 412-292-3079
by Michael P. Welsh, Council Representative, Keystone + Mountain + Lakes Regional Council of Carpenters
Featurewe build futures Feature
20 Spring 2016HIGHWAY BUILDER
Connecting With Pennsylvania
College of Technology
by Marc E. Bridgens, Dean, School of
Construction and Design
Technologies, Pennsylvania College of Technology
we build futuresFeature
Looking for an entry-level worker with good foundation skills, sound safety practices, and experience in a hands-on lab environment? A Penn College graduate or current student intern might be the connection your company needs.
21www.paconstructors.org
Pennsylvania College of Technology is a special mission affiliate of The Pennsylvania State University, located in Williamsport. With more than 5,500 students enrolled in more than 100 majors, the college seeks to be a national leader in applied technology. Penn College offers certificates, associate, and bachelor’s degrees, with online options available.
Currently, 89 percent of students are from Pennsylvania with an additional 5.9 percent from New York, New Jersey, and Maryland. Penn College enjoys a 96-percent placement rate for graduates and has been educating students with “degrees that work” for more than 100 years.
Students are enrolled in majors in one of six academic schools: Business & Hospitality; Construction & Design Technologies; Health Sciences; Industrial, Computing & Engineering Technologies; Sciences, Humanities & Visual Communications; and Transportation & Natural Resources Technologies. Any of our associate degrees can continue on in a 2+2 format and lead to a Bachelor of Science in Applied Management Technology. Some popular construction-related degrees reside within two of those schools and could have the graduate or intern you are looking for.
Students in the college’s Heavy Construction Equipment Technology programs complete an operator or technician emphasis, and technicians can specialize in Caterpillar equipment. Operators take classes on diesel engines, hydraulics, electrical, GPS systems, safe operating techniques, blueprints, and grade stakes. The operators finish the degree with more than 450 hours of “seat time” at a 125-acre operations site. The college owns more than 30 pieces
22 Spring 2016HIGHWAY BUILDER
Increase yourmilling and paving
efficiency, productivity,and profitability with
Bortek street sweepers!Reserve yours today!
Increase yourmilling and paving
efficiency, productivity,and profitability with
Bortek street sweepers!Reserve yours today!
SWEEPERRENTALS
EQUIPMENT PARTS RENTALS SERVICE SUPPLIES
FIRST IN POWER CLEANING EQUIPMENT
SWEEPERLAND.COM
A FAMILY COMPANY SINCE 1969800.6.BORTEK®
®
of equipment, and leases equipment each year so students are training with the latest cutting-edge technology. Our technician programs are accredited by Associated Equipment Distributors and require summer internships. Technicians complete classes in:
Diesel engines Three levels of hydraulics Vehicle electronics Fuel systems and emissions
Lab space for those classes total more than 48,000 square feet and features equipment from several manufacturers. Students in both programs earn associate degrees.
Students in Penn College’s Diesel Technology and On-Site Power Generation majors earn associate degrees. Diesel technicians earn their state inspection license and take classes in:
Medium- and heavy-duty trucks Vehicle electronics Emissions Air conditioning and refrigeration
The labs feature an engine dyno and a 2011 Freightliner with Tier 4 emissions. On-Site Power Generation is a unique degree that combines diesel engines with the college’s electrical department for the generation component. Labs feature modern gen sets – several powered by natural gas.
Students in the Surveying Technology program earn an associate degree, and those in Civil Engineering programs can earn an associate or bachelor’s degree. All programs are accredited by the Engineering Technology Accreditation Commission. Students complete classes in:
Materials Hydraulics Hydrology Highway engineering
Advanced classes include:
Land development Structural steel design Reinforced concrete design
Penn College’s 130-acre main campus serves as an outdoor lab space for programs.
Students in the Construction Management program earn a bachelor’s degree that is accredited by the American Council for Construction Education. These students take classes in:
Materials and methods Documents and specifications Estimating Project planning and scheduling Jobsite management
we build futuresFeature
23www.paconstructors.org
RECEIVE.STORE.SHIP.
Whether you need to move thousands of tons of frac sand from rail to truck, or just keep your city’s road salt supply dry, we can help you do that more efficiently. We’ve covered and conveyed bulk materials for some of the largest corporations and some of the smallest towns across the country. Contact us today to learn how we can get you covered on time and within budget.
AT ENERGY INNOVATIONS, WE SPECIALIZE IN BUILDING RELIABLE AND COST-EFFICIENT STORAGE STRUCTURES.
989.777.2314 | energyinnovationsinc.org
If your company is looking for a summer intern or a graduate as an employee, you can build a relationship with Penn College students in a number of ways.
