STATE OF INDIANA INDIANA UTILITY REGULATORY COMMISSION VERIFIED PETITION OF INDIANA GAS COMPANY, INC. D/B/A CENTERPOINT ENERGY INDIANA NORTH FOR (1) APPROVAL OF AN ADJUSTMENT TO ITS GAS SERVICE RATES THROUGH ITS CSIA RATE SCHEDULE, (2) AUTHORITY TO DEFER 20% OF THE APPROVED EXPENDITURES FOR RECOVERY IN PETITIONER’S NEXT GENERAL RATE CASE, AND (3) APPROVAL OF PETITIONER'S UPDATED 7-YEAR PLAN, INCLUDING ACTUAL CAPITAL EXPENDITURES AND CSIA COSTS, ALL PURSUANT TO IND. CODE CHPT. 8-1-8.4 AND 8-1-39 AND THE COMMISSION'S ORDER IN CAUSE NO. 44429 ) ) ) ) ) ) ) ) ) ) ) ) ) CAUSE NO. 44430 TDSIC-14 INDIANA GAS COMPANY, INC. D/B/A CENTERPOINT ENERGY INDIANA NORTH SUBMISSION OF CORRECTED DOCUMENTS Petitioner Indiana Gas Company, Inc. d/b/a CenterPoint Energy Indiana North (“Petitioner” or “CEI North”), by counsel, respectfully submits to the Indiana Utility Regulatory Commission the following corrections to reflect removal of costs within TMOD Project 3215 in Revised Attachment SAH-4 and Revised Attachment SAH-4 (Confidential) and TDSIC Project 222 in Revised Attachment SAH-8 and Revised Attachment SAH-8 (Confidential) to its Direct Testimony in this Cause: • Petitioner’s Exhibit No. 1, Revised Attachments SAH-2, SAH-3, SAH-4 (Confidential), SAH-8 (Confidential), SAH-9, SAH-12 and SAH-13 • Petitioner’s Exhibit No. 3 (Mathews), Revised Pages 5, 6, 7, 13 and 14 • Petitioner’s Exhibit No. 3, Revised Attachments JRM-1, JRM-2, JRM-3 • Petitioner’s Exhibit No. 4, Revised Attachments KJT-1 and KJT-2 Redline copies of the corrected testimony (Exhibit A) and clean copies of corrected testimony and attachments (Exhibit B) are attached hereto. Petitioner will include clean copies in the court reporter copies into evidence at the hearing.
60
Embed
May 21, 2021 INDIANA UTILITY REGULATORY COMMISSION
This document is posted to help you gain knowledge. Please leave a comment to let me know what you think about it! Share it to your friends and learn new things together.
Transcript
STATE OF INDIANA INDIANA UTILITY REGULATORY COMMISSION
VERIFIED PETITION OF INDIANA GAS COMPANY, INC. D/B/A CENTERPOINT ENERGY INDIANA NORTH FOR (1) APPROVAL OF AN ADJUSTMENT TO ITS GAS SERVICE RATES THROUGH ITS CSIA RATE SCHEDULE, (2) AUTHORITY TO DEFER 20% OF THE APPROVED EXPENDITURES FOR RECOVERY IN PETITIONER’S NEXT GENERAL RATE CASE, AND (3) APPROVAL OF PETITIONER'S UPDATED 7-YEAR PLAN, INCLUDING ACTUAL CAPITAL EXPENDITURES AND CSIA COSTS, ALL PURSUANT TO IND. CODE CHPT. 8-1-8.4 AND 8-1-39 AND THE COMMISSION'S ORDER IN CAUSE NO. 44429
) ) ) ) ) ) ) ) ) ) ) ) )
CAUSE NO. 44430 TDSIC-14
INDIANA GAS COMPANY, INC. D/B/A CENTERPOINT ENERGY INDIANA NORTH SUBMISSION OF CORRECTED DOCUMENTS
Petitioner Indiana Gas Company, Inc. d/b/a CenterPoint Energy Indiana North (“Petitioner”
or “CEI North”), by counsel, respectfully submits to the Indiana Utility Regulatory Commission the
following corrections to reflect removal of costs within TMOD Project 3215 in Revised Attachment
SAH-4 and Revised Attachment SAH-4 (Confidential) and TDSIC Project 222 in Revised
Attachment SAH-8 and Revised Attachment SAH-8 (Confidential) to its Direct Testimony in this
This schedule is the calculation of the proposed revenue requirement CEI North seeks to 26
recover in this TDSIC-14 filing. The revenue requirement calculation is divided on this 27
schedule between the “Return on New Capital Investment”, which calculates the pre-tax return 28
on total net new investment (lines 1 through 8), the “Incremental Expenses”, which calculates 29
the recoverable expenses, both projected and amortized from previously deferred balances 30
(lines 9 through 14), and the netting of margins from former Snow and Ogden customers (line 31
15), as discussed later in my testimony. All items on this schedule are supported by the 32
following schedules and are recoverable as eligible costs under the Order. 33
Deleted: 78,741,91434
A.
A.
A.
Petitioner’s Exhibit No. 3 Cause No. 44430-TDSIC-14
CEI North REVISED Page 13 of 15
North will defer $7,299,719 for the Compliance Component and $1,917,188 for the TDSIC 1
Component during the semi-annual period (July through December 2021), as reflected on line 2
14 of Schedule 7. 3
4
Q. What is the balance of the 20% Deferred Revenue Requirement recorded through 5
December 31, 2020? 6
As noted on Schedule 7, lines 1 through 12, the total deferred revenue requirement through 7
December 31, 2020 is $47,828,361 for the Compliance Component and $15,452,556 for the 8
TDSIC Component, with an additional $7,714,986 (line 13) for the Compliance Component 9
and $2,207,396 (line 13) for the TDSIC Component to be recorded for January through June 10
2021 (TDSIC-13 Rate Effective Period), and an additional $7,299,719 (line 14) for the 11
Compliance Component and $1,917,188 (line 14) for the TDSIC Component to be recorded 12
for July through December 2021 (TDSIC-14 Rate Effective Period). 13
14
Q. Please describe Schedule 8 (Amortization of Deferred Incremental O&M Expense) of 15
Petitioner’s Exhibit No. 3, Attachment JRM-2. 16
This schedule calculates the amortization of deferred O&M expense included for recovery in 17
the Compliance Component revenue requirement. As approved in the Order, the deferred 18
O&M expense balance represents the cumulative expenses incurred through December 31, 19
2020 but not yet recovered or approved to be recovered in the CSIA. The deferred balance, 20
less amounts directly amortized for recovery in prior CSIA filings, will be amortized and 21
recovered over twelve (12) months. 22
23
Line 1 reflects the balance of deferred incremental O&M expenses from prior TDSIC filings2. 24
Line 2 supports the deferred incremental O&M expenses for the current TDSIC period of July 25
through December 2020 (from Petitioner’s Exhibit No. 2, Attachment SJV-2). Line 3 reflects 26
the calculated ending deferred balance as of December 31, 2020, before the inclusion of the 27
expected recoveries from TDSIC-13. Line 4 reflects the expected recoveries minus the 28
variance from TDSIC-13 for the period January through June 2021. This schedule, specifically 29
2 As approved in Cause No. 44429, any remaining over or under recovery variance from the Pipeline Safety Adjustment (once discontinued) would be recoverable in the Compliance Component of the CSIA (Cause No. 44430, Petitioner’s Exhibit No. SEA-1). The total deferred balance includes this adjustment, effective with TDSIC-7.
Deleted: 7,300,10130 Deleted: 1,918,19631
Deleted: 7,300,10132
Deleted: 1,918,19633
A.
-------------:====================='.
A.
Petitioner’s Exhibit No. 3 Cause No. 44430-TDSIC-14
CEI North REVISED Page 14 of 15
the total on line 5, supports line 11 of the revenue requirement calculation on Schedule 1. 1
2
Q. Please describe Schedule 8 (2% TDSIC Annual Retail Revenue Cap Test) of Petitioner’s 3
Exhibit No. 3, Attachment JRM-3. 4
Schedule 8 compares the increase in the TDSIC Component revenue requirement to the prior 5
12-month retail revenues for CEI North, to ensure that the amounts included for recovery in 6
the CSIA adhere to the statutory requirements. As defined in the TDSIC Statute, “the 7
commission may not approve a TDSIC that would result in an average aggregate increase in 8
a public utility’s total retail revenues of more than two percent (2%) in a twelve (12) month 9
period.” (Ind. Code § 8-1-39-14(a)). The increase in the TDSIC Component revenue 10
requirement is calculated by taking the recoverable TDSIC Component revenue requirement 11
(line 17 of Attachment JRM-3, Schedule 1) in the current CSIA, less the prior recoverable 12
portion of the TDSIC Component revenue requirement in the prior CSIA. This amount is 13
compared to 2% of the retail revenues from the prior 12-month period. "Retail revenues" used 14
in this calculation are calculated consistent with CEI North’s Operating Revenues, inclusive of 15
CSIA revenues, from the GCA NOI earnings test. The TDSIC Component revenue 16
requirement reflected on Schedule 8 does not exceed 2% of retail revenues during the 17
previous 12 months. 18
19
Q. Please describe Schedule 9 (NOI Adjusted for GCA Earnings Test) of Petitioner’s 20
Exhibit No. 3, Attachments JRM-2 and JRM-3. 21
In accordance with the Order, CEI North will adjust its statutory NOI earnings test by 22
increasing its authorized NOI by incremental earnings from approved CSIA filings. This 23
calculates the after-tax return on investment that will be added to the authorized NOI by 24
multiplying the net new capital investment from line 6 of Attachments JRM-2 and JRM-3, 25
Schedule 1 by the after-tax WACC on line 5 of Schedule 4, Page 1. Effective with the 26
approved rates in this Cause, CEI North will adjust its authorized NOI by $33,406,805 for the 27
Compliance Component and $10,428,373 for the TDSIC Component, as denoted on line 3 of 28
Schedule 9 of Petitioner’s Exhibit No. 3, Attachments JRM-2 and JRM-3, respectively. 29
30
Q. CEI North filed a petition on November 7, 2014 in Cause No. 44563 requesting a CPCN 31
to provide service to the area previously served by Snow & Ogden, and recovery of the 32
project costs within the CSIA mechanism. Please summarize the Commission’s order. 33
Deleted: JSC34
Deleted: 33,409,05935
Deleted: 10,433,56936
A.
A.
..__-------- ~--------~
--------------:==================='.
