Part C1: Agreement and Contract Data - etenders.gov.za 2017 4 - C1... · under the Contract including compliance with all its ... A Tenderer’s covering letter shall not be included

Tender Documents C1 – 1 Part C1: Agreement and Contract Data Reference no. GRJ5/2017

AIRPORTS COMPANY SOUTH AFRICA GEORGE AIRPORT

CONTRACT NO: GRJ5/2017

ACSA GRJ ENERGY EFFICIENCY UPGRADE

Part C1: Agreement and Contract Data

C1.1 Form of Offer and Acceptance ............................. C1-2 C1.2 Contract Data ......................................................... C1-7 C1.3 Form of Guarantee............................................... C1-16 C1.4 Occupational Health and Safety Agreement ... C1-21 C1.5 Summary of Insurance Arrangements and Claims Procedure .............. C1-22 C1.6 Standard Bid Documents (SDB) ....................... C1-25 SDB 4: Declaration of Interest; SDB 6.1: Preference Points Claim Form in terms of the

Preferential Procurement Regulations 2011; SDB 6.2: Declaration Certificate for Local Production and content; SDB 8: Declaration of Bidder’s Past Supply Chain Management;

Practices SDB 9: Certificate of Independent Bid Determination.

C1.7 Ownership of Plant ............................................. C1-26

Tender Documents C1 –2 C1.1 Part C1: Agreement and Contract Data Form of Offer and Acceptance Reference no. GRJ5/2017



ACSA GRJ ENERGY EFFICIENCY UPGRADE C1.1 FORM OF OFFER AND ACCEPTANCE (Agreement) OFFER The Employer, identified in the Acceptance signature block, has solicited offers to enter into a contract in respect of the following works:

Contract No. GRJ5/2017 for the ACSA GRJ ENERGY EFFICIENCY UPGRADE AT GEORGE

AIRPORT

The Tenderer, identified in the Offer signature block below, has examined the documents listed in the Tender Data and addenda thereto as listed in the Tender Schedules, and by submitting this Offer has accepted the Conditions of Tender. By the representative of the Tenderer, deemed to be duly authorized, signing this part of this Form of Offer and Acceptance, the Tenderer offers to perform all of the obligations and liabilities of the Contractor under the Contract including compliance with all its terms and conditions according to their true intent and meaning for an amount to be determined in accordance with the Conditions of Contract identified in the Contract Data. THE OFFERED TOTAL OF THE PRICES INCLUSIVE OF VALUE ADDED TAX IS

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

.. . . . . . . . . . . . . . .. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . Rand (in words);

R . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . (in figures).

This Offer may be accepted by the Employer by signing the Acceptance part of this Form of Offer and Acceptance and returning one copy of this document to the Tenderer before the end of the period of validity stated in the Tender Data, whereupon the Tenderer becomes the party named as the Contractor in the Conditions of Contract identified in the Contract Data. For the Tenderer: Signature and name of witness: Signature .......................................................... Signature ....................................... Name .......................................................... Name ....................................... Capacity .......................................................... Date ....................................... Name and address of organization . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .


ACCEPTANCE By signing this part of this Form of Offer and Acceptance, the Employer identified below accepts the Tenderer’s Offer. In consideration thereof, the Employer shall pay the Contractor the amount due in accordance with the Conditions of Contract identified in the Contract Data. Acceptance of the Tenderer’s Offer shall form an agreement between the Employer and the Tenderer upon the terms and conditions contained in this Agreement and in the Contract that is the subject of this Agreement.

The terms of the contract, are contained in:

Part T2: Returnable Schedules Part C1: Agreements and Contract Data (which includes this Agreement) Part C2: Pricing Data Part C3: Scope of Works Part C3.5: Generic Specifications Part C3.6: Returnable Technical Schedules

and drawings and documents or parts thereof, which may be incorporated by reference into the Parts above. Deviations from and amendments to the documents listed in the Tender Data and any addenda thereto as listed in the Tender Schedules as well as any changes to the terms of the Offer agreed by the Tenderer and the Employer during this process of offer and acceptance, are contained in the Schedule of Deviations attached to and forming part of this Agreement. No amendments to or deviations from said documents are valid unless contained in this Schedule, which must be duly signed by the authorised representative (s) of both parties. The Tenderer shall within two weeks after receiving a completed copy of this Agreement, including the Schedule of Deviations (if any), contact the Employer’s Agent (whose details are given in the Contract Data) to arrange the delivery of any bonds, guarantees, proof of insurance and any other documentation to be provided in terms of the Conditions of Contract identified in the Contract Data. Failure to fulfil any of these obligations in accordance with those terms shall constitute a repudiation of this Agreement comes into effect. Failure to fulfil any of these obligations in accordance with those terms shall constitute a repudiation of this Agreement. Notwithstanding anything contained herein, this Agreement comes into effect on the date when the Tenderer receives one fully completed original copy of this document, including the Schedule of Deviations (if any). Unless the Tenderer (now Contractor) within five working days of the date of such receipt notifies the Employer in writing of any reason why he cannot accept the contents of this Agreement, this Agreement shall constitute a binding contract between the parties. For the Employer: Signature and name of witness:

Signature .......................................................... Signature .......................................

Name .......................................................... Name .......................................

Capacity .......................................................... Date .......................................