Dedicated scholarships are popular in making that connection with a student early in his or her education. Internships provide an opportunity
to students in the form of experience, but also provide companies with extra workforce during the summer and allow existing employees to act in a mentorship role providing them valuable experience.
Penn College hosts Career Fairs on campus twice during the academic year (fall and spring semesters). Employers come to campus to find the next-generation workforce for their companies. Some employers take
advantage of on-campus recruiting events to hold information sessions about their companies. Students are provided an account with the Penn College Career Hub, an internet-based recruiting system that allows employers and students to connect electronically throughout the year.
An additional resource at Penn College is Workforce Development & Continuing Education, which offers professional development courses and seminars in various business topics. Customized training can be tailored for your company’s specific need.
For more about Penn College, a national leader in applied technology education and workforce development, visit www.pct.edu, email [email protected] or call toll-free 800-367-9222.
Brett Reasner, Dean of Transportation and Natural Resources Technologies [email protected] Marc Bridgens, Dean of Construction and Design
24 Spring 2016HIGHWAY BUILDER
Embrace a Career
in Heavy & Highway Construction
by Steven D. Columbus, Administrative Manager, Western Pennsylvania Operating Engineers Joint Apprenticeship & Training Program
The Western Pennsylvania Operating Engineers Apprenticeship training site includes a new LEED-certified maintenance and classroom building. The site’s “outdoor classroom” includes 138 acres of training area and features 70+ machines in the training fleet. One of the recent additions to the fleet is a Potain tower crane.
24 Spring 2016HIGHWAY BUILDER
Don’t Get Don’t Get
In addition to hands-on
training, Apprentices
attend classroom training
in order to obtain
industry-necessary
certifications.
STUCK STUCK
we build futures
in a Cubicle!in a Cubicle!
Feature
25www.paconstructors.org
The Western Pennsylvania Operating Engineers
Joint Apprenticeship & Training Program is
a non-profit, tuition-free training program
organized for the purpose of providing qualified
Heavy Equipment Operators and Mechanic
Technicians to approximately 600 construction
industry employers in the western Pennsylvania
and eastern Ohio region.
The program has a total of 261 Operator Apprentices and 22 Mechanic Apprentices currently enrolled in their respective courses. Each course is four years in length and combines paid on-the-job training along with related training. The related training takes place at the program’s newly constructed, LEED-certified training facility in New Alexandria.
While attending training, Operator Apprentices receive instruction in the safe, efficient operation of a wide range of heavy construction equipment, from smaller equipment such as forklifts and skidsteer loaders, to large cranes and dozers. Mechanic Apprentices receive training in maintenance, troubleshooting, and repair of the mechanical systems found on various types of construction equipment. Each apprentice must complete a minimum of 200 hours of related training each year. In addition, before graduating, Operator Apprentices must obtain at least 4,000 hours of on-the-job training and the Mechanic Apprentices must obtain at least 6,000 hours.
In addition to Apprenticeship training, the program also offers continuing education, skill upgrade courses, and industry-necessary certifications to the 7,000 journeyman members of Local #66 of the International Union of Operating Engineers.
Approximately 25 percent of the 80,000+ yearly training hours conducted by the program are provided specifically to journeyman.
Course offerings include operator certification for mobile crane, tower crane, and overhead crane through the National Commission for the Certification of Crane Operators, OSHA Construction Outreach Training, First Aid & CPR Training, Forklift Operator Certification, Mine Safety & Health Administration New Miner Training, Pipeline Training, Pipeline Operator Qualification, SafeLand USA, Hazardous Waste Operations & Emergency Response, and Commercial Drivers License skills testing.
Selection for the Apprenticeship Program normally takes place once per year in December or January. During the most-recent selection process, more than 900 applications were received for the Operators Program and more than 100 for the Mechanics Program. The selection process includes testing and interviews. Many graduate apprentices have enjoyed long, successful careers as journeyman Operators and Mechanics. For more information about Apprenticeship in the Operating Engineers, or to be placed on the notification list for future application periods, visit the program’s website at www.wpaoperators.org.
Training scenarios are designed to s
imulate actual
jobsite tasks. In this photo, Apprenti
ces are learning
the skills needed to work effectively
on a “truck fill.”
While participating in hands-on training, Mechanic Apprentices develop many skills that they will need on the job, such as line boring, which these Apprentices are practicing at the Training Site.
