7/28/2019 Assignment-EMCM (Contract Management) Q3
1/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 1 of 24
Question 3
Your company has a 2-year, RM 80 million construction contract that has got into troubles.
The problems include:
Soil problems that necessitate additional RM 5 million of concrete piles and 2-month
delay.
Material price was up 20%.
Transportation cost was up by 30%.
Shoddy work by two sub-contractors has necessitated re-work causing RM 3 million
and a delay of 1 month.
Long monsoon season with heavy rain and flood caused a aggregate delay of two
months.
The consultant modified the design which caused RM 5 million worth of re-work
(including tear-down, clearing and re-build) and 2-month delay (including re-design
time).
Work efficiency is only 70% of original estimate
The client (owner) has threatened to sue your company for the delays and claim
penalties of RM 100,000 per day.
Your company may be facing huge direct financial losses and possible litigation. Your boss
put the blame on the project manager, who is your colleague, and he was removed from the
7/28/2019 Assignment-EMCM (Contract Management) Q3
2/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 2 of 24
project and subsequently asked to resign. You have been assigned by the management to take
over the project.
This is the golden opportunity for you to show off your skills, and to avoid the prospect of been
sacked!
Describe how you would manage the contract.
Be specific, i.e., solve the problems one by one. Dont just give general approaches. You are
solving a problem in this particular case study. Use all the knowledge and skills you have
learnt from the Contract Management module. You are encouraged to use your initiatives.
Present your solution with the following headings: Status Definition, Solution Approach,
Resolution of the legal and contractual problems, Strategy for Modern Contract Management,
Solutions of problems.
(Approx. 2 to 4 marks for each of the first four sections, rest for solution section)
[TOTAL: 20 MARKS]
7/28/2019 Assignment-EMCM (Contract Management) Q3
3/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 3 of 24
Answer 3;
The original contract worth is RM 80 million and the construction contracts duration is to be
completed in 2 years. Assumption was made that this is a government project, the Director of
JKR is the Superintending Officer (S.O) and the power was delegated to JKR District
Engineer. The project name is The Proposed Construction of Academic Building, Dental
Hospital, Hostel and Infrastructure Works for the Faculty of Dentist UITM Sungai Buloh,
Selangor Darul Ehsan. Also assumed that the contract is bounded by JKR (PWD) 203a
conditions of contract where bill of material is form part of the contract and shall also referred
to The Commercial Law of Malaysia.
Figure 1: Traditional Building Contract (BEM Bulletin, Sep-Nov 2007).
It is important to overcome the current difficulties, disadvantage and under pressure situation
and turn it to a better position. The proposal to overcome this situation shall be structured as
follows;
7/28/2019 Assignment-EMCM (Contract Management) Q3
4/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 4 of 24
1. Status Definition.
2. Solution Approach.
3. Resolution of the legal and contractual problems.
4. Strategy for Modern Contract Management.
5. Solutions of problems.
1. Status Definition.
This is a traditional contract where client (JKR) initiates and sanctions of a project, concept
design was done by the architect and the design engineering consultant who are the one who
design and prepare all the necessary document for tender. The company is now facing huge
direct financial losses, progress claims was freeze due to some unresolved issues and possible
litigation. The former project manager was removed from the project and I have just been
assigned by the management to take over the project.
In any contract three main criteria which are the time,cost andacceptableperformance with
safety and sustainability are upmost important to determine the project success. In order to
achieve that the commercial issue which is the cash flow and the adequate time are very-very
important or else the project cannot be running smoothly. We had analysed the project current
situation and it can be summarised as follows;
7/28/2019 Assignment-EMCM (Contract Management) Q3
5/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 5 of 24
Table 1: Summary of Estimated Delay and Forecast Additional Cost Incurred.
No Description Delay Cost (RM)
i) Soil Problems, additional concrete piles (fallunder provisional quantities)
2 months 5.0 Million
ii) Material price was up 20%. 3.0 Million(Assumption)
iii) Transportation cost was up by 30% 0.3 Million(Assumption)
iv) Shoddy work by two sub-contractors hasnecessitated re-work
1 months 3.0 Million
v) Long monsoon season with heavy rain andflood 2 months
vi) The consultant modified the design whichcaused to re-work and additional design time.