Name and address of organization: Airports Company South Africa The Maples, Riverwoods PO Box 75480 24 Johnson Road, Bedfordview Gardenview Gauteng, 2008. Gauteng, 2047


SCHEDULE OF DEVIATIONS Notes: 1. The extent of deviations from the tender documents issued by the Employer prior to the tender closing

date is limited to those permitted in terms of the Conditions of Tender. 2. A Tenderer’s covering letter shall not be included in the final contract document. Should any matter

in such, letter, which constitutes a deviation as aforesaid become the subjects of agreements reached during the process of, offer and acceptance, the outcome of such agreement shall be recorded here,.here.

3. Any other matter arising from the process from offer and acceptance either as a confirmation, clarification or change to the tender documents and which it is agreed by the Parties becomes an obligation of the contract shall also be recorded here.

4. Any change or addition to the tender documents arising from the above agreements and recorded here, shall also be incorporated into the final draft of the Contract.

1 Subject . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

Details . . . .. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

2 Subject . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

Details . . . .. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

3 Subject . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

Details . . . .. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

4 Subject . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

Details . . . .. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

5 Subject . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

Details . . . .. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

By the duly authorised representatives signing this Schedule of Deviations, the Employer and the Tenderer agree to and accept the foregoing Schedule of Deviations as the only deviations from and amendments to the documents listed in the Tender Data and addenda thereto as listed in the Tender Schedules, as well as any confirmation, clarification or changes to the terms of the offer agreed by the Tenderer and the Employer during this process of offer and acceptance. It is expressly agreed that no other matter whether in writing, oral communication or implied during the period between the issue of the tender documents and the receipt by the Tenderer of a completed signed copy of this Agreement shall have any meaning or effect in the contract between the parties arising from this Agreement.


For the Tenderer: For the Employer: Signature …………………………….. Signature …………………………………………..

Name ……………………………… Name ……………………………………………

Capacity ……………………………... Capacity …………………………………………….

Name and address of organisation Name and address of organisation

………………………………………….. Airports Company South Africa ………………………………………….. The Maples, Riverwoods ………………………………………….. 24 Johnson Road, Bedfordview ………………………………………….. Gauteng, 2008

Witnesses:

Signature …………………………….. Signature …………………………………………..

Name ……………………………… Name ……………………………………………

Date ……………………………... Date …………………………………………….


CONFIRMATION OF RECEIPT The Tenderer, (now Contractor), identified in the Offer part of the Agreement hereby confirms receipt from the Employer, identified in the Acceptance part of this Agreement, of one fully completed original copy of this Agreement, including the Schedule of Deviations (if any) today: the…………………………..(day) of……………………………(month) 20……..(year) at…………………………….(place) For the Contractor: Signature: ……………………………………………… Name: ……………………………………………… Capacity: ……………………………………………… Signature and name of witness:

Signature: ……………………………………………… Name: ………………………………………………

Tender Documents C1 - 7 C1.2 Part C1: Agreement and Contract Data Contract Data Reference no. GRJ5/2017




C1.2 Contract Data C1.2.2 Special Conditions of Contract Variations, amendments and additions to the General Conditions of Contract as Special Conditions of Contract prescribed by the Employer are set out below. Each item of the Special Conditions of Contract given below is cross-referenced to the clause in the General Conditions of Contract to which it mainly applies. The following Special Conditions of Contract as prescribed by the Employer, referring to the General Conditions of Contract for Construction Works, Third Edition, 2015, are applicable to this Contract: The following standardized General Conditions of Contract: General Conditions of Contract for Construction Works (Third Edition) 2015, prepared by the South African Institution of Civil Engineering (SAICE) shall apply to and form the General Conditions of Contract for this contract. Copies of these conditions of contract are obtainable from the South African Institution of Civil Engineering (SAICE), Private Bag X200, Halfway House 1685, Tel: (011) 805 5947, Fax: (011) 805 5971, e-mail: [email protected]. Copies of the General Conditions of Contract are available for inspection and scrutiny at the offices of the Employer and Employers Agent / Engineer. The Pro-formas bound with the General Conditions of Contract 2015, on pages 97 to 117 shall not apply to this Contract and shall be replaced with the documentation bound into this Contract Document.

CLAUSE

DESCRIPTION

1.1 1.3.5 1.1.1.5 1.1.1.16

Definitions The Engineer shall retain copyright and property rights on his documentation, etc. “Commencement date” means the date or written notice from the Employer or the Engineer requiring the Contractor, in terms of clause 5.3, to commence the execution of works.” The Employer’s Agent is also referred to as the Engineer.

2.3 2.3.2 2.3.2.1 2.3.2.2 2.3.2.3

Technical data Add the following sub-clauses: “The originals of all Drawings and Specifications prepared by or on behalf of the Engineer shall remain in his custody and references herein to delivery to the Contractor of Drawings or Specifications shall relate to true copies thereof.”

“The Contractor shall be entitled to receive free of charge, to the extent provided in the Contract, copies of each such Drawing and Specification and to receive, or reproduce, such additional copies as he shall reasonably require.”

“All additional copies, whether provided by the Engineer or reproduced by the Contractor, shall be to the Contractor’s account.”

“One copy of all documents constituting the Contract shall be kept on the Site and be available for perusal by the Engineer or any person authorised by him.”


2.3.2.4

“The Contractor shall, in accordance with the Engineer’s instructions, maintain a register on the Site of all Drawings and revisions thereof in the chronological order in which they are delivered to him.”