26 Spring 2016HIGHWAY BUILDER
LEGAL Update
by James W. Kutz, Esquire, McNees, Wallace & Nurick LLC
Examining A+BX Bidding
While most highway
construction projects
in Pennsylvania are still
awarded by utilizing
the traditional low-bid
method based solely
on contract price,
it is not uncommon
for various state
departments of transportation to use a bid
method known as A+BX bidding. As most in
the industry are aware, the "A" component
of this type of bidding is the actual dollar
amount bid for the contract items, while the
"B" component is the number of days the
bidder estimates are required to complete
the job. The "X" component is a daily dollar
amount determined by the public owner that
is effectively the owner's estimate of the cost
per day of having the roadway at issue closed
to traffic or under traffic restrictions. The
low bidder is determined based on adding
A (contract price) and the product of the
estimated days (B) times the daily amount
(X). While the A+BX formula determines
who wins the bid, the contract amount is still
the "A" component of the equation.
The A+BX method of bidding has been
used on federal highway projects since
approximately the early 1990s. It arose out of
a Transportation Research Board taskforce
on innovative contracting, and ultimately
the A+BX bid method was implemented by
the Federal Highway Administration under
a program entitled Special Experimental
Project No. 14. A+BX bidding is often used
in conjunction with incentive/disincentive
clauses, which can provide an incentive for
the contractor to finish early in addition
to the bid advantage gained by bidding an
aggressive schedule on the BX component.
A+BX bidding is most often used on projects
in high-traffic areas, or may be used if there is
some other urgency, (such as an environmental
issue) which causes the public owner to have
a strong desire to have the project ongoing for
as limited time as possible. A+BX jobs usually
contain both a minimum and maximum
number of days that contractors can bid for
the "B" component. Because A+BX bidding
typically increases the cost of construction,
it is only used on a fairly low percentage of
projects. Some frequently asked questions
about A+BX bidding are set forth below.
What are the advantages and disadvantages
of A+BX bidding?
The obvious primary advantage of A+BX
bidding, and the overriding purpose for
its use, is to minimize the inconvenience
on the traveling public. Proponents of
this method of bidding also believe that
the method encourages contractors to pay
particular attention to minimizing job delays,
maximizing efficiencies, and using innovative
methods to save time. Conversely, opponents
of the method argue that A+BX bidding is
fraught with problems, because: (1) inevitable
changes to a contract are magnified, and
nullify any advantages of the bid method;
(2) more resources are needed for contract
administration and scheduling, which costs are
passed on to the owner; (3) it increases the risk
that a schedule cannot be met and therefore
also increases the likelihood that there will be
a dispute; and (4) because owners frequently
set a daily rate that the contractors perceive
as too high. Additionally, any time work is
accelerated, there is invariably a cost to that
acceleration that must be weighed against the
benefits of an expedited schedule.
How does PennDOT make a determination
as to when to use A+BX bidding?
PennDOT generally sets forth its process
for determining both when to use A+BX
bidding and how to calculate the daily road
user value in its internal Publication 448,
Innovative Bidding Practices. Section 5.2 of
Publication 448 notes that A+BX bidding is
"most effective on projects where there is a
real need to shorten the duration of impact to
high-traffic areas such as business or tourist
areas." This section then identifies five project
types on which the method can be considered
as a possible contracting method, including:
(1) projects that add capacity; (2) projects
where construction is expected to have an
economic impact on local communities; (3)
projects which are relatively free of utility
conflicts, railroads, design uncertainties, or
right-of-way issues, which may impact the
schedule; (4) rehabilitation projects in very
high-traffic-volume areas; and (5) projects
where a "pavement alternate option is
desired." Publication 448 also contemplates
that the A+BX provision may apply to an
James W. Kutz, Esquire
27www.paconstructors.org
entire project or just to specific items of work
if only a portion of the project is subject to the
A+BX component. Publication 448 stresses
that before using the method, emphasis must
be placed on constructability reviews during
design to analyze the project's scope and
potential phasing. While Publication 448
is not a contract document, it does provide
insight as to why PennDOT selects a job for
A+BX bidding.
With regard to calculating the daily road user
costs, Section 5.25 of Publication 448 lists a
number of factors that are to be considered
in determining the daily cost to include as
the "B" component of the bid. These factors
include: (1) the average daily traffic in each
activity year in each direction; (2) the average
daily traffic delayed in each direction by
the project; (3) the total number of vehicles
delayed during the activity and the class of
those vehicles; (4) the number of stopped
vehicles that will be in the work zone during
construction; (5) the added time for travel due
to reduced speeds through the work zone; and
(6) cost factors based on an Engineering News
Record Construction Cost Index. These factors
help PennDOT calculate what is essentially
a road user liquidated damages amount that
is assessed for every day the project finishes
beyond whatever completion date the
contractor establishes in the bid.