EXHIBIT B
Petitioner’s Exhibit No. 3 Cause No. 44430-TDSIC-14
CEI North REVISED Page 5 of 15
1
2
III. REVENUE REQUIREMENT 3
4
Q. Please generally explain how the Compliance and TDSIC Component revenue 5
requirements were calculated in this filing. 6
CEI North calculated a revenue requirement for the Compliance and TDSIC Components 7
separately for costs incurred through December 31, 2020. Petitioner’s Exhibit No. 3, 8
Attachment JRM-2 provides schedules 1-10 for the Compliance Component and Petitioner’s 9
Exhibit No. 3, Attachment JRM-3 provides schedules 1-9 for the TDSIC Component, with both 10
summarized on Petitioner’s Exhibit No. 3, Attachment JRM-1 as the total CSIA revenue 11
requirement. The revenue requirement for both the Compliance and TDSIC Components, 12
shown on Schedule 1, includes the return on new capital investments, incremental property 13
tax and depreciation expenses, as well as recovery of the regulatory assets recorded through 14
the deferral of O&M expense, the interim deferral of depreciation expense, and PISCC. CEI 15
North then multiplied the total annual revenue requirement by 80% to achieve the recoverable 16
portion of the revenue requirement on Schedule 4, line 17, for TDSIC-14. The total 17
recoverable amounts are utilized to derive semi-annual CSIA rates based on annualized 18
billing determinants, as described by Witness Tieken. 19
This schedule is the calculation of the proposed revenue requirement CEI North seeks to 26
recover in this TDSIC-14 filing. The revenue requirement calculation is divided on this 27
schedule between the “Return on New Capital Investment”, which calculates the pre-tax return 28
on total net new investment (lines 1 through 8), the “Incremental Expenses”, which calculates 29
the recoverable expenses, both projected and amortized from previously deferred balances 30
(lines 9 through 14), and the netting of margins from former Snow and Ogden customers (line 31
15), as discussed later in my testimony. All items on this schedule are supported by the 32
following schedules and are recoverable as eligible costs under the Order. 33
Petitioner’s Exhibit No. 3 Cause No. 44430-TDSIC-14
CEI North REVISED Page 13 of 15
North will defer $7,299,719 for the Compliance Component and $1,917,188 for the TDSIC 1
Component during the semi-annual period (July through December 2021), as reflected on line 2
14 of Schedule 7. 3
4
Q. What is the balance of the 20% Deferred Revenue Requirement recorded through 5
December 31, 2020? 6
As noted on Schedule 7, lines 1 through 12, the total deferred revenue requirement through 7
December 31, 2020 is $47,828,361 for the Compliance Component and $15,452,556 for the 8
TDSIC Component, with an additional $7,714,986 (line 13) for the Compliance Component 9
and $2,207,396 (line 13) for the TDSIC Component to be recorded for January through June 10
2021 (TDSIC-13 Rate Effective Period), and an additional $7,299,719 (line 14) for the 11
Compliance Component and $1,917,188 (line 14) for the TDSIC Component to be recorded 12
for July through December 2021 (TDSIC-14 Rate Effective Period). 13
14
Q. Please describe Schedule 8 (Amortization of Deferred Incremental O&M Expense) of 15
Petitioner’s Exhibit No. 3, Attachment JRM-2. 16
This schedule calculates the amortization of deferred O&M expense included for recovery in 17
the Compliance Component revenue requirement. As approved in the Order, the deferred 18
O&M expense balance represents the cumulative expenses incurred through December 31, 19
2020 but not yet recovered or approved to be recovered in the CSIA. The deferred balance, 20
less amounts directly amortized for recovery in prior CSIA filings, will be amortized and 21
recovered over twelve (12) months. 22
23
Line 1 reflects the balance of deferred incremental O&M expenses from prior TDSIC filings2. 24
Line 2 supports the deferred incremental O&M expenses for the current TDSIC period of July 25
through December 2020 (from Petitioner’s Exhibit No. 2, Attachment SJV-2). Line 3 reflects 26
the calculated ending deferred balance as of December 31, 2020, before the inclusion of the 27
expected recoveries from TDSIC-13. Line 4 reflects the expected recoveries minus the 28
variance from TDSIC-13 for the period January through June 2021. This schedule, specifically 29
2 As approved in Cause No. 44429, any remaining over or under recovery variance from the Pipeline Safety Adjustment (once discontinued) would be recoverable in the Compliance Component of the CSIA (Cause No. 44430, Petitioner’s Exhibit No. SEA-1). The total deferred balance includes this adjustment, effective with TDSIC-7.
Petitioner’s Exhibit No. 3 Cause No. 44430-TDSIC-14
CEI North REVISED Page 14 of 15
the total on line 5, supports line 11 of the revenue requirement calculation on Schedule 1. 1
2
Q. Please describe Schedule 8 (2% TDSIC Annual Retail Revenue Cap Test) of Petitioner’s 3
Exhibit No. 3, Attachment JRM-3. 4
Schedule 8 compares the increase in the TDSIC Component revenue requirement to the prior 5
12-month retail revenues for CEI North, to ensure that the amounts included for recovery in 6
the CSIA adhere to the statutory requirements. As defined in the TDSIC Statute, “the 7
commission may not approve a TDSIC that would result in an average aggregate increase in 8
a public utility’s total retail revenues of more than two percent (2%) in a twelve (12) month 9
period.” (Ind. Code § 8-1-39-14(a)). The increase in the TDSIC Component revenue 10
requirement is calculated by taking the recoverable TDSIC Component revenue requirement 11
(line 17 of Attachment JRM-3, Schedule 1) in the current CSIA, less the prior recoverable 12
portion of the TDSIC Component revenue requirement in the prior CSIA. This amount is 13
compared to 2% of the retail revenues from the prior 12-month period. "Retail revenues" used 14
in this calculation are calculated consistent with CEI North’s Operating Revenues, inclusive of 15
CSIA revenues, from the GCA NOI earnings test. The TDSIC Component revenue 16
requirement reflected on Schedule 8 does not exceed 2% of retail revenues during the 17
previous 12 months. 18
19
Q. Please describe Schedule 9 (NOI Adjusted for GCA Earnings Test) of Petitioner’s 20
Exhibit No. 3, Attachments JRM-2 and JRM-3. 21
In accordance with the Order, CEI North will adjust its statutory NOI earnings test by 22
increasing its authorized NOI by incremental earnings from approved CSIA filings. This 23
calculates the after-tax return on investment that will be added to the authorized NOI by 24
multiplying the net new capital investment from line 6 of Attachments JRM-2 and JRM-3, 25
Schedule 1 by the after-tax WACC on line 5 of Schedule 4, Page 1. Effective with the 26
approved rates in this Cause, CEI North will adjust its authorized NOI by $33,406,805 for the 27
Compliance Component and $10,428,373 for the TDSIC Component, as denoted on line 3 of 28
Schedule 9 of Petitioner’s Exhibit No. 3, Attachments JRM-2 and JRM-3, respectively. 29
30
Q. CEI North filed a petition on November 7, 2014 in Cause No. 44563 requesting a CPCN 31
to provide service to the area previously served by Snow & Ogden, and recovery of the 32
project costs within the CSIA mechanism. Please summarize the Commission’s order. 33
Petitioner's Exhibit No. 1
Revised Attachment SAH-2
Cause No. 44430-TDSIC-14
CEI North
Page 1 of 1
January 1, 2020-
June 30, 2020
July 1, 2020 -
December 31, 2020 2020 Annual
Compliance Investment Bare Steel and Cast Iron Actual Spend $21,231,359 $21,795,025 $43,026,384
Transmission Modernization Actual Spend $8,191,403 $13,006,592 $21,197,995
Distribution Modernization Actual Spend $4,385,370 $7,819,691 $12,205,061
Storage Modernization Actual Spend $559,577 $665,457 $1,225,035
Actual spend - Total $34,367,709 $43,286,766 $77,654,475
Bare Steel and Cast Iron Planned Spend $43,477,265
SE Columbus Columbus Grandview 6" Valve Replmt 2018 2018 Y
A number of utilities were not identified until construction began and required an additional week of work by the contractor, inspector, etc. to work around. The utilities identified when construction started, were private electric and fiber facilities, which are not located via one call/911. These utilities were also not identified on available historical records. CEI North became aware of and located the private facilities while on-site for the start of construction and spot holing for other activities.
3890 17202802054024 Priority Pipe NW Lafayette Lafayette8" NW3109 Linden Line Segment 1, 2, and 4 - Replace 12.15 miles of previously reconditioned 1942 and 1947 pipe and replace rectifier
2018 2018 Y
Crawfordsville to Lafayette 12” main: This project’s actual cost exceeded the previous estimate primarily due to encountering rock that was not expected. Soil borings were performed along the route, but the rock was encountered at isolated locations where soil borings were not performed. Field investigation determined the need to replace some of the regulator station inlet piping at multiple locations due to unknown material specification and rebuild two stations where the new line supplies the de-rated existing main. Some costs were incurred due to delays caused by vendor supply issues (e.g. stopple fitting availability). Minimal trailing charges in TDSIC-14 period.
4175 18202802054213 Priority Pipe NW Lafayette RomneyDistribution support project for Linden replacement - Derate parallel Linden 8" transmission pipeline to 60 psig
2018 2018 Y
The project was to support the derate of one 8” HP transmission gas line from high pressure to medium pressure and replacement of a second 8” HP transmission gas line with 12” HP transmission gas line. Additional services were found to be connected to the main to be retired during the field investigation and required extending the medium pressure plastic gas main extension to support the transmission projects. An additional 1700’ of 2” and 4” medium pressure plastic main and 41 services were added to the original scope of work due to the removal of farms taps tied onto the two - 8” HP transmission gas lines.
3078 17202802054022 ILI Retrofits SE Bloomington Bloomington10"/16" Dolan to Needmore - ILI retrofit 24.97 miles of pipeline, pressure test 12.36 miles of pipeline, and two proving tool runs
2018 2018 Y
A new pipeline heater and additional electrical work was required at Needmore Station. The 10" line leaked during hydrotest and a section was required to be replaced. The 10" line and 16" were very dirty and required additional cleaning beyond normal. It was necessary to split the pressure test into 2 segments on the 10" pipeline due to weather concerns which increased construction and inspection labor.
3098 17202802054019 Priority Pipe SE Clarksville Sellersburg12" Holman to Airport Valve Cluster (NS5015) - Replace 1.00 miles of 8" pipeline with 12" pipe due to needed pressure test
2018 2018 YProject was completed on an accelerated schedule to ensure line was back in service for heating season resulting in additional labor charges. Also, portions of project were completed on Time & Material basis (hourly rates) due to work being performed in a heavy industrial area with significant heavy traffic.
3286 17202802054025 ILI Retrofits NW Danville Crawfordsville 16" Mt Tabor to Risner - ILI retrofit 3.76 miles of pipeline, heater replacement, and proving tool run 2018 2018 Y
The existing heater failed over the winter prior to construction start and was not included in the original scope of work. During construction it was determined the filter would need to be replaced due to non-compliance with current codes. Two existing valves failed during startup and were required to be replaced.