2 months 5.0 Million
vii) Work efficiency dropped to 70% of originalestimate productivity
2 months 1.0Million(Assumption)
viii) The client (owner) has threatened to sue yourcompany for the delays and claim penalties ofRM 100,000 per day.
Not
effective
yet
Max 10% of
Contract Value 8
Million (estimated)
Total 9 months 25.3 Million
Note:Marked inblue - Consultant/Client issues
Marked inred - Contractor issues
Project progress claims have been very little since a couple of monthsduring the monsoon
and floodas the work progress is affected very badly. In the same time due to the shoddy
works by our two sub-contractors, our progress claims under their portion were not being
approved and not paid. These had tarnished the project cash flow very badly and had caused
thepayment to suppliers, sub-contractors, machineries and even the wages to our in house
workers were also two months delayed. Due to this the project had loose its momentum and
productivities were reduce to 70%.
7/28/2019 Assignment-EMCM (Contract Management) Q3
6/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 6 of 24
Need to carry out additional pilling works due to soil issue, estimated cost incurred RM 5
million with two months additional time. In addition JKR had requested their consultant to
redesign some building section where all of this had resulted to some reworks and
additional to existing job scope. This shall involve quite extensive amount of money where
RM 5million worth of re-work (including tear-down, clearing and re-build) and 2-month
delay (including re-design time) shall be required.
Due to petrol/diesel hikes, natural disaster and redevelopment for those affected countries e.g.
Japan, Australia, New Zealand, United States and others, currently the company need to
absorb the materials and transportation escalation costsof 20% and 30% in which these had
worsened the project cash flow. The project will be at lost shall we are forced to absorb all
these additional cost not to mentioned the heavy penalty/LAD of approximately RM
100,000.00 per day for 9 month which is surely additional of RM 8 million (Normally,
maximum LAD is limited to 10% of the contract value).
The company shall requires additional funding to finance theadditional incurred cost of RM
25.3 million and may requires additional time of nine (9) months to complete all these
works shall no step or action taken to resolve them via contractually approach. Additional
32% of cost from the total contract value (25.3 million / 8 million X 100 = 32%) is very huge
and surely cannot be covered with the 15% (12 million) estimated net profit. In addition RM 4
million (5% of the contract value) are deducted gradually from the claims and shall be retained
for 12 months after the completion date as retention money.
7/28/2019 Assignment-EMCM (Contract Management) Q3
7/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 7 of 24
Basically all the matter arises here can be portrayed in these followings figures;
Figure 3: Provisional Quantities in Conjunction to PWD Form 203a Condition of
Contract Clause 26.5 to 26.7.
Chart 4: S.Os Instruction and Variation are in Conjunction to PWD Form 203a Condition
of Contract Clause 5.0 to 24.0.
7/28/2019 Assignment-EMCM (Contract Management) Q3
8/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 8 of 24
Chart 3: Failure to Complete on Time (BEM Bulletin, Sep-Nov 2007).
Chart 4: Price Escalation Who Will Pay??? (BEM Bulletin, Sep-Nov 2007).
7/28/2019 Assignment-EMCM (Contract Management) Q3
9/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 9 of 24
2. Solution Approach.
I believe collaboration approaches between contractor, consultants and client is the best
strategy to overcome this issues. After all Conditions of Contract in PWD Form 203a is a
very established form of contract and the most important is it offers a very fair deal to all the
parties involves. We can fight for our right via collaboration approach and win-win strategy.
However shall the matter have been left for a length of time and therefore some personnel that
represent the parties involves might leaved the project either resigned or being assigned to
another project, the solution even via collaboration also not as simple as it take especially
when the person who give the instruction is no more in the picture.
The good working relations between all the parties involves i.e. the client, consultant and
contractor that have the spirit of partnering and sharing the common goal objectives to
complete the project within budgeted cost, scheduled time and at acceptable performance with
safety and sustainability shall ease the collaboration and the negotiation of all parties in
finding the best solution methods to resolves these issues.
In partnering and collaboration contract approach, it can lower the risk of time and cost
overrun as the parties including the contractor, client and consultant are working together
towards the completion of the project and to complete them on time. This understanding of all
parties involve are also reducing the exposure to litigation. Less confrontation and a good
7/28/2019 Assignment-EMCM (Contract Management) Q3
10/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 10 of 24
working environment and trust contribute the fast solving problems before they escalate to
disputes. The project performance and quality are improved because energies are focused to
achieve the project goal and not misdirected to adversarial concerns.