Once PennDOT makes the determination to
utilize the A+BX method of bidding, it then
includes a special provision in each contract
to implement the process. In recent years,
contractors raised a concern that different
PennDOT Districts were using slightly
different Special Provisions to implement
the A+BX method, which was making the
bid process more confusing. Contractors
also raised concerns about particular
portions of the Special Provisions for A+BX
jobs, including especially a provision that
purportedly precluded time extensions for
extra work unless the extra work exceeded
5 percent of the overall contract value. As
a result of discussions with APC's Risk
Allocation Committee, PennDOT issued a
Clearance Transmittal in January 2016 that
contained revised Special Provisions for both
interim milestone A+BX bidding and Project
completion A+BX bidding, as well as certain
amendments to PennDOT's Publication
448. These Special Provisions are to be
used on all PennDOT A+BX jobs, and they
eliminate the 5 percent extra work provision.
While these provisions had not yet formally
been adopted when this article was prepared,
it appears likely that they will eventually
become applicable on all A+BX projects for
PennDOT. Thus, the A+BX bid process used
by PennDOT should now be uniform, and the
industry's concern about the 5 percent issue
has also been addressed.
Is the A+BX method of bidding legal?
Whenever a public owner uses an "innovative"
28 Spring 2016HIGHWAY BUILDER
method of bidding, it is not unusual for legal
challenges to such methods. While the use of
A+BX bidding by states is authorized by the
Federal Regulations, there is neither a statute
in Pennsylvania that specifically addresses the
use of A+BX bidding, nor is there any appellate
case law in Pennsylvania that addresses the
use of this method. Indeed, the legality of the
A+BX bid method does not appear to ever
have been vetted by any state or federal court.
In such cases, any court that may be asked to
rule on the legality of the A+BX bid method
would typically look to a more general body of
public bid case law that requires such things
as a level playing field for bidders, for bids
to be awarded utilizing a common standard,
and for bids to only consider objectively
measurable criteria. Given that both the time
and cost components of the A+BX formula
would appear to be objectively measurable
and utilize a common standard, it is likely
that a PA court would find the A+BX method
perfectly acceptable under Pennsylvania law.
One caveat to such a blanket statement that
A+BX bidding is legal in Pennsylvania is based
on language found in recent opinions issued
by both the Pennsylvania Supreme Court
and the Commonwealth Court in Brayman
Construction v. PennDOT. In that case, both
courts enjoined PennDOT from awarding
construction contracts using a "two-step
design-build best-value approach" or "any
other innovative method that does not award
the bid based on field competitive bids." While
A+BX bidding can be classified as "innovative,"
given its use of primarily objective criteria,
an entity challenging the bid method would
undoubtedly face an uphill struggle unless it
can show a particular job has a bid deficiency,
such as including a daily amount as the "X"
component which has no rational basis. However,
to date, the A+BX method has been frequently
used and no legal challenge has been filed.
What are the potential bid issues that arise
when A+BX bidding is used?
The recent use of the A+BX method of
bidding on a PennDOT project involving
six bridges over Interstate 78 highlights the
problems that can occur when A+BX bidding
is used. That project was initially bid in June
2015, and was ultimately rebid twice after
all bids were rejected twice. Changes to the
specifications were made between rounds two
and three after the low bidder on round two
bid an extremely low number of days, and
PennDOT decided to include a minimum
number of days in round three. The I-78 bid
was ultimately awarded to the second low
bidder on the third round of bidding after the
low bidder's bid during the third round was
rejected due to an alleged bid mistake.
As the I-78 job exemplifies, whether it is
PennDOT or any other entity using the A+BX
method, one problem on A+BX projects is
that bid mistakes occur more frequently. It is
not uncommon for bidders to misinterpret the
public owner's specifications, enter a number of
days that are technically not permitted by the
contract, or otherwise make what is arguably
a bid error. While PennDOT's ECMS system
minimizes the opportunity for bid mistakes
on PennDOT projects as compared to the
bid processes used by other state and federal
agencies, the potential for bid mistakes is likely
far greater on A+BX projects than on other
traditionally bid jobs.
Similarly, the I-78 job demonstrates that
re-bids are common on A+BX jobs, because
owners and contractors often take a different
view as to how a bidder may approach such
jobs. Other bid disputes can arise if the
owner has not thoroughly set forth in the
bid documents the various construction
techniques/alternates that may be permitted.
If those methods can have a significant
impact on the number of days the project can
take, the owner may get unexpectedly widely
varying bid results.
Finally, a bid issue may arise if an owner sets
an extraordinarily high daily amount for the
value of each day a project is not open to
traffic. In that event, a bidder's remedy would
be to file a bid protest, most likely before bids
are open to object for what it believes is an
erroneous calculation.