4151 18202802054011 Casings SE Martinsville Martinsville Replace 10" pipeline with shorted casing under SR 39 2018 2018 Y
3083 18202802054021 Gas Quality / Conditioning SE Clarksville Crestwood Install filter separator and odorizer at Crestwood PP 2019 2019 Y
Engineering costs exceeded estimate due to complexity of project (more engineering hours were required). Costs for temporary odorizer exceeded the estimate due to extended duration of the project caused by the additional utility conflicts. Other utilities' below ground assets not reflected on station drawings were identified during construction increasing costs for locating and caused some changes to design. Station site is shared by multiple pipelines. As communicated in TDSIC-11, this project was projected to be 30% over estimate for the reasons described.
4088 17202802054016 Miscellaneous SE Clarksville Crestwood Crestwood Station Expansion 2019 2019 Y
3112 18202802054023 Pressure Test NE Anderson Anderson 16" Anderson #2 to Layton Road - Pressure test 0.58 miles 2019 2019 Y Overheads were less than estimated and project contingency amount was not required.
3215 18202802054020 ILI Retrofits SE Clarksville Clarksville16" Applegate Ln. TBS to Holman LP - ILI retrofit 2.69 miles of pipeline, replace rectifier, and proving tool run
2019 2019 Y
3419 18202802054024 Pressure Test NE Muncie New Castle8" Muncie to New Castle - Install 1,600' of 10" pipeline under I-70 and pressure test 0.50 miles of pipeline
2019 2019 Y Material and land costs were much less than estimated. Contingency costs included in the estimate for unknown factors were not necessary.
3033 18202802054030 Gas Quality / Conditioning NW Lafayette Wolcott Install gas chromatograph at Wolcott Storage Field 2019 2019 N
The electrical installation costs for this project were underestimated. The high density of existing underground facilities at the jobsite - not well-documented in historical records and discovered as construction started - which required the use of hydrovac excavation services for a portion of this project which was not anticipated in the estimate. Rain delays also extended the construction duration of the project, increasing T&M costs for portions of the work and inspection costs. Minimal trailing charges in TDSIC-14 period for final equipment connections at the chromatograph building and start up.
3912 18202802054025 Obsolete Equipment NE Muncie New Castle 10" New Castle River Rd Station - Rebuild due to two unsupported regulators 2019 2019 Y
3916 18202802054028 ILI Retrofits SE Clarksville Prospect NS5011 12" Wallace Farms to Longview Beach - Install filter separator connection at launcher 2019 2019 Y
4075 18202802054018 Pressure Test SE Bloomington BloomingtonNS5055 8" Needmore PP to Bloomington South TBS - Pressure test 0.5 miles of pipeline and mitigate (7) pipeline exposures
2019 2019 Y
The length of the HDD and associated cost increased due to additional required depth determined necessary in the field during construction. Additional stopple (gas stopping procedure) field services were required because the sequencing of the work was changed because of delays in acquiring easement. Easement acquisition also increased in costs. Additional costs were also incurred to install an additional stopple fitting to enable removal of a segment for testing - need identified during construction activities. Credit in TDSIC-14 period associated with reimbursement from subcontractor damage to the main during excavation.
CEI NorthCompliance Plan - Transmission Modernization Projects
Petitioner's Exhibit No. 1
Revised Attachment SAH-4
Cause No. 44430-TDSIC-14
CEI North
Page 2 of 3($13,006,592) Diff
$13,006,592 Control - Plant file
$0 Below total
Database
Project
Number
Oracle Project Number Project Category Division OC City Project Short Description
CEI NorthCompliance Plan - Transmission Modernization Projects
3508 19202802054017 ILI Retrofits NW Lafayette Lafayette 12" Taylor Pig Trap to Risner Stn. - ILI retrofit 25.83 miles of pipeline 2020 2020 Y
3923 19202802054013 ILI Retrofits NE Muncie Muncie
12" King Station (RS 274) to RS 220 (CR 400 Station) - ILI retrofit 1.69 miles of pipeline and replace 0.40 miles of 8" pipe with 12" pipe between RS 220 and ANR Muncie
2020 2020 Y
4294 18202802054029 ILI Retrofits NW Lafayette Lafayette 16" Taylor to Wolcott - ILI retrofit 28.32 miles of pipeline 2019 2019 Y
3941 19202802054012 Gas Quality / Conditioning SE Franklin Bargersville Install gas chromatograph and filter separator at Bargersville PP 2020 2020 Y Project is complete and trending under estimate, but not all charges have been incurred.
4298 19202802054016 Gas Quality / Conditioning NW Danville Brownsburg Install gas chromatograph at HCJ PP 2020 2020 N
4321 19202802054212 ILI Retrofits SE Clarksville ClarksvilleDistribution support project for Holman to Applegate retrofit - Install 1,242' of 4" PE main to create second feed
2019 2019 Y
3190 19202802054011 ILI Retrofits SE Martinsville Martinsville16" Martinsville to Hindustan - ILI retrofit, replace, and pressure test portions of 9.02 miles of pipeline and install launchers and receivers
2020 2020 Y
4860 19202802054022 Casings NE Muncie Muncie Retire 16" casing on 12" King Station to RS 220 pipeline at CR 400 E 2019 2019 Y
3471 18202802054019 Gas Quality / Conditioning SE Columbus St. Paul Install gas chromatograph at REX PP N/A N/A N
3246 18202802054017 ILI Retrofits NW Danville Lebanon
12" HCJ to Lebanon LP - Install launcher/receiver barrels at two regulator stations and install one distribution support project in preparation for ILI retrofit 11.21 miles of pipeline and proving tool run in a later year
2022 2022 N Actual charges include engineering costs only.
3164 18202802054014 Priority Pipe NW Greencastle GreencastleAirport to US 40 - Replace 3.65 miles of 8" pipeline with 12" pipe due to needed pressure test
N/A N/AProject reprioritized beyond the current Compliance Plan ending in 2020 due to the pipeline not having HCAs
N
3424 18202802054015 Priority Pipe NW Terre Haute Terre Haute 6" Margaret #2 to Texas Gas PP - Replace 200' of pipeline due to unknown grade N/A N/A
Project reprioritized beyond the current Compliance Plan ending in 2020 due to the pipeline not having HCAs
N
3970 18202802054026 Gas Quality / Conditioning SE Franklin Shelbyville Install gas chromatograph at Shelbyville ANR PP N/A N/AProject reprioritized beyond the current Compliance Plan ending in 2020 due to the pipeline not having HCAs
N
3472 15202802054021 Priority Pipe NW Lafayette Wolcott Replace NW3811 N/A N/AProject reprioritized beyond the current Compliance Plan ending in 2020 due to the pipeline not having HCAs
Y
4962 19202802054023 Obsolete Equipment SE Columbus ColumbusReplace existing heater with new 4.0 MM BTU Line Heater at the Columbus North PP Station at 5601 N 200 W, Columbus IN.
2020 2020 Y
4963 20202802054011 Gas Quality / Conditioning NW Lafayette Wolcott Install filter/separators at Wolcott Station, McCormick Station and Purdue TBS 2020 2020 Y
4920 20202802054013 Priority Pipe NW Rockville Bloomingdale Veedersburg NW3120 HCA Replace 2020 2020 Y Construction bids were less than estimated. Engineering and materials were also under the estimate. 3233 20202802054014 Priority Pipe SE Clarksville Clarksville 8" Applegate-Clark HCA Replace 2020 2020 Y5040 19202802054020 Priority Pipe SE Bloomington Unionville 8" Exposure near Unionville 2020 2020 Y
517 19202802054221 ILI Retrofits NW Danville Crawfordsville
Distribution support project for 2021 TMOD 4876 - 12" Taylor to Risner retrofit - Install 575' of 4" PE main to supply services currently on transmission line
2020 2020 Y Construction is complete, but not all charges have been incurred
4886 19202802054222 Miscellaneous NW Lafayette RomneyDistribution support project for 2021 TMOD 12" Taylor to Risner retrofit - Install 695' of 2" PE to retire regulator station
2020 2020 Y Construction is complete, but not all charges have been incurred
4890 19202802054223 Priority Pipe SE Bloomington Martinsville
Distribution support project for TMOD 3190 16" Martinsville to Hindustan retrofit - Install 6,465' of 2" PE and retire 450' of 6" STL to supply services currently on transmission line
2020 2020 Y
3217 TBD ILI Retrofits SE Bloomington Bloomington12" Dolan to Hindustan - ILI retrofit 4.97 miles of pipeline, install launcher/receiver, and proving tool run
N/A N/A N
3031 19202802054213 Obsolete Equipment NE Muncie New CastleRetire Joyner Farms Regulator Station 1645 in pit and install approximately 250' of 2" PE main to feed services
2019 2019 N
4615 TBD ILI Retrofits SE Crawfordsville CrawfordsvilleDistribution support project for Taylor to Risner retrofit - Install 2,100' of 6" PE to replace two services to distribution system
N/A N/A N
4616 TBD ILI Retrofits NE Muncie MuncieDistribution support project for King to ANR Muncie retrofit - Install 250' of 2" PE to create second feed
N/A N/A N
4210 18202802054016/20202802054031 Miscellaneous SE Clarksville Prospect Install building over station equipment at Wallace
Farms - Wallace Farms Electric Service 2021 2021 N Building will not be constructed at the site due to permitting/zoning/adjacent property owner concerns, but electric service to controls and valves will be completed in 2021.
4173 17202802054236 ILI Retrofits NW Crawfordsville Crawfordsville Distribution support project for 16" Mt. Tabor to Risner retrofit - Install 3,000' of 4" PE 2018 2018 Y Project was completed on an accelerated schedule. Also, project was completed on T & M due to work being
performed in a heavy industrial area with significant heavy traffic.
4153 18202802054022 Obsolete Equipment NE Muncie Dunkirk Dunkirk TBS Heater Replacement 2018 2018 Y Project was estimated as a completely new heater installation including piping changes. The new heater was designed to bolt up to the existing piping reducing installation costs.
3167 17202802054020 Pressure Test SE Franklin Bargersville 16" Brooklyn TBS to Shelbyville - Pressure test 15.07 miles of pipeline 2018 2018 Y
Increased actual costs were primarily due to additional work required at Fulmer Station where historical drawings did not correctly indicate the existing piping configuration. CEI North installed a 6” filter at Grassy Creek Station in lieu of 4” that was designed and several additional cleaning/pig runs were required to remove liquids found in the pipeline.