The partners shall proactively anticipate and try to solve or avoided the problems. Variations if
happen mean they are really genuine and unavoided. With a good communications and
empowerment by senior management this shall be able to reduce the need of lawyers in the
administration. Good communication allows all parties to resolve issues expeditiously as they
can meet up frequently and this shall avoid mistake or rework. The opportunity for financial
successful also increased because of non adversarial or win-win attitude on all parties.
3.Resolution of the legal and contractual problems.
It is part of a project manager responsibility find an equitable, speedy and cheap method of
resolving disputes and maintains focus on the project. In my opinion collaboration and
cooperative attitude among all parties involves including the client (JKR), consultant and
contractor is still the best method to resolve all the issues and disputes face in this project
however shall it is fails we still have other options as proposed by alternative dispute
resolution approach as tabulated in Table 1, below;
7/28/2019 Assignment-EMCM (Contract Management) Q3
11/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 11 of 24
Table 2: Dispute Resolution Steps
Steps Cost/
Hostility
Name Process
1 Low Prevention Risk allocation, Incentive for cooperation, Partnering
2 Negotiation Direct negotiation, Step negotiations
3 Independent
Expert
Dispute review board, Standing arbitrator or Independent
expert.
4 Mediation Non-binding resolution, Mini-trial, Advisory opinion,
Advisory arbitration.
5 Arbitration Binding resolution6 High Litigation Civil Court, Judge
In my opinion and based from my previous experiences, all the issues arise here are straight
forward and can be resolved in conjunction to PWD Form 203a Conditions of Contractand
the Contract Document. If all parties have the spirit of partnering and sharing common goal all
these issues can be amicably resolved. Despite collaboration approach, negotiation is another
good approach to resolve all the crops up issues. In normal practice contractor shall approach
and convince the consultant and JKR especially on the variation orders that results to schedule
and commercial impacts.
The project team shall require to search for any documents that might help to support our
claim on the variation, escalation cost, provisional quantities and E.O.T., The document might
come in various forms e.g. Sites Instruction (if any), Notification of Change (if any), proof of
any instruction written on site diary, instruction recorded in the Minute of Meetings, soil
investigation report, piling records, rain records recorded in site diary and materials invoices,
PWD Cost of Index for escalation cost and etc.
7/28/2019 Assignment-EMCM (Contract Management) Q3
12/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 12 of 24
Convincing the consultant earlier then the client (JKR) might also help to resolve these issues.
Maybe we should approach their COW and their RE and put all the issues, stories and issues
to them for their understanding and for them to chew first. This can be done over a coffee talk,
golf game or even a karaoke session. That is where good communication and interpersonal
skill is very important. Later the consultant may give their good recommendation to the client
shall we managed to explain them properly and convincingly about the problems faced. This
can be followed appending all the issues, who responsible for it and how to solve in the
weekly or monthly meetings with that is attended by the consultant and the client/JKR.
It might creates a havoc as the quantities is quite big and not been highlighted in advance but
this is unavoided as that should be done by the earlier project manager. We will also include
all the issue arises in the coming biweekly or monthly report. After that notification about
these issues can be forwarded concurrently to both the consultant and the client (JKR). In
order to avoid an upset the client (JKR) we can also approach them separately. That is where
in modern contract management, good relations between all parties are important as after all
everybody are sharing the common goal to complete the work in time.
Theorically most of the issues arises are unavoidable and allows by the contract and therefore
with a good communication skill and approach might be able to achieve a mutual
understanding and solution. Shall everybody are transparent to each other, have a high respect
and understanding these issues can be easily be resolved cordially.
7/28/2019 Assignment-EMCM (Contract Management) Q3
13/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 13 of 24
We shall then submit the detail justification and variation claim where normally it will be
followed by a few meetings as the consultant and the client want to know these issues in more
detail. Shall the consultant and the client agreed to the change order/variation and the EOT
that have been submitted, another meeting shall normally be called in order to quantify and
negotiate for the additional cost and EOT required.