4.1 4.1.2

Extent of obligations and liability Amend the first three lines to read: “Where any part of the Works, whether permanent or temporary is designed by the Contractor, he shall, notwithstanding any approval of the Engineer be liable for any error or deficiency in any design, drawing or document and any loss or damage arising out of such error or deficiency.”

4.2 4.4.3

Employers Agent’s instructions “Add the Engineer to the consultation between the Employer and the Contractor. ”

4.9. 4.9.2 4.9.3

Construction Equipment Add the following new sub-clauses: “In order to preclude seizure by the owner of any construction equipment being held by the Contractor on a hire-purchase agreement for the purposes of the contract, the Employer shall be entitled to pay any such owner the amount of any outstanding instalment or other sum owing under any hire or hire -purchase agreement and in the event of his doing so, any amount thus paid by him shall be a debt payable to the Employer by the Contractor and may be deducted by the Employer from any monies owing or that may become owing the Contractor in terms of the Contract, or be recovered at law from the Contractor by the Employer.”

“When entering into any subcontract for the execution of any part of the works, the Contractor shall incorporate in such subcontract, by reference or otherwise, the provisions of this clause in respect of construction equipment brought to the site by the subcontractor.”

5.4 5.4.4

Access to the Site Add the following new sub-clauses:

“The Contractor shall bear all costs and charges for special and temporary rights of way required by him in connection with access to the Site. The Contractor shall also provide at his own cost any additional facilities outside the Site required by him for purposes of the Works.”

5.9 5.9.1

Instructions Add the following paragraph: “All additional copies, whether provided by the Engineer or reproduced by the Contractor, shall be to the Contractor’s account.”

5.11 5.11.4

Suspension of the Works Add the following after “Contractor,” and before “the Contractor: in the second line “5.11.4 “or by reason of any contractor executing construction work, which is not in accordance with, the

Contractor’s Health and Safety Plan for the site or which poses a threat to the health and safety of persons”

5.14 5.14.4

Completion Add the following at the end of this sub-clause:


“However, a Certificate of Completion will not be issued before the Contractor hands over a consolidated Health and Safety file that shall include all the specified information.” The Certificate of Completion will also not be issued until all specifications as per Scope of Work are completed.

6.5 6.5.3

Dayworks In the last sentence: Delete the first word “if” and replace with “when”

6.6 6.6.1 6.6.3

Provisional sums and prime cost sums In the first line of Clause 6.6.1.2.1 after the word ”sums” and the fourth line of Clause 6.6.1.2.2 after the word “amount” insert “excluding VAT.” Delete this sub-clause and replace with the following: “Expenditure in connection with Provisional and Prime Cost Sums shall be solely at the discretion and on the instruction of the Engineer. No expenditure shall be incurred under a Contingency Allowance without the written approval of the Employer. Any parts of the amounts provided under any of the above items in the Bill of Quantities which are not expended shall not be included in the Contract Price.”

6.7 6.7.1

Measurement of the Works Replace the contents of sub-clause (6.7.1) with the following: “The quantities in the Bill of Quantities are nominal quantities which are included solely for the purpose of Tender evaluation. These quantities are not guaranteed, nor have they any other significance in terms of the Contract other than a means of assessing the Tender. Only the actual quantities of work which are executed by the Contractor in fulfilment of his obligations under the Contract will be measured or approved by the Engineer for payment purposes. An alteration of the quantities included in the Bill of quantities shall not affect the validity of the Contract. The Tendered rates and prices shall remain valid and applicable irrespective of any differences between the quantities in the Bill of Quantities and the quantities finally certified for payment.

6.8 6.8.2 6.8.4

Adjustment in rates and/or prices Insert “VAT and” after “excluding” in the parenthesis in the third line. Add “Engineer” after “Employer” in the eighth line.

6.10 6.10.2

Payments Replace the second sentence (commencing “The valuation of such materials ……….”) with the following : “The valuation of such materials shall be based on the purchase price and delivery cost reflected by the relevant invoices or receipts, exclusive of Value Added Tax and discounts to the Contractor and inclusive of any other duties payable on such material. (Value Added Tax will be added only to the nett amount certified by the Engineer as payable to the Contractor in respect of each Payment Certificate.

6.11

Variations exceeding 15 per cent For the purpose of this Tender abovementioned Clause shall change so that 15% (Fifteen percent) reads 100% (One Hundred percent).

7.2 7.2.1

Quality of Plant, workmanship and materials Add the following to this sub-clause: “The onus rests with the Contractor to produce work which conforms in quality and accuracy of detail to all the requirements of the specifications and drawings, and the Contractor shall, at his own expense,


institute a quality-control system and provide experienced personnel, together with all transport, instruments and equipment, to ensure adequate supervision and positive control of the works at all times.”