Petitioner's Exhibit No. 1
Revised Attachment SAH-4
Cause No. 44430-TDSIC-14
CEI North
Page 3 of 3($13,006,592) Diff
$13,006,592 Control - Plant file
$0 Below total
Database
Project
Number
Oracle Project Number Project Category Division OC City Project Short Description
CEI NorthCompliance Plan - Transmission Modernization Projects
4174 17202802054235 Priority Pipe NW Lafayette Romney Distribution support project for Linden replacement - Install 3,500' of 2" PE 2018 2018 Y
Required relocating of a regulator station because of easement issues was not included in the original design. Installed three additional main extensions to pick up 12 services to be removed from HP main to the MP main. The additional main extensions required acquisition of easement. Existing rocky condition under the creek was not considered in the original design which required a rock cutting machine and equipment, also several of the tie-in locations were deep which required shoring. Additional traffic control was required due to congestion on US231.
3285 16202802054019 Pressure Test SE Bloomington Bloomington 8"/10" Dolan to IU Meter - Pressure test 1.80 miles of pipeline 2017 2017 Y
A casing was found shorted under a RR crossing and required insertion of a new segment of pipe and spacers. Additionally, undocumented fittings on the transmission line required replacement resulting in additional labor and material costs. A mechanical coupling at the Dolan station was found on pressure test, that trapped several pigs. Also had additional legal fees for ROW acquisition and restoration due to flooding.
3475 17202802054026 Pressure Test NW Wolcott Wolcott Wolcott Storage Field - Pressure test 3.50 miles of pipeline 2017 2017 Y
Project costs increased due to scope changes. Original scope was to replace leaking valve. However, once the project was started pipe seam anomalies were identified at four locations in the vicinity and cut outs/replacements were completed.
4205 17202802054029 Priority Pipe NE Lebanon Zionsville 16" HCJ to Zionsville - Replace leaking valve 2018 2018 Y
Project costs increased due to scope changes. Original scope was to replace leaking valve. However, once the project was started pipe seam anomalies were identified at four locations in the vicinity and cut outs/replacements were completed. Additional charges due to attorney fees related to land owner issue/easement issues.
4208 17202802054028 Priority Pipe NW Danville Brownsburg 12" HCJ to Fox - Replace leaking insulator 2017 2017 Y
Petitioner's Exhibit No. 1
Revised Attachment SAH-8
Cause No. 44430-TDSIC-14
CEI North
Page 1 of 4($3,248,768.21) Diff Diff
$3,248,768 Control - Plant file
$0 Below total Below total
Maximo Work Order
NumberOracle Project Number Project Category Division OC City Project Short Description
Previous
Planned
Year
(10/1/20)
Current
Planned
Year
Previous
Estimate
(10/1/20)
Current
Estimate
Estimate
Variance
($)
Estimate
Variance
(%)
Timing Variance Commentary Estimate Variance CommentaryCurrent Period
Actual Spend (7/1/20
-12/31/2020)
Annual Actual Spend
(1/1/20 -12/31/2020)
Inception to Date Actual
Spend
(1/1/14 - 12/31/20)
Actual Spend
Variance
($)
Actual Spend
Variance
(%)
In-service?
(Y or N)
Actual Spend Variance Commentary
8664431 13592002061213 Public Improvement SE CLARKSVILLE NEW ALBANYIN-NEW ALBANY-2500 BLK CHARLESTOWN RD~RELOCATE
GAS MAIN2023 2023 N
10845148 17573302G61212 Public Improvement NE MUNCIE MUNCIE
IN-MUNCIE-WHEELING AVE - RELOCATE MAIN
2020 2020 Y
The project is complete and was projected to exceed the
estimate by 25% in TDSIC-13, but has since trended to
~10% over estimate. Originally designed to install the gas
main in the grass strip/under the sidewalk west of
Wheeling Ave based on the plans provided by the City’s
contracted engineering firm. The fiber- optic utility
relocated before the gas main and bored in the new line
very close to the proposed gas main location. After much
consideration we decided to install our main in the road
to avoid conflict with the fiber line. This resulted in
increased hard surface removal: asphalt cutting & spoil
removal. As well as hard surface restoration: flowable fill
& concrete cap.
15656560 18595502G61217 Public Improvement NW LAFAYETTE FRANKFORTIN-FRANKFORT-WASHINGTON AVE ~~RELOCATE MAINS DUE
TO ROAD RECONSTRUCTION PROJECT - PHASE 22020 2020 N
15634137 18592002G61213 Public Improvement SE CLARKSVILLE NEW ALBANYIN-NEW ALBANY- MT TABOR ROAD PH 2 - RELOCATE MAINS
DUE TO ROAD IMPROVEMENT PROJECT 2024 2024 N
15438738 17583502G51011 System Improvement SE FRANKLIN GREENWOOD IN-GREENWOOD-SYSTEM IMPROVEMENT ON MULLINIX RD
AND UPRATE OUT OF GRASSY CREEK STATION
2018 2018 YEasements costs were less than estimated - could not
acquire some easements and installed main in public
ROW.
15589827 18595302G51214 System Improvement NW DANVILLE PLAINFIELD
IN-PLAINFIELD-STAFFORD RD AREA 3 UPRATE GAS MAIN
2019 2019 Y
Original estimate assumed obtaining easement for
main installation. Planned easements were not
acquired because of existing landlock forced us to
change the scope of the project and installed the main
in public right of way. Additional 100' of 6" pipe
installed because of the route change.
15589890 18595302G51215 System Improvement NW DANVILLE PLAINFIELDIN-PLAINFIELD-STANLEY RD AREA 2 ELEVATE RETEST GAS
MAIN
2019 2019 Y
Unforeseen utility conflicts caused extra depth main
installation by installing shoring, additional traffic
control needed. Additional spot holes by vac truck
required to identify/locate other utilities.
13807515 17595502G51212 System Improvement NW LAFAYETTEWEST
LAFAYETTEIN-WEST LAFAYETTE - KLONDIKE AREA 1~ELEVATE/RETEST
GAS MAIN
2020 2021
Waiting on IURC decision on design and
uprate procedure in regards to
undocumented test records on steel
main and services. Project completion
anticipated in 2021.
N
15497686 18595502G51210 System Improvement NW LAFAYETTEWEST
LAFAYETTE
IN-WEST LAFAYETTE - KLONDIKE AREA 2~ELEVATE/RETEST
GAS MAIN
2020 2021
Waiting on IURC decision on design and
uprate procedure in regards to
undocumented test records on steel
main and services. Project completion
anticipated in 2021.
Y
Project duration has been extended due to
complexities of uprate plan/process including
collaboration with the IURC Pipeline Safety Division.
Due to the delays it was necessary to construct a
temporary reg station and 2500' of 4" PE main to
connect two an adjacent system last winter. Field
investigation identified an additional 68 services
beyond the quantity estimated that were retired,
retested, or replaced. Charges in TDSIC-14 period
are for the service replacements. Still waiting for IURC
and PHMSA on uprate guidance.
12626778 17202802G53011 System Improvement SE CLARKSVILLEJEFFERSONVILL
E IN-JEFFERSONVILLE-REBUILD RS #14-34-GTE2019 2019 Y
13758448 18202802G53013 System Improvement NW LAFAYETTE FRANKFORT IN-FRANKFORT-REBUILD STATION 2 2019 2019 Y
15525323 18595302G51212 System Improvement NW DANVILLE PLAINFIELD
IN-PLAINFIELD AREA 1 UPRATE GAS MAIN
2020 2022
Still waiting for IURC and PHMSA on
uprate guidance, possible reschedule the
project to 2022.
Y
The initial charges are related to research, engineering
design and uprate procedure. Also, sewer locating has
been completed along with 59' of 2" PE main installed
with 2 services, and additional scattered service
replacements necessary prior to performing the future
uprate. The original plan to increase the system
operating pressure of the system to improve reliability
has been delayed as the Company and IURC work
through specific requirements for the existing main and
service line testing procedures/requirements. Still
waiting for IURC and PHMSA on uprate guidance,
possible reschedule the project to 2022.
15975625 19595302051011 System Improvement NW DANVILLEZIONSVILLE
WHITESTOWN
IN-ZIONSVILLE-E 300 S - INSTALL PIPE TO CONNECT 421 TO
WHITESTOWN AND ANSON AREA NEAR AMAZON TO PROVIDE
CAPACITY AND DELIVERABILITY TO AREA NORTH AND EAST
OF ZIONSVILLE
2019 2019 Y
The project scope was reduced due to ~800' of main
being installed under rural extension project
18595302044210 eliminating the need to install new
17 Recoverable Compliance and TDSIC Components within CSIA (80%) 62,353,517$ 16,376,445$ 78,729,962$ (A)
18 To Be Deferred (20%) 15,588,379$ 4,094,111$ 19,682,490$
Notes:
(A)
including the full equity and debt return, and then eligible operating expenses [Line 17 less Line 8 - $23,714,361]. The collection priority will not impact the total amount
authorized by the Commission for immediate recovery in the CSIA [Line 17 - $78,729,962], nor the amount deferred and authorized for future recovery in a base rate
For accounting purposes only, the collection of 80% of the revenue requirement will cover in order of priority the full return on the investments [Line 8 - $55,015,601],
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
COMBINED COMPLIANCE AND TDSIC COMPONENT
ANNUAL REVENUE REQUIREMENT THROUGH DECEMBER 31, 2020
Petitioner's Exhibit No. 3
REVISED Attachment JRM-2
Cause No. 44430-TDSIC-14
CEI North
Schedule 1
Page 1 of 1
TotalLine Description Amount Reference
Return on New Capital Investment:
1 Gross New Capital Investment - As of End of Period 505,508,413$ Schedule 2, Line 18, Col. G2 Accumulated Depreciation - As of End of Period (32,130,516)$ Schedule 2, Line 42, Col. G3 Net New Capital Investment - As of End of Period 473,377,897$ Line 1 + Line 2
4 New Capital Investment CWIP - As of End of Period 8,314,340$ Schedule 2, Line 48, Col. G
5 PISCC Deferred Balance - As of End of Period 19,911,441$ Schedule 3, Line 28, Col. G
6 Total New Capital Investment - As of End of Period 501,603,678$ Line 3 + Line 4 + Line 5
7 Pre-Tax Rate of Return 8.37% Schedule 4, Page 1, Line 17
8 Annualized Return on New Capital Investment 41,984,228$ Line 6 x Line 7
Incremental Expenses:
9 Property Tax Expense - Annualized 3,659,615$ (Line 1 x 0.72%) + (Line 4 x 0.24%) (A)
10 Depreciation Expense - Annualized 17,157,848$ Schedule 5, Line 17
14 Total Incremental Expenses 35,966,366$ Sum Lines 9-13
Margin Netting:
15 Reduction of Margins from New Snow & Ogden Customers - As of End of Period (8,697)$ Schedule 10, Line 5, Col. H (C)
16 Annual Revenue Requirement - Compliance Component 77,941,896$ Line 8 + Line 14 + Line 15
17 Recoverable Compliance Component of CSIA (80%) 62,353,517$ Line 16 x 80% (B)
18 To Be Deferred (20%) 15,588,379$ Line 16 x 20% (B)
Notes:
(A)
(B) To Attachment JRM-1, Schedule 1, Line 1(C) Commission's Order in Cause No. 44563, page 11, Net margins should represent a deduction to the Compliance Component revenue requirement,
with 80% of the margins credited immediately to the CSIA and 20% of the margins credited against the deferral to be recovered in CEI North's next base rate case.