Responsive People I Creative Solutions
www.rkk.com
Engineers | Construction Managers | Planners | Scientists
TransportationEnvironmental / InfrastructureConstruction Management / InspectionUtilitiesSite Development
with offices in York, Allentown & King of Prussia, PA
29www.paconstructors.org
What contract issues exist on A+BX projects
that may not exist on other traditionally bid
projects?
While the contracting differences may vary
widely from project to project and state to state,
it is not uncommon for owners to exclude or
modify their typical scheduling specifications/
time extension specifications on A+BX jobs.
For example, in PennDOT's recent Clearance
Transmittal, the proposed special provision
indicates that Section 108.06 of the Form 408
Specifications, which deals with time extensions
and reductions, "will not apply to any time
reduction or extension of the bidder's number of
consecutive calendar days," but rather provides
that any such extension will be "mutually agreed
upon by both the Contractor and the Engineer."
This provision further contemplates that if an
agreement cannot be reached, the engineer will
make the decision based on the best information
available, and if the contractor disagrees with
that decision it may raise a claim as set forth in
Section 105.01.
Another contract difference between A+BX
jobs and traditionally bid jobs involves the
typical liquidated damages clauses that a
highway construction project may contain.
Under the law, liquidated damages are
required to be a reasonable estimate of the
harm the owner will suffer in the event of
late completion, and if they are not, they are a
penalty, and unenforceable. In the case of an
A+BX project, the "road user" component of
liquidated damages on which public agencies
typically rely is usually fully addressed in
the "BX" component of an A+BX project.
Therefore, such contracts typically should not
contain other separate road-user liquidated
damages, as the enforceability of those
damages would be questionable.
Other contract issues that may differ on
A+BX jobs may involve other typical
timing or date provisions or restrictions on
traditionally bid jobs that simply should never
apply on an A+BX job. The best example of
this is any contract provision that theoretically
"allows" the owner a certain minimum
number of days to review submittals. To truly
derive the benefits of A+BX bidding, a public
owner must be prepared to act much more
expeditiously than it may on traditional jobs.
What are the most likely areas of dispute on
A+BX projects?
Given the high-dollar amount usually associated
TRANSPORTATION & INFRASTRUCTURE
BUILDINGS & FACILITIES
CONSTRUCTION MANAGEMENT
ENERGYSERVICES
Offices in Philadelphia, Douglassville, Harrisburg, Pittsburgh, and WilliamsportContact: Leonard Smith, Jr., PE(717) [email protected]
An employee-owned firmwww.stvinc.com
STV provides value- and quality-driven bridge and roadway designs throughout Pennsylvania and the nation. Whether your project is design-build or traditional delivery, we are committed to successful infrastructure design.
We are 100 percent employee-owned and, with a stake in the business, we focus on what matters most: personal attention, quality, and innovative thinking. Our steady growth is proof-positive that we do it right, one successful project after another; above: PennDOT District 6-0 I-95 Section BRI Reconstruction Betsy Ross Interchange.
Enduring. Driven. Visionary.©
Inte
rvis
ion
New
Med
ia /
Roge
r Sw
ingl
e
30 Spring 2016HIGHWAY BUILDER
LEGAL Update
with every day of an A+BX project (which
dollar amounts may also include incentives for
finishing early), the most obvious source of
any dispute on such projects is the entitlement
to additional time (and compensation) for
any critical path delay. For that reason, A+BX
projects significantly increase the risk on
contractors and owners, as well as third parties.
Contractors not only must be mindful of their
own productivities/staffing and other delays,
but also must be vigilant about potential delays
by subcontractors or suppliers and must address
the risk of those delays in their subcontracts.
Similarly, the owner must be aware that any
delay for which it is contractually responsible,
including utility delays, added work, differing
site conditions, excessive re-bid time or design
errors, may quickly give rise to a huge claim,
particularly if a contractor plans to finish
early. A public owner can face a large delay
claim on A+BX jobs merely by having the job
delayed by third parties such as utilities or other
government agencies.
The high, daily delay penalty associated with
A+BX projects can also effectively force a
contractor to submit a legal challenge in the
event the job is delayed, for whatever reason.
Since the daily cost is calculated in the same
manner as road-user liquidated damages, the
amount must still be reasonable or it could be
classified as a penalty, and thus unenforceable.
While it is unclear how a court may treat such
a challenge, if the penalty imposed for finishing
late is too harsh, a contractor may decide to
have a court evaluate the daily amount.