7.4 7.4.1 7.4.6

Samples and testing Add the following to this sub-clause: Samples must be submitted for approval by the Engineer on all equipment before ordering as well as installation of the equipment. The contractor will be responsible for all rectification costs should any work by condemned because of non-compliance. Add the following to this sub-clause: “The Contractor shall conduct tests or have them conducted continually on a regular basis, to check the properties of natural materials and processed natural materials and of products manufactured on site, such as concrete and asphalt. Although not a requirement for the Contractor to conduct regular tests on any commercially produced products such as cement, bitumen, steel and pipes, the Contractor shall remain fully responsible for any defective material or equipment provided by him. Similarly, the quality of all elements of the works shall be checked on a regular basis so as to ensure compliance with the specified requirements. The intensity of control and of tests to be conducted by the Contractor in terms of these obligations is no t specified but shall be adequate to ensure that proper control is being exercised to the satisfaction of the Engineer. Where any natural materials or products made from natural materials are supplied, upon completion of each element of the construction works, the Contractor shall test and check such materials, products and or elements for compliance with the specified requirements and shall submit his results to the Engineer for approval. Such submission shall include all his measurements and test results and shall furnish adequate proof of compliance with the specified requirements.”

7.6 7.6.3.3

Defective Plant, materials and work Add the following new sub-clause: “To stop any contractor from executing construction work, which is not in accordance with, the Contractor’s health and safety plan for the site or which poses a threat to the health and safety of persons and to implement the required health and safety measures before continuing.”

8.3 8.4.1.1

Expected risks Delete and replace with the following: “hereby indemnifies the Employer, the Engineer and all Consultants against any liability in respect of damage to or physical loss of the property of any person, including any employee of the Contractor, or injury to or death of any person, including any employee of the Contractor and”

8.6 8.6.8 8.6.9

Insurances Add the following new sub-clause: “Where the contract involves manufacturing and/or fabrication of the works or part thereof at premises other than the Site, the Contractor shall satisfy the Employer that all materials and equipment for incorporation in the works are adequately insured during manufacture and/or fabrication. In the event of the Employer having an insurable interest in such works during manufacture or fabrication then such interest shall be noted by endorsement to the Contractor’s Policies of insurance.” Refer to Part C1.5 Summary of Insurance and Claims Procedure

9.2 9.2.1.3.9

Termination by the Employer Add the following new sub-clause:


“Has failed to execute construction work in accordance with the Contractor’s Health and Safety Plan or without a threat to the health and safety of persons within fourteen (14) days after receiving from the Engineer written notice of the same. “

10.1 10.1.6

Contractor’s claim Add the following sub-clause: “Early warning – A Party shall notify the other as soon as he is aware of any circumstance which may delay or disrupt the Works, or which may give rise to a claim for additional payment. The Contractor shall take all reasonable steps to minimise these effects. The Contractor’s entitlement to extension of the Time for Completion or additional payment shall be limited to the time and payment which would have been due if he had given prompt notice and had taken all reasonable steps.”


PART 1: CONTRACT DATA PROVIDED BY THE EMPLOYER The General Conditions of Contract make several references to the Contract Data for specific data, which together with the General and Special conditions collectively describe the risks, liabilities and obligations of the contracting parties and the procedures for the administration of the Contract. The Contract Data shall have precedence in the interpretation of any ambiguity or inconsistency between it and the general conditions of contract. The General Conditions of Contract shall be read in conjunction with the variations, amendments and additions set out in the Contract Specific Data below. Each item of data given below is cross -referenced to the clause in the General Conditions of Contract to which it mainly applies. The Contract Data and General Conditions of Contract shall have precedence over the Drawings, Scope of Work and Standardised Specifications in the interpretation of any ambiguity or inconsistency between these documents. The following contract specific data, referring to the General Conditions of Contract for Construction Works, Third Edition, 2015, are applicable to this Contract:

CLAUSE DESCRIPTION

1 1.1.1.13 1.1.1.14 1.1.1.15 1.2.1.2 1.1.1.16 1.2.1.2 1.1.1.26

GENERAL The Defects Liability Period is 12 months. The required time for achieving Practical Completion is as offered by the Tenderer, inclusive of non-working days and inclusive of special non-working days referred to in Clause 5.8.1 below. The Employer is the Airports Company South Africa SOC Ltd (Reg No. 1993/04149/30), GEORGE AIRPORT, represented by the Airport Manager and/or such other person or persons duly authorised thereto by the Employer in writing Address to: Airports Company South Africa SOC Ltd Cnr of R102 & R404, George 9300 The Employer’s Agent is BDE Consulting Engineers, acting through a director or an official authorised thereto in writing The address of the Electrical Engineer is: Address: 73 Meade Street, George PO Box 1862, George 6530 Telephone: 044 – 801 9700 Facsimile: 044 – 801 9709 e-mail: [email protected] / [email protected] The Pricing Strategy is a Re-measurement Contract as defined in Sub clause 1.1.1.27

Field Code Changed

mailto:[email protected]

mailto:[email protected]


3 3.2.3

EMPLOYERS AGENT (ENGINEER) Add the following to this sub-clause: The Engineer is required to obtain the specific approval of the Employer before executing any of the following functions or duties: 1. Clause 3.3.1 Nomination of Engineer’s Representative 2. Clause 3.3.4 Engineer’s authority to delegate 3. Clause 5.8.1 Non-working times 4. Clause 5.11.2 Suspension of the Works 5. Clause 5.12.4 Acceleration instead of extension of time

5 5.3.1

TIME AND RELATED MATTERS The documentation required before commencement with Works are:

1. Health and Safety Plan (Refer to Clause 4.3) 2. Initial Works programme (Refer to Clause 5.6) 3. Security or performance guarantee (Refer to Clause 6.2) 4. Insurance (Refer to Clause 8.6)

5.3.2 1. The Health and Safety Plan is to be delivered within 14 days of the Commencement Date.