The annualized level of property taxes is calculated using an estimated CEI North rate of 2.40% multiplied by the tax basis of the: (1) plant, estimated to be 30% of the gross new capital investment amount, and (2) CWIP, estimated to be 10% of the new capital investment CWIP amount.
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
COMPLIANCE COMPONENT
ANNUAL REVENUE REQUIREMENT THROUGH DECEMBER 31, 2020
Petitioner's Exhibit No. 3
REVISED Attachment JRM-2
Cause No. 44430-TDSIC-14
CEI North
Schedule 2
Page 1 of 1
A B C D E F G
Balance at Balance atLine Gross New Capital Investment 6/30/2020 7/31/2020 8/31/2020 9/30/2020 10/31/2020 11/30/2020 12/31/2020
28 Total PISCC Deferred Balance Line 26 + Line 27 18,815,623$ 18,894,525$ 19,001,243$ 19,160,608$ 19,374,239$ 19,608,146$ 19,911,441$
To Schedule 1, Line 5
Annualized Amortization Expense
29 Transmission Line 4 x Line 21 x 12 185,528$ 30 Distribution Line 5 x Line 22 x 12 544,323$ 31 Distribution - IEDC Line 6 x Line 23 x 12 -$ 32 Underground Storage Line 7 x Line 24 x 12 5,238$ 33 General Line 8 x Line 25 x 12 633$ 34 Total Amortization Expense Sum Lines 29-33 735,722$
To Schedule 1, Line 13
(A) Based on Amortization Life of Plant as of December 31, 2013. Annual depreciation rate is 1 divided by Number of Years, as shown on Attachment JRM-2, Schedule 6.(B) Calculated as the PISCC rates (lines 2 & 3) multiplied by the monthly PISCC eligible balances. PISCC eligible balances are based on the gross plant placed in service not yet captured for recovery in the CSIA.(C) Amortization of approximately $52,390 per month beginning in July 2020 is based on annualized amortization expense of $628,678 from TDSIC-12, Attachment JCS-R2, Schedule 3, Line 34.
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
COMPLIANCE COMPONENT
POST IN-SERVICE CARRYING COSTS (PISCC)
Petitioner's Exhibit No. 3
REVISED Attachment JRM-2
Cause No. 44430-TDSIC-14
CEI North
Schedule 4
Page 1 of 2
A B C D = B x C
Line After-Tax (A) Amount ($000's) Weighting Cost WACC
1 Debt 474,876$ 30.75% 4.84% 1.49%2 Equity 777,931$ 50.37% 10.20% 5.14%3 Cost Free Capital 265,532$ 17.19% 0.00% 0.00%4 Other 26,100$ 1.69% 1.50% 0.03%5 Total 1,544,440$ 6.66% (B)
To Schedule 9, Line 2
Pre-Tax Equity Component Calculation
6 After-Tax Cost of Equity per Line 2 5.14% Line 2, Col. D7 One 100.00%8 Less: Current State Tax Rate 5.075% (C)
9 Federal Taxable 94.93% Line 7 - Line 810 One Less Federal Income Tax 79.00% 1 - 21%11 Effective Gross-Up Factor 74.99% Line 9 x Line 1012 Pre-Tax Equity 6.85% Line 6 / Line 11
Forecast - Adjusted ROR (fixed ROE)
Pre-Tax
13 Debt 1.49% from Line 114 Equity 6.85% from Line 1215 Cost Free Capital 0.00% from Line 316 Other 0.03% from Line 417 Total Pre-Tax Rate of Return 8.37% Sum Lines 13-16
To Schedule 1, Line 7
(A) All data in Lines 1 through 5 are per Order in most recent TDSIC Case, Cause No. 44430-TDSIC-13
(B) Proof Equity Debt and Other Total18 Total New Capital Investment 501,603,678$ 501,603,678$ from Schedule 1, Line 619 Pre-Tax Return 6.85% 1.52% from Lines 13-1620 Return 34,380,812$ 7,624,376$ Line 18 x Line 1921 State Tax 1,744,826$ 5.075% x Line 2022 Federal Taxable Return 32,635,986$ 7,624,376$ Line 20 - Line 2123 Federal Tax 6,853,557$ Line 22 x 21%24 After Tax Return $ 25,782,429$ 7,624,376$ 33,406,805$ Line 20 - Lines 21 and 23
25 After-Tax Rate of Return 6.66% Line 24 / Line 18equals Line 5
(C) Represents a blended State Tax Rate: - January 1, 2021 - December 31, 2021 @ 5.075%- Based on 5.250% @ January 1, 2021 and 4.900% @ July 1, 2021
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
COMPLIANCE COMPONENT
PRE-TAX RATE OF RETURN AND AFTER TAX PISCC RATE AT JUNE 30, 2020
Petitioner's Exhibit No. 3
REVISED Attachment JRM-2
Cause No. 44430-TDSIC-14
CEI North
Schedule 4
Page 2 of 2
A B C D = B x C
Line After-Tax (A) Amount ($000's) Weighting Cost WACC
1 Debt 474,873$ 31.66% 4.87% 1.54%2 Equity 728,182$ 48.54% 10.20% 4.95%3 Cost Free Capital 270,233$ 18.01% 0.00% 0.00%4 Other 26,820$ 1.79% 1.50% 0.03%5 Total 1,500,108$ 6.52%
(A) All data in Lines 1 through 5 represent the actual balances as of December 31, 2019 (as presented in TDSIC-13 filing on JCS-3, Sch 4, Pg 2).
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
COMPLIANCE COMPONENT
AFTER TAX PISCC RATE AT DECEMBER 31, 2019
Petitioner's Exhibit No. 3
REVISED Attachment JRM-2
Cause No. 44430-TDSIC-14
CEI North
Schedule 5
Page 1 of 1
Balance atLine Description 12/31/2020 Reference
Depreciable In-Service Balance
1 Transmission 161,520,002$ Schedule 2, Line 13, Col. G2 Distribution 339,660,890$ Schedule 2, Line 14, Col. G3 Distribution - IEDC -$ Schedule 2, Line 15, Col. G4 Underground Storage 4,015,342$ Schedule 2, Line 16, Col. G5 General 312,178$ Schedule 2, Line 17, Col. G6 Total 505,508,413$ Sum Lines 1-5
Monthly Depreciation Rates
7 Transmission 0.24% (A)
8 Distribution 0.30% (A)
9 Distribution - IEDC 0.00% (B)
10 Underground Storage 0.30% (A)
11 General 0.35% (A)
Annualized Depreciation Expense
12 Transmission 4,600,616$ Line 1 x Line 7 x 1213 Distribution 12,399,542$ Line 2 x Line 8 x 1214 Distribution - IEDC -$ Line 3 x Line 9 x 1215 Underground Storage 144,704$ Line 4 x Line 10 x 1216 General 12,986$ Line 5 x Line 11 x 1217 Total Annualized Depreciation Expense 17,157,848$ Sum Lines 12-16
To Schedule 1, Line 10
(A)
(B) Reflects no plant additions through current period for class of plant.
Current average of authorized depreciation rates. Supporting work papers will show a detailed calculation of depreciation rates by class of plant.
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
COMPLIANCE COMPONENT
ANNUALIZED DEPRECIATION EXPENSE ON NEW CAPITAL INVESTMENT
10 Distribution - IEDC 3.57%11 Underground Storage 3.85%12 General 4.00%
Deferred Depreciation Amortization Expense
13 Transmission Line 1 x Line 8 81,871$ 14 Distribution Line 2 x Line 9 295,814$ 15 Distribution - IEDC Line 3 x Line 10 -$ 16 Underground Storage Line 4 x Line 11 2,790$ 17 General Line 5 x Line 12 421$ 18 Deferred Depreciation Amortization Expense Sum Lines 13-17 380,896$
To Schedule 1, Line 12
(A) Calculated by taking the gross new plant investment, less retirements, placed in-service but not yet included in CSIA recovery.(B) Amortization of approximately $27,173 per month beginning in July 2020 is based on annualized amortization expense of $326,070 from TDSIC-12, Attachment JCS-R2, Schedule 6, Line 18.(C) Based on Amortization Life of Plant as of December 31, 2013. Annual depreciation rate is 1 divided by Number of Years.
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
COMPLIANCE COMPONENT
AMORTIZATION OF DEFERRED DEPRECIATION
Petitioner's Exhibit No. 3
REVISED Attachment JRM-2
Cause No. 44430-TDSIC-14
CEI North
Schedule 7
Page 1 of 1
Line Description Amount Reference1 TDSIC-1, Compliance Component - through 06/30/2014 593,517$ TDSIC-1, JCS-2, Sch 7, Line 12 TDSIC-2, Compliance Component - through 12/31/2014 1,207,722$ TDSIC-2, JCS-2, Sch 7, Line 23 TDSIC-3, Compliance Component - through 06/30/2015 1,794,369$ TDSIC-3, JCS-2, Sch 7, Line 34 TDSIC-4, Compliance Component - through 12/31/2015 2,440,171$ TDSIC-4, JCS-2, Sch 7, Line 45 TDSIC-5, Compliance Component - through 06/30/2016 3,067,362$ TDSIC-5, JCS-2, Sch 7, Line 56 TDSIC-6, Compliance Component - through 12/31/2016 3,386,735$ TDSIC-6, JCS-2, Sch 7, Line 67 TDSIC-7, Compliance Component - through 06/30/2017 4,144,544$ TDSIC-7, JCS-2, Sch 7, Line 7 (B)
8 TDSIC-8, Compliance Component - through 12/31/2017 5,079,749$ TDSIC-8, JCS-2 (Revised), Sch 7, Line 89 TDSIC-9, Compliance Component - through 06/30/2018 5,891,954$ TDSIC-9, JCS-2, Sch 7, Line 9
10 TDSIC-10, Compliance Component - through 12/31/2018 6,236,696$ TDSIC-10 JCS-R2, Sch 7, Line 10 (C)
11 TDSIC-11, Compliance Component - through 06/30/2019 7,288,122$ TDSIC-11 JCS-2 (Revised), Sch 7, Line 1112 TDSIC-12, Compliance Component - through 12/31/2019 6,697,420$ TDSIC-12 JCS-R2, Sch 7, Line 1213 TDSIC-13, Compliance Component - through 06/30/2020 7,714,986$ TDSIC-13 JCS-2, Sch 7, Line 1314 TDSIC-14, Compliance Component - through 12/31/2020 7,299,719$ (A)
15 Total Deferred Revenue Requirement 62,843,066$
Notes:
(A)
(B) Adjusted to reflect the lower pre-tax rate of return using a 21% Federal Tax Rate - no other changes made to authorized amounts.(C) TDSIC-10 deferred revenues have been adjusted to reflect the corrected allocation previously described in Witness Swiz’s
TDSIC-11 testimony (Page 18).