Another potential area for dispute may arise
if the owner prohibits the contractor from
working nights and weekends to expedite the
job, particularly if it is not expressly prohibited
in the contract. For example, refusing to allow
a contractor to work because inspection forces
are not available can result in a dispute.
Finally, the compressed nature of an A+BX job
can result in many disputes. On a tight jobsite
with limited room for error, any directed change,
which on a typical job may not raise much of
a concern, now may result in both delays and
inefficiencies. Any differing site condition that
requires study and redesign similarly could
create much more of an issue than it might on a
job with a more reasonable schedule.
In summary, while A+BX bidding has its
place, both parties must be ready to move
quickly, and the impact of any significant
change will be considerably magnified.
I.U.O.E.
LOCAL 66 CONTRACTORS DEVELOPERS
I.U.O.E. Local 66 Headquarters111 Zeta Drive Pittsburgh, PA 15238412-968-9120 www.iuoe66.org
For over 100 years Local 66, in partnership with our employers, has been committed to providing Qualified and Competent Operating Engineers. For Local 66, meeting your short and long term employment needs is a priority.
The operating engineers lead the nation in pipeline training.TO BUILD A BETTER FUTURE IN ENERGYAND PIPELINE CONSTRUCTION
WHAT CAN LOCAL 66 DO FOR YOU?
The best trained, most capable work force. Professional tradesman and tradeswomen have received the specialty training needed to meet the complex challenges of your project.
Services you can count on. We’ll work with you to answer any questions or solve any problems at your convenience.
Smart business know-how. You’ll benefit from our years of experience and a proven track record we bring to the job.
Bottom-line dollar-for-dollar value. Value is bringing the highest professional and performance standards to your job site- from the beginning of a project to its completion. We at Local 66 are committed to being the premier value provider of operating engineers in the region.
31www.paconstructors.org
Submit news about your company to Cynthia K. Sells via email at [email protected]
Wagman Clothing Drive Benefits Local Shelters
During the holiday season, Wagman offices in Pennsylvania and Virginia collected clothing and shoes to benefit respective local area shelters. The drive created some friendly competition between the four offices. Wagman averaged pounds per person to figure out which office won the inter-office competition. In total, the company donated 1,350 pounds of clothing to benefit those in need.
• Wagman’s two York, PA, offices collected a total of 965 pounds of clothing, which was donated to Harvest of Blessing Food and Clothing Bank in York.• Wagman’s Berryville, VA, office collected a total of 283 pounds of clothing, which was donated to Blue Ridge Hospice in Leesburg, VA.• Wagman’s Dinwiddie, VA, office collected a total of 102 pounds of clothing which was donated to the Cares Service Center in Petersburg, VA.
Lisa Wagman Glezer, vice president of Communications at Wagman Inc. said, “The spirit of giving was profound and the competition between offices kept it fun. We were thrilled to donate over 1,000 pounds of clothing and shoes to three agencies that benefit the communities where our employees live, work, and play.”
The Berryville, VA, office came in first place with the office competition, averaging more than 35 pounds of clothing donations per person.
The two York, PA, offices collectively donated more than 900 pounds of clothing.
32 Spring 2016HIGHWAY BUILDER
Michael Baker International Tops List of Leading Engineering Firms
Michael Baker International, a global leader in engineering, planning
and consulting services, was recently ranked in the Pittsburgh Business Times as the number one engineering firm in the Greater Pittsburgh Area based on 2015 billings. The company has traditionally occupied the top spot on the list, which is published annually.
“Michael Baker International achieved solid results in 2015 – in Pittsburgh and beyond – by delivering a full continuum of innovative solutions to our clients, many of whom are facing a host of challenges as they restore our nation’s infrastructure,” said Kurt Bergman, CEO of Michael Baker International. “Pittsburgh is our hometown, and we are proud of this latest validation that we make a difference in the communities we serve. The Pittsburgh-based projects we have undertaken are primed to increase efficiency and safety for commuters, businesses, and residents alike.”
Recent Pittsburgh-based projects include:• Greenfield Bridge: Michael Baker serves as the primary construction management and inspection services firm for the $17.5-million project to replace the former bridge.• East Liberty Transit Center: The company partnered with the City of Pittsburgh and a host of other regional stakeholders on this $150-million project that resulted in the construction of a multimodal transit center at the site of the former East Liberty Busway Station. The Engineers’ Society of Western Pennsylvania named the center its 2015 Transportation Project of the Year.• Route 28: The Pennsylvania Department of Transportation enlisted Michael Baker to develop a plan to upgrade a two-mile section of this key north/south artery between the City of Pittsburgh, its northern suburbs, and the Pennsylvania Turnpike. The company has received a host of awards for its work on the project from Engineering News
Record MidAtlantic Division, the Pennsylvania Society of Professional Engineers Pittsburgh Chapter, the Engineers’ Society of Western Pennsylvania, and the American Society of Highway Engineers Pittsburgh Section. Michael Baker also accepted the Grand Conceptor Award for this project at ACEC/PA’s Diamond Awards for Engineering Excellence ceremony, held in Lancaster on March 10.