Basically the following issues shall fall under the stipulated clause of the PWD 203a
Conditions of Contract;
Soil problems that necessitate additional RM 5 million of concrete piles and 2-month
delay. - fall under clause 26.0 Bill of Quantities, Sub-clause Provisional Quantities 26.5,
26.6 and 26.7 and additional time should fall under clause 43.0 Delay and EOT.
Material price was up 20% - fall under clause 30.0 Fluctuation of Price.
Transportation cost was up by 30% - fall under clause 30.0 Fluctuation of Price.
Shoddy work by two sub-contractors has necessitated re-work causing RM 3 million and
a delay of 1 month fall under clause 10.1 Obligation of the Contractor sub-clause i).
Long monsoon season with heavy rain and flood caused a aggregate delay of two months
- Clause 43.1 b) exceptionally inclement weather and clause 57.0 Effect of Force Majeure
sub-clause 57.2 c) can be used to apply for extension of time clause 43.0 Delay and EOT.
The consultant modified the design which caused RM 5 million worth of re-work
l(including tear-down, clearing and re-build) and 2-month delay (including re-design
time). - This fall under Clause 5.0 S.O.S Instruction and Clause 24.0 Variations. To apply
for extension of time clause 43.0 Delay and EOT.
7/28/2019 Assignment-EMCM (Contract Management) Q3
14/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 14 of 24
Work efficiency is only 70% of original estimate fall under 10.1 Obligation of the
Contractor sub-clause i) to complete the works on time. It is the responsibility of the
contractor to accelerate the works progress in order to get the work progress back to
right track.
The client (owner) has threatened to sue your company for the delays and claim penalties
of RM 100,000 per day. fall under clause 40.0 Damages for Non-Completion but this
can be avoided as most of the issues are actually subject to EOT in conjunction to clause
43.0 Delay and EOT.
In my opinion and through my past experiences dealing with various clients including JKR, all
the above issues are not so serious as for most of them we have the basis to make claim for
extra quantities, variation claims and EOT. I believed with the right approach, proper
documentations, convincing justifications and sufficient proof and supporting documents, all
these issues can be settled amicably. Most of the issues are actually allowed by the
Conditions of Contract of JKR/PWD Form 203a. The most important thing we need to
notify and justify to the consultant and JKR what make we feel we are entitle for the variation,
additional claims on provisional sum and the EOT.
In worst scenario shall some of our request being rejected although they are allowed by the
contract conditions, we can bring this matter to arbitration court. Litigation although it is
legally allowed in the contract law in the other hand is not advisable as it will be carried out
openly and might not favourable by the client. One thing for sure although our intention is to
protect the companys right and to recover from loses we also do not want this exercise to
7/28/2019 Assignment-EMCM (Contract Management) Q3
15/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 15 of 24
tarnish any parties and our potential for future job with them and other project provider might
also notice this as well and may not favourable to our action. Arbitration in the other hand
shall be carried out in a close court and can be settled quietly.
4. Strategy for Modern Contract Management.
In modern contract management win-win solution approach to all the parties involves is
something that everybody is looking forward to achieve best. In modern contract management
traditional approach which full with adversarial confliction should be avoided. Win-lose
strategy in traditional adversarial attitude might put the project in jeopardy. Conflicting does
not help the project to succeed. In modern contract management all the parties involved should
sharing the common goals which is to complete the project within budgeted cost, scheduled
time and at acceptable performance with safety and sustainability.
Treating all the parties as smart partner can plays a key role in attaining continuous
improvement especially in delivering of the construction project. The spirit of partnering
approach treats contractors as own resources, motivate them, recognition of commons goal
create atmosphere of trust, teamwork and goodwill which will facilitate this goals. Working in
a good working atmosphere shall ease all parties in discussing sharing ideas and making a
good decision shall any problem arise. By conflicting we not only will failed to solve the
problems but might go deeper into trouble.
7/28/2019 Assignment-EMCM (Contract Management) Q3
16/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 16 of 24
In the other hand prolong or avoidance of problems and the issues faced are not giving the
project any good. All parties should understand that we are actually in this mess together and
therefore in making the project into a success all parties involves should give their best
commitment and to trust each other in solving the problems and achieving the mutual goals.