Attachment KJT-1, Schedule 3, Line 20, Sum of Jul-Dec 2021 x Allocation of Compliance Component Revenue Requirement from Attachment JRM-1, Schedule 1
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
COMPLIANCE COMPONENT
DEFERRED REVENUE REQUIREMENT (20%)
Petitioner's Exhibit No. 3
REVISED Attachment JRM-2
Cause No. 44430-TDSIC-14
CEI North
Schedule 8
Page 1 of 1
Line Description Amount Reference
1 Balance - at end of previous reconciliation period [06/30/2020] 15,331,202$ TDSIC-13, JCS-2, Sch 8, Line 5 (A)
2 Deferral - current reconcilation period [Jul-Dec 2020] 6,806,403$ Petitioner's Exhibit No. 2, Attachment SJV-23 Balance - at end of current reconciliation period [12/31/2020] 22,137,605$ Sum Lines 1-34 Less: Expected Recoveries (8,105,320)$ (B)
5 Balance - to be recovered in current effective period 14,032,285$ Sum Lines 4-5To Schedule 1, Line 11
Notes:
(A) Includes remaining North PSA balance at 04/10/17 as shown in TDSIC-7(B) Expected recoveries attributable to O&M from TDSIC-13
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
COMPLIANCE COMPONENT
AMORTIZATION OF DEFERRED INCREMENTAL O&M EXPENSE
Petitioner's Exhibit No. 3
REVISED Attachment JRM-2
Cause No. 44430-TDSIC-14
CEI North
Schedule 9
Page 1 of 1
TotalLine Description Amount Reference
1 Total New Statutory Investment - As of End of Period 501,603,678$ From Schedule 1, Line 6
2 After-Tax Rate of Return 6.66% From Schedule 4, Page 1, Line 5
3 NOI Adjustment for GCA Earnings Test - TDSIC-14, Compliance Component 33,406,805$ Line 1 x Line 2
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
COMPLIANCE COMPONENT
NOI ADJUSTED FOR GCA EARNINGS TEST
Petitioner's Exhibit No. 3
REVISED Attachment JRM-2
Cause No. 44430-TDSIC-14
CEI North
Schedule 10
Page 1 of 1
A B C D E F G H
Balance at Total ThruLine Description 6/30/2020 7/31/2020 8/31/2020 9/30/2020 10/31/2020 11/30/2020 12/31/2020 12/31/2020
Net Margins from Snow & Ogden Customers
1 Snow & Ogden Average Customers (A) 30.000 30.000 30.000 30.000 30.000 30.0002 Rate 210 - Order Granted Margin Per Customer (B) 14.79$ 14.71$ 16.37$ 21.07$ 29.25$ 40.04$ 3 Customer Margin Adjustment 50,290$ 444$ 441$ 491$ 632$ 878$ 1,201$ 54,377$ 4 Less: Expected Recoveries (C) 45,680$ 5 Balance - at end of current reconciliation period [12/31/2020] 8,697$
To Schedule 1, Line 15
Notes:
(A)
(B)
(C) Expected recoveries through December 31, 2020
Revised base rates and charges were approved effective June 1, 2018 following a Thirty Day Filing pursuant to Cause No. 45032, identified by the Commission as #50171 (approved May 30, 2018).
As customers are added at various points during the calendar month, the applicable billing period for a customer is prorated by day during the first billing month, resulting in a 'partial customer'. That customer in subsequent periods is considered one full customer.
NET MARGINS GAINED FROM NEW CUSTOMERS (SNOW & OGDEN)
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
COMPLIANCE COMPONENT
Petitioner's Exhibit No. 3
REVISED Attachment JRM-3
Cause No. 44430-TDSIC-14
CEI North
Schedule 1
Page 1 of 1
TotalLine Description Amount Reference
Return on New Capital Investment:
1 Gross New Capital Investment - As of End of Period 168,395,764$ Schedule 2, Line 18, Col. G2 Accumulated Depreciation - As of End of Period (12,341,770)$ Schedule 2, Line 42, Col. G3 Net New Capital Investment - As of End of Period 156,053,994$ Line 1 + Line 2
4 New Capital Investment CWIP - As of End of Period 546,547$ Schedule 2, Line 48, Col. G
5 PISCC Deferred Balance - As of End of Period 7,110,176$ Schedule 3, Line 33, Col. G
6 Total New Capital Investment - As of End of Period 163,710,717$ Line 3 + Line 4 + Line 5
7 Pre-Tax Rate of Return 7.96% Schedule 4, Page 1, Line 17
8 Annualized Return on New Capital Investment 13,031,373$ Line 6 x Line 7
Incremental Expenses
9 Property Tax Expense - Annualized 1,213,761$ (Line 1 x 0.72%) + (Line 4 x 0.24%) (A)
10 Depreciation Expense - Annualized 5,793,393$ Schedule 5, Line 17
14 Total Incremental Expenses 7,439,183$ Sum Lines 9-13
Margin Netting:
15 Reduction of Margins from New Snow & Ogden Customers - As of End of Period -$ N/A for TDSIC Component
16 Annual Revenue Requirement - TDSIC Component 20,470,556$ Line 8 + Line 14
17 Recoverable TDSIC Component of CSIA (80%) 16,376,445$ Line 16 x 80% (B)
18 To Be Deferred (20%) 4,094,111$ Line 16 x 20% (B)
Notes:
(A)
(B) To Attachment JRM-1, Schedule 1, Line 2
The annualized level of property taxes is calculated using an estimated CEI North rate of 2.40% multiplied by the tax basis of the: (1) plant, estimated to be 30% of the gross new capital investment amount, and (2) CWIP, estimated to be 10% of the new capital investment CWIP amount.
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
TDSIC COMPONENT
ANNUAL REVENUE REQUIREMENT THROUGH DECEMBER 31, 2020
Petitioner's Exhibit No. 3
REVISED Attachment JRM-3
Cause No. 44430-TDSIC-14
CEI North
Schedule 2
Page 1 of 1
A B C D E F G
Balance at Balance atLine Gross New Capital Investment Balance 6/30/2020 7/31/2020 8/31/2020 9/30/2020 10/31/2020 11/30/2020 12/31/2020
21 Transmission Line 9 + Line 15 977,771$ 991,574$ 1,004,516$ 1,016,387$ 1,028,345$ 1,040,382$ 1,052,525$ 22 Distribution Line 10 + Line 16 6,654,282$ 6,668,994$ 6,686,792$ 6,707,729$ 6,733,836$ 6,764,953$ 6,800,818$ 23 Distribution - IEDC Line 11 + Line 17 93,217$ 93,217$ 93,217$ 93,217$ 93,217$ 93,217$ 94,757$ 24 Underground Storage Line 12 + Line 18 41,968$ 44,603$ 47,419$ 49,869$ 52,323$ 54,780$ 59,416$ 25 General Line 13 + Line 19 31,609$ 31,609$ 31,609$ 31,609$ 31,609$ 31,609$ 31,609$ 26 PISCC Deferred Balance Sum Lines 21-25 7,798,848$ 7,829,997$ 7,863,553$ 7,898,812$ 7,939,331$ 7,984,942$ 8,039,126$
27 Amortization of PISCC - Transmission (242,787)$ (249,286)$ (255,786)$ (262,285)$ (268,784)$ (275,283)$ (281,782)$ 28 Amortization of PISCC - Distribution (554,042)$ (569,563)$ (585,084)$ (600,605)$ (616,126)$ (631,647)$ (647,168)$ 29 Amortization of PISCC - Distribution - IEDC -$ -$ -$ -$ -$ -$ -$ 30 Amortization of PISCC - Underground Storage -$ -$ -$ -$ -$ -$ -$ 31 Amortization of PISCC - General -$ -$ -$ -$ -$ -$ -$ 32 Less: Amortization of PISCC (C) (796,830)$ (818,850)$ (840,870)$ (862,890)$ (884,910)$ (906,930)$ (928,950)$
33 Total PISCC Deferred Balance Line 26 + Line 32 7,002,018$ 7,011,147$ 7,022,683$ 7,035,922$ 7,054,421$ 7,078,012$ 7,110,176$
To Schedule 1, Line 5
Annualized Amortization Expense
34 Transmission Line 4 x Line 21 x 12 30,957$ 35 Distribution Line 5 x Line 22 x 12 242,886$ 36 Distribution - IEDC Line 6 x Line 23 x 12 3,384$ 37 Underground Storage Line 7 x Line 24 x 12 2,285$ 38 General Line 8 x Line 25 x 12 1,264$ 39 Total Amortization Expense Sum Lines 29-33 280,777$
To Schedule 1, Line 13
(A) Based on Amortization Life of Plant as of December 31, 2013. Annual depreciation rate is 1 divided by Number of Years, as shown on Attachment JRM-3, Schedule 6.(B) Calculated as the PISCC rates (line 2 & 3) multiplied by the monthly PISCC eligible balances. PISCC eligible balances are based on the gross plant placed in-service not yet captured for recovery in the CSIA.(C) Amortization of approximately $22,020 per month beginning in July 2020 is based on annualized amortization expense of $264,240 from TDSIC-12, Attachment JCS-R3, Schedule 3, Line 39.
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
TDSIC COMPONENT
POST IN-SERVICE CARRYING COSTS (PISCC)
Petitioner's Exhibit No. 3
REVISED Attachment JRM-3
Cause No. 44430-TDSIC-14
CEI North
Schedule 4
Page 1 of 2
A B C D = B x C
Line After-Tax (A) Amount ($000's) Weighting Cost WACC
1 Debt 534,876$ 33.44% 4.73% 1.58%2 Equity 749,716$ 46.87% 10.20% 4.78%3 Cost Free Capital 291,246$ 18.21% 0.00% 0.00%4 Other 23,611$ 1.48% 0.50% 0.01%5 Total 1,599,449$ 6.37% (B)
To Schedule 9, Line 2
Pre-Tax Equity Component Calculation
6 After-Tax Cost of Equity per Line 2 4.78% Line 2, Col. D7 One 100.00%8 Less: Current State Tax Rate 5.075% (C)
9 Federal Taxable 94.93% Line 7 - Line 810 One Less Federal Income Tax 79.00% 1 - 21%11 Effective Gross-Up Factor 74.99% Line 9 x Line 1012 Pre-Tax Equity 6.37% Line 6 / Line 11
Forecast - Adjusted ROR (fixed ROE)
Pre-Tax
13 Debt 1.58% from Line 114 Equity 6.37% from Line 1215 Cost Free Capital 0.00% from Line 316 Other 0.01% from Line 417 Total Pre-Tax Rate of Return 7.96% Sum Lines 13-16
To Schedule 1, Line 7
(A) All data in Lines 1 through 5 represent the actual balances as of December 31, 2020.