2. The Works programme is to be delivered within 14 days of the Commencement Date.

3. The time to deliver the Performance Guarantee; within 14 days of the Commencement Date

(The Performance Guarantee is to contain the wording of the document included in C1.3, Form of Guarantee)

The liability for the guarantee shall be for 10% of the Contract Price

4. Proof of Insurance is to be delivered within 14 days of the Commencement Date.

5. The Commencement of Works shall only follow after above requirements are met and an

instruction is issued by the Engineer.

5.8.1 The non-working days are Sundays The special non-working days are gazetted public holidays falling outside of the year end break and the days on which the contractor grants the majority of his permanent workforce leave around the 15 th December and the first Monday of the subsequent year (as defined by SAFCEC).

5.13.1 5.14.1

The penalty for failing to complete the Works is 0,5% of the final Contract Price per calendar day of delay. Maximum amount of delay damage is 5,0% of Final Contract Price The requirement to achieving Practical Completion is when the Works is energised and fit for the intended purpose and occupation without danger or undue inconvenience to the Employer.

5.16.3 The latent defects period is 10 years


6 6.5.1.2.3

PAYMENT AND RELATED MATTERS The percentage allowance to cover the relevant overhead charges is 10%.

6.8.2 Contract Price Adjustment

The tender calls for a fix price for the construction period offered in terms of the envisage program of the

Employer.

6.10.1.5

The percentage advance on materials on site, but not yet built into the Permanent Works is 80% upon proof of ownership and insurance. The balance, excluding retention money, shall be paid on a pro-rata basis measured in accordance with the % of the items installed and ready for testing and commissioning. Payment to the Contractor for any materials on site shall only be authorized after proof of ownership by the Contractor has been lodged with the Engineer in the form of receipted invoices and ce rtification in the wording of the document in C1.7 Ownership of Plant

6.10.3 Notwithstanding the provision of a performance guarantee in terms of Clause 6.2.1, interim payments to the Contractors shall be subject to retention by the Employer of an amount of 10% of the said amounts due to the Contractor. The limit of retention money is 5% of the Contract Value, including allowances for contingencies and Contract Price Adjustment. The retention applicable to the Defects Liability Period is 2.5% of the Contract Value. A guarantee in lieu of retention is permitted for the latent defects period.

8 8.6.1.1.2

RISK AND RELATED MATTERS The value of Plant and materials supplied by the Employer to be included in the insurance sum is R 0.00 (Nil).

8.6.1.1.3 The amount to cover professional fees for repair or reinstatement of damage to the works to be included in the insurance sum is R200,000.00

8.6.1.3 The limit of public liability insurance is R5,000,000.00 per claim

10 10.5.3

CLAIMS AND DISPUTES The number of ad-hoc Adjudication Board Members to be appointed is 1(one).

10.7.1 Disputes are to be referred for final settlement to arbitration.


PART 2: DATA PROVIDED BY THE CONTRACTOR Clause 1.1.1.9: The name of the Contractor is : ........................................................................................................................... Clause 1.2.1.2: The address of the Contractor is Physical ................................................................... Postal ................................................................... Address: Address: ................................................................... ................................................................... ................................................................... ................................................................... ................................................................... ................................................................... Telephone : ................................................................... Fax: ................................................................... e-mail : ................................................................... Clause 1.1.1.14: Time for achieving Practical Completion is ………………………………weeks. Clause 6.2.1: The security to be provided by the Contractor shall be a Performance Guarantee of 10% of the Contract Sum. Clause 6.5.1.2.3:

The percentage allowance to cover the relevant overhead charges is 10%. Clause 6.8.3: The variations in cost of Special Material and Contract Price Adjustment Schedule shall be indicated in Part T2, Form C9: Returnable Documents.

Signed

Date

Name

Position

Tenderer

Tender C1 - 16 C1.3 Part C1: Agreement and Contract Data Form of Guarantee Reference no. GRJ5/2017

C1.3 PERFORMANCE GUARANTEE (Pro-forma)



ACSA GRJ ENERGY EFFICIENCY UPGRADE Tender reference no. GRJ5/2017, WHEREAS Airports Company South Africa (hereinafter referred to as the Employer”) entered into, a Contract with: . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

(Hereinafter called “the Contactor”) on the . . . . . . . . . day of . . . . . . . . . . . . . . . . . . . . . . . . . . . .20. . . ,

For Contract No. GRJ5/2017 for the ENERGY EFFICIENCY UPGRADE AT GEORGE AIRPORT

AND WHEREAS it is provided by such Contract that the Contractor shall provide the Employer with

security by way of a guarantee for the due and faithful fulfilment of such Contract by the Contractor; AND WHEREAS . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . has / have at the request of the Contractor, agreed to give such guarantee; NOW THEREFORE WE . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . do hereby guarantee and bind ourselves jointly and severally as Guarantor and Co-principal Debtors to the Employer under renunciation of the benefits of division and exclusion for the due and faithful performance by the Contractor of all the terms and conditions of the said Contract, subject to the following conditions: 1. The Employer shall, without reference and / or notice to us, have complete liberty of action to act in

any manner authorized and/or contemplated by the terms of the said Contract, and/or to agree to any modifications, variations, alterations, directions or extensions of the completion date of the works under the said Contract, and that its rights under this guarantee shall in no way be prejudiced nor our liability hereunder be affected by reason of any steps which the Employer may take under such Contract, or of any modification, variation, alterations of the completion date which the Employer may make, give, concede or agree to under the said Contract.