All parties should sit down and discuss about the project problems and what is the best
approach to resolve are the issues. For instance all parties involve should accept their fault
shall any, fairly treatment to other parties, to fulfil each party obligations as what have been
stipulated in the Conditions of Contract, to work as a team, and etc. in order to lead the
project towards a success. Owner and contractor work together to manage the risk and achieve
a better result for both parties.
Client also need to safeguards and to protect the contractors against unforeseen risks and
circumstances beyond their control for their mutual benefits. The key to all of this is
communication, consideration and anticipation for risk how to solve them before they occurs.
Farsighted project contract management Ex-ante Incentivization that plan incentives in
advance normally adopted to goverment projects where project risk are between low to
medium. In the other hand Ex-post Governance were used where the risk need to be monitored
closely to allow adaptation to deal with uncertainty or unforeseen events that can caused
incompleteness.
The following conclusion was made by the contractor on who should be responsible for each
problem arises;
7/28/2019 Assignment-EMCM (Contract Management) Q3
17/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 17 of 24
Table 3: Proposed Amicably Solution as Per Modern Contract Management Strategy.
No Description of Problems Responsibility of Proposed Solution
1 Soil problems that necessitate additional
RM 5 million of concrete piles and 2-
month delay. Under ProvisionalQuantities)
Client To allow contractor
claim for extra
quantities underProvisional Quantities /
re-measured items and
to grant EOT.
2 Material price was up 20%. Client Client to issue VariationOrder under Fluctuation
of Price (Building CostIndex).
3 Transportation cost was up by 30%. Client Client to issue Variation
Order under Fluctuation
of Price.
4 Shoddy work by two sub-contractors has
necessitated re-work causing RM 3
million and a delay of 1 month.
Main Contractor
and sub-
contractor
Main Contractor to
ensure the re-works is
carried out either by the
sub-contractors or
themselves.
5 Long monsoon season with heavy rain
and flood caused an aggregate delay oftwo months.
Client Client to issue EOT.
6 The consultant modified the design which
caused RM 5 million worth of re-work
(including tear-down, clearing and re-
build) and 2-month delay (including re-
design time).
Client/Consultant Client to issue Variation
Order and grant EOT
7 Work efficiency is only 70% of original
estimate.Main Contractor Main Cont to accelerate
the work at their owncost to fulfil their
contractual obligation.
8 The client (owner) has threatened to sueyour company for the delays and claimpenalties of RM 100,000 per day.
Main ContractorSubject towhether the
requested EOT is
sufficient or not.
Negotiation and requestfor the EOT.
Note:Marked inblue - Consultant/Client issues
Marked inred - Contractor issues
7/28/2019 Assignment-EMCM (Contract Management) Q3
18/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 18 of 24
5. Solutions of problems.The following is our strategy on how to settle these problems;
a) Commercial Issues;Additional RM 25.3 million estimated shall be required in order to complete the works and to
pay the LAD and the statuses are tabulated below;
Table 4: Estimated Commercial Impact and their Solution.
No Description Cost (RM) What to do
i) Soil Problems additional concretepiles (Under Provisional Quantities)
5.0 Million To notify the Consultant and
JKR on Extra amount under
Provisional Quantities and
request EOT.
ii) Material price was up 20%. 3.0 Million(Assumption)
To notify the Consultant and
JKR request Variation Order
and EOT.
iii) Transportation cost was up by 30%. 0.3 Million
(Assumption)
To notify the Consultant and
JKR request Variation Orderand EOT.
iv) Shoddy work by two sub-contractorshas necessitated re-work.
3.0 Million To notify the sub-contractors
v) Long monsoon season with heavyrain and flood
To notify the Consultant and
JKR request EOT.
vi) The consultant modified the designwhich caused to re-work and
additional design time.
5.0 Million To notify the Consultant and
JKR and request Variation
Order and EOT.
vii) Work efficiency dropped to 70% oforiginal estimate productivity.
1.0Million(Assumption)
Catch up plan to increase
productivity by adding
resources.viii) The client (owner) has threatened to
sue your company for the delays and
claim penalties of RM 100,000 per
day.
Not effective yet
8 Million
(estimated)
Max 10% of Contract Value
Shall request for EOT.