(B) Proof Equity Debt and Other Total18 Total New Capital Investment 163,710,717$ 163,710,717$ from Schedule 1, Line 619 Pre-Tax Return 6.37% 1.59% from Lines 13-1620 Return 10,435,117$ 2,603,000$ Line 18 x Line 1921 State Tax 529,582$ 5.075% x Line 2022 Federal Taxable Return 9,905,535$ 2,603,000$ Line 20 - Line 2123 Federal Tax 2,080,162$ Line 22 x 21%24 After Tax Return $ 7,825,372$ 2,603,000$ 10,428,373$ Line 20 - Lines 21 and 23
25 After Tax Return % 6.37% Line 24 / Line 18equals Line 5
(C) Represents a blended State Tax Rate: - January 1, 2021 - December 31, 2021 @ 5.075%- Based on 5.250% @ January 1, 2021 and 4.900% @ July 1, 2021
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
TDSIC COMPONENT
PRE-TAX RATE OF RETURN AT DECEMBER 31, 2020
Petitioner's Exhibit No. 3
REVISED Attachment JRM-3
Cause No. 44430-TDSIC-14
CEI North
Schedule 4
Page 2 of 2
A B C D = B x C
Line After-Tax (A) Amount ($000's) Weighting Cost WACC
1 Debt 474,876$ 30.75% 4.84% 1.49%2 Equity 777,931$ 50.37% 10.20% 5.14%3 Cost Free Capital 265,532$ 17.19% 0.00% 0.00%4 Other 26,100$ 1.69% 1.50% 0.03%5 Total 1,544,440$ 6.66%
(A)
All data in Lines 1 through 5 represent the actual balances as of June 30, 2020 (as presented in TDSIC-13 filing on JCS-3, Sch 4, Pg 1).
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
TDSIC COMPONENT
AFTER TAX PISCC RATE AT JUNE 30, 2020
Petitioner's Exhibit No. 3
REVISED Attachment JRM-3
Cause No. 44430-TDSIC-14
CEI North
Schedule 5
Page 1 of 1
Balance atLine Description 12/31/2020 Reference
Depreciable In-Service Balance
1 Transmission 22,348,651$ Schedule 2, Line 13, Col. G2 Distribution 140,754,240$ Schedule 2, Line 14, Col. G3 Distribution - IEDC 2,451,542$ Schedule 2, Line 15, Col. G4 Underground Storage 2,384,954$ Schedule 2, Line 16, Col. G5 General 456,377$ Schedule 2, Line 17, Col. G6 Total 168,395,764$ Sum Lines 1-5
Monthly Depreciation Rates
7 Transmission 0.25% (A)
8 Distribution 0.29% (A)
9 Distribution - IEDC 0.24% (A)
10 Underground Storage 0.36% (A)
11 General 0.33% (A)
Annualized Depreciation Expense
12 Transmission 661,299$ Line 1 x Line 7 x 1213 Distribution 4,940,017$ Line 2 x Line 8 x 1214 Distribution - IEDC 70,460$ Line 3 x Line 9 x 1215 Underground Storage 103,501$ Line 4 x Line 10 x 1216 General 18,116$ Line 5 x Line 11 x 1217 Total Annualized Depreciation Expense 5,793,393$ Sum Lines 12-16
To Schedule 1, Line 10
(A)
(B) Reflects no plant additions through current period for class of plant.
Current average of authorized depreciation rates. Supporting work papers will show a detailed calculation of depreciation rates by class of plant.
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
TDSIC COMPONENT
ANNUALIZED DEPRECIATION EXPENSE - ON NEW CAPITAL INVESTMENT
8 Transmission 2.94%9 Distribution 3.57%10 Distribution - IEDC 3.57%11 Underground Storage 3.85%12 General 4.00%
Deferred Depreciation Amortization Expense
13 Transmission Line 1 x Line 8 14,032$ 14 Distribution Line 2 x Line 9 133,562$ 15 Distribution - IEDC Line 3 x Line 10 1,563$ 16 Underground Storage Line 4 x Line 11 1,491$ 17 General Line 5 x Line 12 604$ 18 Deferred Depreciation Amortization Expense Sum Lines 13-17 151,252$
To Schedule 1, Line 12
(A) Calculated by taking the gross new plant investment, less retirements, placed in-service but not yet included in CSIA recovery.(B) Amortization of approximately $12,005 per month beginning in July 2020 is based on annualized amortization expense of $144,056 from TDSIC-12, Attachment JCS-R3, Schedule 6, Line 18.(C) Based on Amortization Life of Plant as of December 31, 2013. Annual depreciation rate is 1 divided by Number of Years.
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
TDSIC COMPONENT
AMORTIZATION OF DEFERRED DEPRECIATION
Petitioner's Exhibit No. 3
REVISED Attachment JRM-3
Cause No. 44430-TDSIC-14
CEI North
Schedule 7
Page 1 of 1
Line Description Amount (A) Reference1 TDSIC-1, TDSIC Component - through 06/30/2014 154,886$ TDSIC-1, JCS-3, Sch 7, Line 12 TDSIC-2, TDSIC Component - through 12/31/2014 142,189$ TDSIC-2, JCS-3, Sch 7, Line 23 TDSIC-3, TDSIC Component - through 06/30/2015 593,033$ TDSIC-3, JCS-3, Sch 7, Line 34 TDSIC-4, TDSIC Component - through 12/31/2015 866,375$ TDSIC-4, JCS-3, Sch 7, Line 45 TDSIC-5, TDSIC Component - through 06/30/2016 1,430,201$ TDSIC-5, JCS-3, Sch 7, Line 56 TDSIC-6, TDSIC Component - through 12/31/2016 1,508,103$ TDSIC-6, JCS-3, Sch 7, Line 67 TDSIC-7, TDSIC Component - through 06/30/2017 1,695,222$ TDSIC-7, JCS-3, Sch 7, Line 7 (C)
8 TDSIC-8, TDSIC Component - through 12/31/2017 1,577,588$ TDSIC-8, JCS-3 (Revised), Sch 7, Line 89 TDSIC-9, TDSIC Component - through 06/30/2018 1,816,862$ TDSIC-9, JCS-3, Sch 7, Line 9
10 TDSIC-10, TDSIC Component - through 12/31/2018 1,724,791$ TDSIC-10 JCS-R3, Sch 7, Line 10 (D)
11 TDSIC-11, TDSIC Component - through 06/30/2019 2,077,604$ TDSIC-11 JCS-3 (Revised), Sch 7, Line 1112 TDSIC-12, TDSIC Component - through 12/31/2019 1,865,702$ TDSIC-12 JCS-R3, Sch 7, Line 1213 TDSIC-13, TDSIC Component - through 06/30/2020 2,207,396$ TDSIC-13 JCS-3, Sch 7, Line 1314 TDSIC-14, TDSIC Component - through 12/31/2020 1,917,188$ (B)
15 Total Deferred Revenue Requirement 19,577,140$
Notes:
(A)
(B)
(C) Adjusted to reflect the lower pre-tax rate of return using a 21% Federal Tax Rate - no other changes made to authorized amounts.(D) TDSIC-10 deferred revenues have been adjusted to reflect the corrected allocation previously described in Witness Swiz’s
TDSIC-11 testimony (Page 18).
Pending results from 2% TDSIC Annual Retail Revenue Cap Test from Attachment JRM-3, Schedule 8, additional information may be provided for TDSIC Deferred in Excess of 2% Cap.Attachment KJT-1, Schedule 3, Line 20, Sum of Jul-Dec 2021 x Allocation of TDSIC Component Revenue Requirement from Attachment JRM-1, Schedule 1
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
TDSIC COMPONENT
DEFERRED REVENUE REQUIREMENT (20%)
Petitioner's Exhibit No. 3
REVISED Attachment JRM-3
Cause No. 44430-TDSIC-14
CEI North
Schedule 8
Page 1 of 2
TotalLine Description Amount Reference
1 Current TDSIC Recoverable Portion (A) 16,376,445$ Schedule 1, Line 172 Less Current IEDC Recoverable Portion (223,027)$ Schedule 8, Page 2, Line 173 Prior TDSIC Recoverable Portion (A) 16,701,151$ TDSIC-13, JCS-3, Schedule 1, Line 174 Less Prior IEDC Recoverable Portion (179,424)$ TDSIC-13, JCS-3, Schedule 8, Page 2, Line 175 Increase in TDSIC Recoverable Portion (368,309)$ Line 1 + Line 2 - Line 3 - Line 4
6 Total Retail Revenues (A) 566,110,250$ 12 Months Ended As of End of Period7 TDSIC Cap 2% [Ind. Code § 8-1-39-14(a)]8 TDSIC Cap - 2% of Retail Revenues 11,322,205$ Line 6 x Line 7
9 Does Increase in TDSIC Exceed 2% Cap? No If Line 5 > Line 8, Yes; If not, No
If Yes:
10 TDSIC Cap - 2% of Retail Revenues -$ If Yes - Line 8; If No, $011 Plus: Prior TDSIC Recoverable Portion -$ If Yes - Line 3; If No, $012 Total TDSIC Recoverable in CSIA -$ Line 10 + Line 11
13 Current TDSIC Recoverable Portion -$ If Yes - Line 1; If No, $014 TDSIC Deferred in Excess of 2% Cap -$ Line 13 - Line 12
If No:
15 Current TDSIC Recoverable Portion - CSIA 16,376,445$ If No, Line 1; If Yes, $0
Note:
(A) TDSIC Recoverable portion is calculated by subtracting the recoverable component from Distribution IEDC (targeted economic development projects) from the total recoverable component. Retail revenues are also adjusted to exclude revenues associated with targeted economic development projects.