“In 2016, Michael Baker is poised for continuous growth at a time when our elected officials are focusing more of their attention on the need to invest in and improve our highways, bridges, airports, transportation systems, and more,” Bergman said. “As a company, we will continue to play a critical role in responding to this national imperative.”
The Pittsburgh Business Times published the list of the top 25 engineering firms in the region in its February 12th edition.
Erdman Anthony on List of Top 100 Geospatial FirmsPoint of Beginning (POB) magazine has ranked Erdman Anthony among the top 100 geospatial firms of 2015. The ranking is based on private-sector firms’ geospatial revenue. Erdman Anthony ranked No. 59, with 7 percent of its revenue coming from geospatial projects.
The ranking also reflects information about the geospatial business throughout the United States and beyond. POB collected information on who is working in the geospatial space, where the projects are, what services companies perform, and what kind of equipment is used.
POB helps land surveyors and geomatics professionals in the surveying business succeed through coverage of new technologies and opportunities. The magazine offers practical solutions to surveying and mapping problems, while keeping firms up-to-date on business strategies, the law, and education.
INDUSTRY Briefs
33www.paconstructors.org
New Hire Brings Stormwater Expertise to Firm’s Construction Subsidiary
Thomas J. Wedeking recently joined AMS of Skelly and Loy as an assistant construction project manager/estimator. In addition to his project management and bidding/estimating functions, Wedeking will assist field construction and surveying crews as needed. Wedeking has experience in the implementation of green and conventional stormwater infrastructure construction;
site-specific, best-management practices (BMPs) for erosion control; sediment removal practices; and stormwater-related maintenance efforts. Following more than four years of service in the U.S. Army, he worked on a construction crew at Stormwater Maintenance in Parkton, Md. Wedeking earned a Bachelor of Science degree in Natural Resources Conservation and Management from the University of Kentucky. He recently completed the OSHA 40-Hour HAZWOPER training and the OSHA Permit Required Confined Space Entry training. He also completed the Maryland SHA Erosion and Sediment Control (Yellow Card) training and the Maryland Department of the Environment Responsible Personnel (Green Card) training.
Wagman Project Recognized at MdQIOn Feb. 4, 2016, the Maryland Quality Initiative (MdQI) hosted an Awards of Excellence banquet during the annual MdQI Conference in Baltimore, Md. The Awards of Excellence
acknowledge the commendable efforts of engineering consultants and contractors who have delivered successful public-sector transportation projects in Maryland. Wagman Heavy Civil Inc. (Wagman) was a finalist in the Modal/Municipal – Projects Over $5 Million Category for their MD 4 Bridge Replacement over MD 223 project in Prince George’s County, Md. This $18-million project included the complete reconstruction of dual two-span bridges and also included significant excavation, drainage, base, and asphalt paving to construct new roadway approaches to the bridges. This project had exemplary work performance for quality, production, and safety, and finished seven months ahead of schedule.
For more information about Maryland Quality Initiative (MdQI), visit www.mdqi.org.
Thomas J. Wedeking
34 Spring 2016HIGHWAY BUILDER
INDUSTRY Briefs
Wagman’s Berryville, VA Office Receives United Way Silver Award
On Feb. 18, 2016, Wagman’s Geotechnical Construction office in Berryville, Va., received a Silver Award for its support of the 2015 United Way Northern Shenandoah Valley (NSV) Campaign. The award was presented during the United Way of NSV in Virginia 70th Annual Meeting and Recognition Dinner. The Silver Award recognizes Employee
Campaigns that have a $75-$99 per capita or increased campaign giving by $1,500 or more from the previous year.
TPD Vice President Appointed to College Board of Trustees Philip Wursta, vice president of Traffic Planning and Design Inc. (TPD) and leader in the local civil engineering community, has been appointed to the Bucks County Community College (BCCC) Board of Trustees. The board is comprised of 15 members of the community who meet monthly to govern the two-year, public college, which was founded in 1964. Wursta previously served the college as a long-time board member and past president of the BCCC Foundation.