Total 25.3 Million
Note:Marked inblue - Consultant/Client issuesMarked inred - Contractor issues
7/28/2019 Assignment-EMCM (Contract Management) Q3
19/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 19 of 24
The details of action and justification to be made shall be as follows;
i. Due to soil problems that necessitate additional RM 5 million of concrete piles and the
project was delayed 2 months because of it. Under Bill of Quantities Contract, the
concrete piles quantities should fall under clause 26.0 Bill of Quantities, Sub-clause
Provisional Quantities 26.5, 26.6 and 26,7 Therefore despite we can actually claim the
additional quantities under re-measured items we can also apply for extension of time due
this issue under clause 43.0 Delay and EOT.
In addition shall we refer to the case of, The Privy Council held in the case of Mitsui
Construction Co v. Attorney of Hong Kong (1986) 33 BLR 1 that quantities for certain
works in the BQ under re-measurement contract are wildly wrong (in this case
substantially increased) and contractor was entitled to higher rates for those works.
ii. Material price was up 20% due to patrol hikes and a lot of development going on in
almost in every part of the world which had push the materials cost to an upward trend. In
JKR 203a there is a clause that allows claims for escalation on materials. It is under clause
30.0 Fluctuation of Price.
iii. Transportation cost was up by 30% due to patrol hikes and increase on maintenance and
spare parts cost. The clause 30.0 Fluctuation of Price of the Contract Conditions shall be
used.
7/28/2019 Assignment-EMCM (Contract Management) Q3
20/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 20 of 24
iv. Shoddy work by two sub-contractors has necessitated re-work causing RM 3 million and
a delay of 1 month. The two sub-contractors are actually the nominated sub-contractors
for this project, under clause 61.0 stated no liability to the government because of the
nominated sub-contractor/supplier failure to do their job. But being our sub-contractor we
can either instruct them to repair or re-do their shoddy job or we can deduct their claims
and retention money and seeking the S.O. approval either to do it ourselves or to engage
other sub-contractors. After all the payments to nominated sub-contractor/supplier are
made direct to them deducted from the main contractor claims. Therefore shall our claim
are not approved due to their shoddy job, they also shall not got their claims. Clause 60.0
Payment to Nominated Sub-Contractor or supplier.
v. Long monsoon season with heavy rain and flood caused an aggregate delay of two
months. Clause 43.1 b) exceptionally inclement weather and clause 57.0 Effect of Force
Majeure sub-clause 57.2 c) can be used to apply for extension of time clause 43.0 Delay
and EOT.
vi. The consultant modified the design which caused RM 5 million worth of re-work
(including tear-down, clearing and re-build) and 2-month delay (including re-design time).
This additional works should be fall under Clause 5.0 S.O.S Instruction and Clause 24.0
Variations, where the price shall later being discussed and agreed by all parties. The
agreed addition/omission shall be later be adjusted to the contract sum. To apply for
extension of time clause 43.0 Delay and EOT.
7/28/2019 Assignment-EMCM (Contract Management) Q3
21/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 21 of 24
Referring to section 71 (Act 136) Contract Act 1950 stated, Where a person lawfully
does anything for another person, or delivers anything to him, not intending to do so
gratuitously, and such other person enjoys the benefit thereof, the latter is bound to make
compensation to the former in respect of, or to restore, the thing so done delivered.
(Emphasis supplied). Case of Aw Yong Wai Choo & Ors v. Arief Trading Sdn Bhd. &
Anor [1992] 1 MLJ 166 are referred.
vii.Work efficiency is only 70% of original estimate fall under 10.1 Obligation of the
Contractor sub-clause i) to complete the works on time. It is the responsibility of the
contractor to accelerate the works progress in order to get the work progress back to right
track.
viii. The client (owner) has threatened to sue your company for the delays and claim penalties
of RM 100,000 per day. Maximum of RM 8 million as max LAD are limited to 10% of
Contract Value. I believed it should fall under clause 40.0 Damages for Non-Completion
but this can be avoided as most of the issues are actually subject to EOT in conjunction to
clause 43.0 Delay and EOT.