2. This guarantee shall be limited to the payment of a sum of money. 3. The Employer shall be entitled, without reference to us, to release any guarantee held by it, and to

give time to or compound or make any other arrangement with the Contractor. 4. This guarantee shall remain in full force and effect until the issue of the Certificate of Completion in

terms of the Contract, unless we are advised in writing by the Employer before the issue of the said Certificate of his intention to institute claims, and the particulars thereof, in which event this guarantee shall remain in full force and effect until all such claims have been paid or liquidated.

1. Our total liability hereunder shall not exceed the Guaranteed Sum of . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .Rand (in words);

R . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . (in figures)


6. The Guarantor reserves the right to withdraw from this guarantee by depositing the Guaranteed Sum with the beneficiary, whereupon our liability hereunder shall cease.

7. We hereby choose our address for the serving of all notices for all purposes arising here from as

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

. . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

IN WITNESS WHEREOF this guarantee has been executed by us at . . . . . . . . . . . . . . . . . . . . . . . . . . .

on this . . . . . . . . . day of . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 20 . . . . . . . .

Signature . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . Duly authorized to sign on behalf of . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . Address . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . As witnesses: 1 . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2 . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . For use with the General Conditions of Contract for Construction Works, Second Edition, 2015 GUARANTOR DETAILS AND DEFINITIONS “Guarantor” means: …………………………………………………………………………………………………. Physical address: …………………………………………………………………………………………………… …………………………………………………………………………………………………… …………………………………………………………………………………………………… “Employer” means: ……………………………………………………………………………. “Contract” means: ……………………………………………………………………………… “Engineer” means: ……………………………………………………………………………….


“Works” means: …………………………………………………………………………………. “Site” means: ……………………………………………………………………………………… “Contract” means: ………………………………………………………………………………… “Contract” means: The Agreement made in terms of the Form of Offer and Acceptance and such amendments or additions to the Contract as may be agreed in writing between the parties. “Contract Sum” means: The accepted amount inclusive of tax of R……………………………………….. Amount in words: … ……………………………………….……………………………………………………. ……………………………………………………………………………………………………………………… “Guarantee Sum” means: The maximum aggregate amount of R………………………………………….. Amount in words: ………………………………………..………………………………………………………. ………………………………………………………………………………………………………………………. “Expiry Date” means: ……………………………………..……………………………………………………..


CONTRACT DETAILS Engineer issues: Interim Payment Certificates, Final Payment Certificates and the Certificate Completion of the Works as defined in the Contract. PERFORMANCE GUARANTEE 1. This Guarantor’s liability shall be limited to the amount of a Guaranteed Sum. 2. The Guarantor’s period of liability shall be from and including the date of issue of this Performance

Guarantee and up to and including the Expiry Date or the date of issue by the Engineer of the Certificate of Completion of the Works or the date of payment in full of the Guaranteed Sum, whichever occurs first. The Engineer and/or the Employer shall advise the Guarantor in writing of the date on which the Certificate of Completion of Works has been issued.

3. The Guarantor hereby acknowledges that: 3.1 any reference in this performance Guarantee to the Contact is made for the purpose of

convenience and shall not be construed as any intention whatsoever to create an accessory or any intention whatsoever to create a suretyship;

3.2 its obligation under this Performance Guarantee is restricted to the payment of money. 4. Subject to the Guarantor’s maximum liability referred to in 1, the Guarantor hereby undertakes to

pay the Employer the sum certified upon receipt of the documents identified in 4.1 to 4.3: 4.1 A copy of first written demand issued by the Employer to the Contractor stating that payment of a

sum certified by the Engineer in an Interim or Final Payment Certificate has not been made in terms of the Contract and failing such payment within seven (7) calendar days, the Employer intends to call upon the Guarantor to make payment in terms of 4,2;

4.2 A first written demand issued by the Employer to the Guarantor’s physical address with a copy to the Contractor stating that a period of seven (7) days has elapsed since the written demand in terms of 4.1 and the sum certified has still not been paid;

4.3 A copy of the aforesaid payment certificate which entitles the Employer to receive payment in terms of the Contract of the sum certified in 4.

5. Subject to the Guarantor’s maximum liability referred to in 1, the Guarantor undertakes to pay to

the Employer the Guaranteed Sum or the full outstanding balance upon receipt of a first written demand from the Employer to the Guarantor’s physical address calling up this Performance Guarantee, such demand stating that:

5.1 the Contract has been terminated due to the Contractor’s default and that this Performance

Guarantee is called up in terms of 5; or 5.2 a provisional of final sequestration or liquidation court order has been granted against the

Contractor and that the Performance Guarantee is call up in terms of 5; and 5.3 the aforesaid written demand is accompanied by a copy of the notice termination and/or the

provisional/final sequestration and/or the provisional liquidation court order. 6. It is recorded the aggregate amount of payments required to be made by the Guarantor in terms

of 4 and 5 shall not exceed the Guarantor’s maximum liability in terms of 1. 7. Where the Guarantor has made payments in terms of 5. the Employer shall upon the date of issue

of the Final Payment Certificate submit an expense account the Guarantor showing how all monies received in terms of this Performance Guarantee have been expended and shall refund the Guarantor any resulting surplus. All monies refunded to the Guarantor in terms of this Performance Guarantee shall bear interest at the prime overdraft rate of the Employer’s bank compounded monthly and calculated from the date payment was made by the Guarantor to the Employer until the date of refund.