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
TDSIC COMPONENT
2% TDSIC ANNUAL RETAIL REVENUE CAP TEST
Petitioner's Exhibit No. 3
REVISED Attachment JRM-3
Cause No. 44430-TDSIC-14
CEI North
Schedule 8
Page 2 of 2
Line Description Distribution - IEDC Reference
Return on New Capital Investment:
1 Gross New Capital Investment - As of End of Period 2,451,542$ Schedule 2, Line 15, Col. G2 Accumulated Depreciation - As of End of Period (213,055)$ Schedule 2, Line 39, Col. G3 Net New Capital Investment - As of End of Period 2,238,487$ Line 1 + Line 2
4 New Capital Investment CWIP - As of End of Period -$ Schedule 2, Line 45, Col. G
5 PISCC Deferred Balance - As of End of Period 94,757$ Schedule 3, Line 23 + Line 29, Col. G
6 Total New Capital Investment - As of End of Period 2,333,244$ Line 3 + Line 4 + Line 5
7 Pre-Tax Rate of Return 7.96% Schedule 4, Page 1, Line 17
8 Annualized Return on New Capital Investment 185,726$ Line 6 x Line 7
Incremental Expenses
9 Property Tax Expense - Annualized 17,651$ (Line 1 x 0.72%) + (Line 4 x 0.24%) (A)
10 Depreciation Expense - Annualized 70,460$ Schedule 5, Line 14
12 Amortization Expense - Deferred Depreciation 1,563$ Schedule 6, Line 15, Col. G
13 Amortization Expense - Deferred PISCC 3,384$ Schedule 3, Line 36, Col. G
14 Total Incremental Expenses 93,058$ Sum Lines 9-13
Margin Netting:
15 Reduction of Margins from New Snow & Ogden Customers - As of End of Period -$ N/A for TDSIC Component
16 Annual Revenue Requirement - TDSIC Component 278,784$ Line 8 + Line 14
17 Recoverable TDSIC Component of CSIA (80%) 223,027$ Line 16 x 80% (B)
18 To Be Deferred (20%) 55,757$ Line 16 x 20%
Notes:
(A)
(B) To Attachment JRM-3, Schedule 8, Page 1, Line 2
The annualized level of property taxes is calculated using an estimated CEI North rate of 2.40% multiplied by the tax basis of the: (1) plant, estimated to be 30% of the gross new capital investment amount, and (2) CWIP, estimated to be 10% of the new capital investment CWIP amount.
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
TDSIC COMPONENT
TARGETED ECONOMIC DEVELOPMENT REVENUE REQUIREMENT THROUGH DECEMBER 31, 2020
Petitioner's Exhibit No. 3
REVISED Attachment JRM-3
Cause No. 44430-TDSIC-14
CEI North
Schedule 9
Page 1 of 1
TotalLine Description Amount Reference
1 Total New Capital Investment - As of End of Period 163,710,717$ From Schedule 1, Line 6
2 After-Tax Rate of Return 6.37% From Schedule 4, Page 1, Line 5
3 NOI Adjustment for GCA Earnings Test - TDSIC-14, TDSIC Component 10,428,373$ Line 1 x Line 2
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTH
CEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)
Total Excluding IURT29 210 47,552,514$ 7.13$ Line 15 + 2230 220/229 16,355,622$ 0.0976$ Line 16 + 2331 225 341,261$ 0.0180$ Line 17 + 2432 240 380,725$ 0.1359$ Line 18 + 2533 245 2,091,273$ 0.0167$ Line 19 + 2634 260/270 3,972,376$ 0.0061$ Line 20 + 27
35 Total 70,693,771$
Total Including IURT (D)36 210 7.24$ Line 29 / 0.985337 220/229 0.0991$ Line 30 / 0.985338 225 0.0183$ Line 31 / 0.985339 240 0.1379$ Line 32 / 0.985340 245 0.0169$ Line 33 / 0.985341 260/270 0.0062$ Line 34 / 0.9853
Notes:(A) From KJT-1, Schedule 2, Column D + Column F(B) From KJT-1, Schedule 2, Column H(C) From JRM-1, Schedule 2, Page 1, Line 22 – amount to be recovered from or passed back to customers over 6-months.(D) IURT gross up factor of 0.9853 effective January 1, 2021(E) Based on 2021 budgeted annual customer count and volumes(F) Based on 2020 budgeted semi-annual customer count and volumes
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTHCEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)RATE DERIVATION
FOR THE PERIOD OF JULY 1, 2021 THROUGH DECEMBER 31, 2021
9 245 Large General Transportation Service 3.47% 2,163,667$ 1.02% 167,040$ 3.47% (414,410)$
10 260/270Large Volume Transportation Service & Long-term Contract Service 7.05% 4,395,923$ 2.07% 338,992$ 7.05% (841,957)$
62,353,517$ 16,376,445$ (11,942,652)$
Notes:(A) From JRM-1, Schedule 1, Page 1 of 1, Line 1, Col. C(B) From JRM-1, Schedule 1, Page 1 of 1, Line 2, Col. C(C) Line 1 + Line 2(D) From WP JRM-1-2.2 EADIT Credit
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTHCEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)ALLOCATION OF REVENUE REQUIREMENT EXCLUDING VARIANCES
10 240 - Interruptible Sales Service Therms 0.1359$ 0.1359$ 0.1359$ 0.1359$ 0.1359$ 0.1359$ 0.1284$ 0.1284$ 0.1284$ 0.1284$ 0.1284$ 0.1284$ 11 245 - Large General Transportation Service Therms 0.0167$ 0.0167$ 0.0167$ 0.0167$ 0.0167$ 0.0167$ 0.0139$ 0.0139$ 0.0139$ 0.0139$ 0.0139$ 0.0139$ 12 260/270 - Large Volume Transportation Service & Long-term Contract Service Therms 0.0061$ 0.0061$ 0.0061$ 0.0061$ 0.0061$ 0.0061$ 0.0058$ 0.0058$ 0.0058$ 0.0058$ 0.0058$ 0.0058$
Projected Recoveries13 210 - Residential Sales Service Line 1 x Line 7 4,015,277$ 4,008,389$ 4,012,869$ 4,033,720$ 4,086,447$ 4,110,841$ 3,887,368$ 3,894,444$ 3,895,524$ 3,886,338$ 3,869,314$ 3,851,982$ 47,552,514$ 14 220/229 - General Sales Service Line 2 x Line 8 267,891$ 259,072$ 343,222$ 878,615$ 2,203,605$ 3,591,757$ 3,070,110$ 2,516,959$ 1,744,628$ 891,751$ 385,524$ 202,485$ 16,355,622$ 15 225 - School/Government Transportation Service Line 3 x Line 9 9,340$ 9,620$ 11,034$ 17,116$ 26,133$ 44,572$ 53,588$ 55,620$ 49,243$ 32,203$ 21,122$ 11,670$ 341,261$ 16 240 - Interruptible Sales Service Line 4 x Line 10 10,817$ 7,776$ 8,381$ 25,511$ 101,261$ 67,488$ 42,009$ 36,087$ 33,669$ 25,846$ 13,046$ 8,833$ 380,725$ 17 245 - Large General Transportation Service Line 5 x Line 11 106,699$ 114,474$ 140,198$ 172,973$ 200,900$ 301,454$ 240,468$ 252,437$ 152,881$ 170,768$ 126,660$ 111,361$ 2,091,273$ 18 260/270 - Large Volume Transportation Service & Long-term Contract Service Line 6 x Line 12 305,296$ 311,685$ 291,670$ 329,651$ 365,926$ 375,356$ 382,450$ 351,083$ 338,647$ 317,418$ 311,885$ 291,308$ 3,972,376$
19 Total Recoveries including variances during first six months 4,715,321$ 4,711,017$ 4,807,374$ 5,457,585$ 6,984,273$ 8,491,470$ 7,675,993$ 7,106,631$ 6,214,592$ 5,324,324$ 4,727,551$ 4,477,640$ 70,693,771$
Notes:(A) Based on 2021 budgeted annual customer count and volumes(B) First six months Per KJT-1, Sch 1, Lines 29 - 34. Second six months Per KJT-1, Sch 1, Lines 15 - 20. All rates exclude IURT.
INDIANA GAS COMPANY, INC. d/b/a CENTERPOINT ENERGY INDIANA NORTHCEI NORTH
COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT (CSIA)PROJECTED RECOVERIES BY MONTH
Indiana Gas Company, Inc. D/B/A Sheet No, 40 Vectren Energy Delivery of Indiana, Inc. (Vectren North) Fourteenth Revised Page 1 of 1 Tariff for Gas Service Cancels Thirteenth Revised Page 1 of 1 I.U.R.C. No. G-19
Effective: July 1, 2021
APPENDIX K COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT
APPLICABILITY
The Compliance and System Improvement Adjustment (“CSIA”) shall be applicable to all Customers on the Rate Schedules set forth in the CSIA Charges section below.
DESCRIPTION
The CSIA shall include, as approved by the Commission:
(1) In Cause No. 44429, recovery of costs incurred pursuant to Federally Mandated Projects(“Compliance”) as provided for in Ind. Code Ch. 8-1-8.4;
(2) In Cause No. 44429, recovery of costs associated with Company’s TDSIC Plan (“TDSIC”) asprovided for in Ind. Code Ch. 8-1-39 for the purposes of safety, reliability, systemmodernization, or economic development; and
(3) In Cause No. 45032-S21, credits associated with the amortization of Excess AccumulatedDeferred Income Tax (“EADIT Credits”) liability resulting from the Tax Cuts and Jobs Act of2017.
Reconciliation
Company’s actual CSIA costs and EADIT Credits shall be reconciled semi-annually with actual CSIA recoveries, with any differences being reflected as a charge or credit in a subsequent CSIA.
Allocation Percentages
CSIA costs and EADIT Credits shall be allocated to the Rate Schedules based on percentages approved in Cause No. 44430 TDSIC-5 and Cause No. 45032-S21.
Indiana Gas Company, Inc. D/B/A Sheet No, 40 Vectren Energy Delivery of Indiana, Inc. (Vectren North) Fourteenth Revised Page 1 of 1 Tariff for Gas Service Cancels Thirteenth Revised Page 1 of 1 I.U.R.C. No. G-19
Effective: July 1, 2021
Deleted: Thirteenth
Deleted: Twelfth
Deleted: January
APPENDIX K COMPLIANCE AND SYSTEM IMPROVEMENT ADJUSTMENT
APPLICABILITY
The Compliance and System Improvement Adjustment (“CSIA”) shall be applicable to all Customers on the Rate Schedules set forth in the CSIA Charges section below.
DESCRIPTION
The CSIA shall include, as approved by the Commission:
(1) In Cause No. 44429, recovery of costs incurred pursuant to Federally Mandated Projects(“Compliance”) as provided for in Ind. Code Ch. 8-1-8.4;
(2) In Cause No. 44429, recovery of costs associated with Company’s TDSIC Plan (“TDSIC”) asprovided for in Ind. Code Ch. 8-1-39 for the purposes of safety, reliability, system modernization, or economic development; and
(3) In Cause No. 45032-S21, credits associated with the amortization of Excess AccumulatedDeferred Income Tax (“EADIT Credits”) liability resulting from the Tax Cuts and Jobs Act of2017.
Reconciliation
Company’s actual CSIA costs and EADIT Credits shall be reconciled semi-annually with actual CSIA recoveries, with any differences being reflected as a charge or credit in a subsequent CSIA.
Allocation Percentages
CSIA costs and EADIT Credits shall be allocated to the Rate Schedules based on percentages approved in Cause No. 44430 TDSIC-5 and Cause No. 45032-S21.