The company shall required additional funding to finance the additional RM 25.3 million
which consists of RM 13.3 million that we feel a claimable amounts from client due to
variation to original scope of works and provisional sum and RM 3 million for repair/redo the
shoddy works and RM 1 million for accelerating the works progress for catch up plan
7/28/2019 Assignment-EMCM (Contract Management) Q3
22/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 22 of 24
including increase resources e.g. manpower, machineries, longer working hours and etc and 8
million for the LAD (maximum of 10% of the contract value).
However wemight be able to recover RM 3 million for the shoddy works from the two sub-
contractors or to instruct them to carry out the repair and redo works at their cost. Although
contractually we can recover them from the two sub-contractors but there is a possibility it is
not going to happen after all their performance bond is only 10% of their work value of RM 5
Million which is only worth RM 500, 000.00. Good news is the client (JKR) has not paid their
work portion yet therefore the sub-contractors might not have the capacity and money to carry
out the redo works.
My suggestion is, to buy the raw materials and supply required machineries in order to assist
our sub-contractor but they need to supply the manpower and supervision. Later all these
additional cost shall be deducted from the sub-contractors claims. One thing for sure they must
be agreed but both parties and necessary notices and meeting need to be carried out to make
them legally minuted in order to avoid any future argument. Another alternative is to take over
the sub-contractors works and to be deducted accordingly from their contract.
Shall the cost are more we can either forfeit their performance bond and bring them to
arbitration court or litigation or to absorb the excess cost..
My proposal requires us to spend extra RM 1 million from our own pocket for the catch up
plan but shall this can be carried out within the approved period of EOT,this might enable us
7/28/2019 Assignment-EMCM (Contract Management) Q3
23/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 23 of 24
to avoid from paying high penalty or LAD. The partnering spirit and our effort to drive the
work progress back to the right track might be sufficient to convince the consultant and client.
b) Delay Proposed EOT Required.
Below is how we strategise to resolve the delay issue;
Table 5: Showing How Many EOT Required in Completing all Problematic Issues.
No Description Delay Month
M1 M2 M3 M3
i) Soil Problems, additional concrete piles(Provisional Quantities)
2 months
ii) Material price was up 20%.
iii) Transportation cost was up by 30%
iv) Shoddy work by two sub-contractors has
necessitated re-work
1 months
v) Long monsoon season with heavy rain and flood 2 months
vi) The consultant modified the design which causedto re-work and additional design time.
2 months
vii) Work efficiency dropped to 70% of originalestimate productivity
2 months
viii) The client (owner) has threatened to sue your
company for the delays and claim penalties of RM
100,000 per day.
Total Required EOT 4 months
Note:Marked inblue - Consultant/Client issues
Marked inred - Contractor issues
Total extension of time (EOT) required shall be as the above table, where due to long
monsoon and flood (this incident had occurred) we need a replacement of two months the
7/28/2019 Assignment-EMCM (Contract Management) Q3
24/24
Name: Mohd. Norizam Bin Md. Salleh
Matriculation No.: CGS 00534317
Intake: September 2010
Assignment EMCM5103
Q 3 - Page 24 of 24
effected works can be carried out concurrently with the additional pilling works due to soil
problems. For the change of design, this activity shall be carried out immediately after the
piling works completed. This because the sequence of works as the pilling works needs to be
completed before we could build the building structure. For this activity we are also entitled
for EOT therefore in total only four months additional numbers of days are required. Two
months additional duration also requires to carry out the acceleration works and one month for
the repair/redo works as the result of our sub-contractors fault, we will also carry out them
concurrently and to complete them within the requested EOT duration.
By doing this weshall complete all of the said activities within the four (4) months required
additional periods and possibly no penalty/LAD will be imposed to us. As mentioned earlier
I personally feel that with win-win approach all these issues can be amicably resolve and the
common goal of completing the project within budgeted cost, scheduled time and at
acceptable performance with safety and sustainability can be achieved. It is important for
every party involve giving a high respect to each other right and acting accordingly in
conjunction to the conditions of contract fairly for everybody benefit and towards achieving
the project common goals.
All in all as other issues are more or less under control, we only need to spend additional cost
of RM 1 million for the acceleration of works and shall be given VO and the provisional
quantities amounted of RM 13.3 million. In which RM 5 million for additional concrete piles
(provisional quantities), RM 3 million for materials escalation, RM 300 thousand for
transportation escalation cost and RM 5 million for the rework due to the change in design.