Wursta received a B.S. in engineering in 1985 from Penn State University and a M.S. in transportation engineering from Villanova University. Outside of his work with BCCC, Wursta leads TPD’s regional transportation engineering efforts. He also serves as the current president of the Bucks County Transportation Management Association. His appointment is a direct correlation to his dedication to the goals of BCCC, which are to provide the opportunity for an accessible, affordable, high-quality education. It is also due to his efforts to safely and intelligently continue to bolster economic development and transportation infrastructure throughout Bucks County and beyond.
Gannett Fleming Cited in National Engineering Competition
Gannett Fleming of Pittsburgh, has earned a National Recognition Award for exemplary engineering achievement in the American Council of Engineering Companies’ (ACEC) 49th annual Engineering Excellence Awards for the renovation of the Squirrel Hill Tunnel in Pittsburgh.
Serving 102,000 vehicles a day, the 4,225-foot-long tunnel had gained a reputation for bottlenecks and incidents involving oversized trailers. Taking
this major portal offline for an extended period, however, risked creating new traffic headaches for drivers and in the surrounding communities.
The project team developed an innovative strategy that allowed the tunnel to undergo the needed upgrades while remaining open. Removal, rather than repair, of 18,000 square feet of severely deteriorated ceiling proved to be a more cost-effective strategy. In addition to increasing vertical clearance, the ceiling removal also increases the tunnel’s light levels, enabling drivers to maintain more consistent speeds day and night.
ACEC recognized 151 projects throughout the nation and the world as preeminent engineering achievements, and all were eligible for top national honors. Judging for this year’s awards – known industry-wide as the “Academy Awards of the engineering industry” – took place in February, and was conducted by a panel of more than 30 engineers, architects, government officials, media members, and academia. Award criteria included uniqueness and originality, technical innovation, social and economic value, complexity, and success in achieving goals.
Winners of the top national awards – including 16 Honor Awards, eight Grand Awards and the prestigious “Grand Conceptor Award” for the year’s most outstanding overall engineering achievement – will be revealed at the annual Engineering Excellence Awards Dinner and Gala, a black tie event to be held April 19, 2016, at the Marriott Wardman Park Hotel in Washington, D.C.
Ryan Smith (Wagman) accepts the United Way NSV Silver Award from Nadine Pottinga, CEO of United Way NSV
35www.paconstructors.org
AECOM..................................................... 21All Crane Rental ........................................... 9ARROW Land Solutions LLC ................. 31Asphalt Shingle Grinding Service Inc. ... IFCMichael Baker International ......................... 6Bortek Industries......................................... 22Buchart Horn Inc. ....................................... 32Cleveland Brothers Equipment Co. Inc. ...BCDFP Foundation Products LLC ................ 15
The EADS Group ...................................... 32Eagle Concrete Products Co. ..................... 21Energy Innovations Inc. ............................. 23Equipment Corporation of America .....16-17Gannett Fleming ..................................... IFCGRL Engineers Inc. .................................... 5Gunn-Mowery Insurance Group ................. 5Hanson Aggregates Pennsylvania ............... 25HDR Engineering Inc. .............................. 28IUOE Local 66 ........................................... 30JBC Associates Inc. ...................................... 9Jilco Inc. ........................................................ 6
Johnson Mirmiran & Thompson Inc. ....... 14Mackin Engineering ................................... 33McTish, Kunkel & Associates .................... 23The Neel Company .................................... 11New Enterprise Stone & Lime Co. Inc. ....... 3RK&K ......................................................... 28STV ............................................................. 29Terre Hill Concrete Products ...................... 27Trumbull/Lindy Paving/Gulisek ................ 11Urban Engineers Inc. .................................... 5Whitman, Requardt and Associates LLP .. 14Witman Engineers & Consultants LLC ...... 3
ADVERTISERS Index
APC800 North Third StreetHarrisburg, PA 17102
Change Service Requested
YOUR MACHINE IS TALKING.ARE YOU LISTENING?
TAKE THE GUESSWORK OUT OF EQUIPMENT MANAGEMENT.
HOW WELL DO YOU KNOW YOUR FLEET?Cat has developed an online quiz to demonstrate what you would gain from smart equipment management. Visit www.cat.com/knowyourfleet to answer 8 questions that can help you increase your uptime and reduce your operating costs.www.clevelandbrothers.com
Technology is changing the construction game – helping businesses work faster, harder, and smarter.
Are you taking advantage of it?
Let VisionLink make fleet management easier, no
matter the make or model. View critical machine
data to run more efficient and productive
operations from anywhere – remote jobsites, from
the office, or around the world. Available via
desktop and mobile devices.
With VisionLink, you’ll gain access to:• Machine hours, locations, fuel burn, idle time, and
much more
• Equipment boundary configurations for better
security
• Fleet health and maintenance data
• Fault codes and alerts via text or email*
• Va