8. Payment by the Guarantor in terms of 4 or 5 shall be made within seven (7) calendar days upon

receipt of the first written demand to the Guarantor.


9. Payment by the Guarantor in terms of 5 will only be made against the return of the original Performance Guarantee by the Employer.

10. The Employer shall have the absolute right to arrange his affairs with the Contractor in any

manner which the Employer may deem fit and the Guarantor shall not have the right to claim his release from his Performance Guarantee on account of any conduct alleged to be prejudicial to the Guarantor.

11. The Guarantor chooses the physical address as stated above for the service of all notices for all

purposes in connection herewith. 12. This performance Guarantee is neither negotiable nor transferable and shall expire in terms of 2,

where after no claims will be considered by the Guarantor. The original of this Guarantee shall be returned by the Guarantor after it has expired.

13. This Performance Guarantee, with the required demand notices in terms of 4 or 5, shall be

regarded as a liquid document for the purposes of obtaining a court order. 14. Where this performance Guarantee is issued in the Republic of South Africa the Guarantor hereby

consents in terms of Section 45 of the Magistrate’s Court Act No 32 of 1944, as amended, to the jurisdiction of the Magistrate’s Court of any district having jurisdiction in terms of Section 28 of the said Act, notwithstanding that the amount of the claim may exceed the jurisdiction of the Magistrate’s Court.

Signed at: ………………………………………………………………………………………………………….. Date: ……………………………………………………………………………………………………………... Guarantor’s signatory (1): ……………………………………………………………………………………... Capacity: ………………………………………………………………………………………………………… Guarantor’s signatory (2): ……………………………………………………………………………………... Capacity: ………………………………………………………………………………………………………… Witness signatory (1): ………………………………………………………………………………………….. Witness signatory (2): …………………………………………………………………………………………..

Tender C1 - 21 C1.4 Part C1: Agreement and Contract Data OHS Agreement Reference no. GRJ5/2017



ACSA GRJ ENERGY EFFICIENCY UPGRADE C1.4 OCCUPATIONAL HEALTH AND SAFETY AGREEMENT (To be completed and signed by all Mandatories) OCCUPATIONAL HEALTH AND SAFETY ACT NO. 85 VAN 1993 Note: Section I(1)(xxviii) of the Act defines a “Mandatory” as including “an Agent, a Contractor or a Contractor for Work”. The Employer and the Contractor hereby agree, in terms of the provisions of Section 37(2) of the Occupational Health and Safety Act, Act No. 85 of 1993, herein after referred to as “the Act”, that the Contractor as an employer in its own right and in its capacity as Contractor the execution of the works, shall have certain obligations and that the following arrangement shall apply between them to ensure compliance by the Contractor with the provisions of the Act, namely: 1. The Contractor undertakes to acquaint the appropriate officials and the employees of the Contractor with all

relevant provisions of the Act, and the regulations promulgated in terms of the Act, and 2. The Contractor undertakes that all relevant duties, obligations and prohibitions imposed in terms of the Act

and regulations will be fully complied with, and 3. The Contractor hereby accepts sole liability for such compliance with the relevant duties, obligations and

prohibitions imposed by the Act and regulations and expressly absolves the Employer and the Employer’s Consulting Engineers from being obliged to comply with any of the aforesaid duties, obligations and prohibitions in respect of the work included in the Contract, and

4. The Contractor shall be obliged to report forthwith to the Employer any investigations, complaint or criminal

charge with may arise as a consequence of the provisions of the Act and regulations pursuant to work performed on behalf of the Employer, and shall, on written demand, provide full details in writing of such investigation, complaint or criminal charge.

Signature . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . Duly authorized to sign on behalf of . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . Address . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . As witnesses: 1 . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2 . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .

Tender C1 - 22 C1.5 Part C1: Agreement and Contract Data Summary of Insurance Arrangements and Claims Reference no. GRJ5/2017



ACSA GRJ ENERGY EFFICIENCY UPGRADE C1.5 SUMMARY OF INSURANCE ARRANGEMENTS AND CLAIMS The insurance clauses in this document should be extracted and attached to tender documents and to contracts. SECTION A: DEFINITIONS Landside refers to:

• Areas of the airport before the security points, and

• The restricted area beyond the security points but, within the perimeter of gatehouses, passenger terminals

and cargo buildings

Airside refers to:

• The Apron / manoeuvring areas

• Area within the airside boundary/perimeter fence, excluding the internal areas of the passenger terminals,

perimeter gatehouses and cargo buildings

SECTION B: INSURANCE CLAUSES 1. Insurance requirements for contracts with a value below R50million on the LANDSIDE 1.1 Contract Works

• With regards to contract works claims, the contractor/consultant is responsible for a deductible (excess)

of R250 000.

• Contractors / consultants may re-insure the deductible

1.2 Public Liability

• In the event of a claim against the contractor / consultant for 3rd party property damage the contractor /

consultant will be responsible for a deductible (excess) of R275 000

• In the event of a claim against the contractor / consultant for removal of lateral support, the contractor /


• Contractors / consultants may re-insure the deductibles

1.3 Professional Indemnity

• All consultants are responsible for Professional Indemnity cover of R5million

• Contractors who have a material design element, excluding typical P & G related work, as part of their

scope, are responsible for Professional Indemnity cover of R5million

• In the event of a claim above R5million, the ACSA PI cover will kick in for the amount in excess of R5m.

• Proof of cover in the form of a certificate of insurance should be provided to ACSA before a contract is

signed between ACSA and the contractor and/or consultant.

2. Insurance requirements for contracts below R50million on the AIRSIDE 2.1 Contract Works

• With regards to contract works claims, the contractor / consultant is responsible for a deductible (excess)

of R250 000.

• Contractors / consultants may re-insure the deductible


• In the event of a claim brought against the contractor / consultant for 3rd party property damage the

contractor / consultant will be responsible for a deductible (excess) of R525 000

• In the event of a claim brought against the contractor / consultant for removal of lateral support, the



• In the event of a claim brought against the contractor / consultant for damage to aircraft, the contractor /






scope, are responsible for a Professional Indemnity cover of R5million.

• In the event of a claim above R5million, the ACSA PI cover will kick in for the amount in excess of R5million.



3. Insurance requirements for contracts with a value above R50 million on the LANDSIDE

• Contracts with a value of more R50 million are not automatically covered under the construction policies.

A separate quote is provided by insurers per contract.

3.1 Contract Works With regards to contract works claims, the contractor / consultant is responsible for the following deductibles:

• All Civil Work and Earthworks – R300 000 deductible (excess)

• All other claims – R300 000 deductible (excess)

• Other property insured – R700 000 deductible (excess)



• In the event of a claim brought against the contractor / consultant for 3rd party property damage the








scope, are responsible for a Professional Indemnity cover of R10million

• In the event of a claim above R10million, the ACSA PI cover will kick in for the amount in excess of R10m



4. Insurance requirements for contracts with a value above R50 million on the AIRSIDE

• Contracts with a value of more R50 million are not automatically covered under the construction policies.

A separate quote is provided by insurers per contract.

4.1 Contract Works With regards to contract works claims, the contractor / consultant is responsible for the following deductibles:

• All Civil Work and Earthworks excluding Runways – R300 000 deductible (excess)

• Runway Rehabilitation – R300 000 deductible (excess)

• New Runway Construction – R700 000 deductible (excess)

• All other claims – R300 000 deductible (excess)

• Other property insured – R700 000 deductible (excess)



• In the event of a claim brought against the contractor / consultant for 3 rd party property damage the

contractor / consultant will be responsible for a deductible (excess) of R1 025 000


contractor / consultant will be responsible for a deductible (excess) of R1 250 000

• In the event of a claim for damage to aircraft, the contractor / consultant will be responsible for a deductible

(excess) of R1 250 000






scope, are responsible for a Professional Indemnity cover of R10million

• In the event of a claim above R10million, the ACSA PI cover will kick in for the amount in excess of R10m



Tender C1 - 25 C1.6 Part C1: Agreement and Contract Data Standard Bid Documents Reference no. GRJ5/2017



ACSA GRJ ENERGY EFFICIENCY UPGRADE C1.6 STANDARD BID DOCUMENTS (SDB): The following SDBD documents is attached to this page and

must be completed and signed: SDB 4 (4 pages): Declaration of Interest SDB 6.1 (6 pages): Preference Points Claim Form in terms of the Preferential

Procurement Regulations 2011 SDB 6.2 (4 pages): Declaration Certificate for Local Production and content SDB 8 (2 pages): Declaration of Bidder’s Past Supply Chain Management

Practices SDB 9 (4 pages): Certificate of Independent Bid Determination

Tender C1 - 26 C1.7 Part C1: Agreement and Contract Data Ownership of Plant Reference no. GRJ5/2017


CONTRACT NO: GG/15/06/AB


C1.7 OWNERSHIP OF PLANT (Pro forma) I/We, the undersigned, ……………………………………..………………………………………………. ………………………………………………..……………...…………………………………(Name of the Contractor) hereby declare that the materials for which payment is claimed in terms of Clause 49.1.5 of the General Conditions of Contract that:

1 The material as described on the copy of the Invoice No. ………….. (annexed hereto) supplied pursuant

to the Contract shall become the property of the Client after payment.

2 The material and equipment paid by the Client are set aside and are marked as the property of the Client.

3 It is confirmed that such material and equipment are in the care of the Contractor solely for the purposes

of the Contract and shall not be within the ownership of or disposition of the Contractor.

4 Any interim certificate issued by the Engineer shall be without prejudice of the exercise of any power of the

Engineer contained in the Contract to reject material and/or equipment which is not in accordance with the

Contract and upon any such rejection the property in the rejected material and/or equipment shall

immediately revert to the Contractor.

5 That we shall be liable for loss of or damage to any of the Contractor’s equipment which may happen

otherwise than through the default of the Employer.

Address where the material/equipment will be held: …………………………………………………………………………………………………………………………. …………………………………………………………………………………………………………………………. Signed in the presence of the subscribing witnesses: At …………………………. for and on behalf of the Contractor on this …….… day of …….……………….. Signature . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . Duly authorized to sign on behalf of . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . Address . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . As witnesses: 1 . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2 . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . .