ADDIS ABABA UNIVERSITY ADDIS ABABA INSTITUTE OF TECHNOLOGY S C H O O L O F G R A D U A T E S T U D I E S ASSESSING THE IMPACT OF VARIATION ORDERS ON PUBLIC BUILDING PROJECTS IN ADDIS ABABA BY ANDUALEM ENDRIS YADETA A Thesis Submitted to the School of Graduate Studies of Addis Ababa University, Addis Ababa Institute of Technology in partial fulfillment of the requirements for the Degree of Master of Science in Civil Engineering (Construction Technology and Management) OCTOBER 2014
114
Embed
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa-By Andualem
This document is posted to help you gain knowledge. Please leave a comment to let me know what you think about it! Share it to your friends and learn new things together.
Transcript
ADDIS ABABA UNIVERSITY ADDIS ABABA INSTITUTE OF TECHNOLOGY S C H O O L O F G R A D U A T E S T U D I E S
ASSESSING THE IMPACT OF VARIATION ORDERS
ON PUBLIC BUILDING PROJECTS IN ADDIS ABABA
BY
ANDUALEM ENDRIS YADETA
A Thesis Submitted to the School of Graduate Studies of
Addis Ababa University, Addis Ababa Institute of Technology in partial
fulfillment of the requirements for the Degree of
Master of Science in Civil Engineering
(Construction Technology and Management)
OCTOBER 2014
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University ii Addis Ababa Institute of Technology
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University iii Addis Ababa Institute of Technology
DECLARATION
“I declare that this research report entitled “Assessing the Impact of
Variation Orders on Public Building Projects in Addis Ababa” is the result
of my own work, it contains no materials previously published or written by
another person except where due reference is made. This report has not been
previously submitted for any degree at other higher education institutions.”
Signature: :
Name of candidate: Andualem Endris Yadeta
Date : 03/11/2014
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University iv Addis Ababa Institute of Technology
DEDICATION
I dedicate this work for my teachers who nurtured me in my school life.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University v Addis Ababa Institute of Technology
ACKNOWLEDGEMENTS
First of all may thankful honor return to God who sustained me during my research project! I
accomplished everything through Him who strengthens me.
I would like to convey my truthful gratitude to my Advisor Associate Professor Wubishet
Jekale Mengesha (Dr.-Ing) for his invaluable guidance and motivation throughout this
research. I am truly lucky to have him as my advisor and I thank him for inspiring me on my
research I had never dreamt of which afterwards became part of my life.
I acknowledge Addis Ababa Institute of Technology, all Civil and Environmental
Engineering department staffs that have been always supportive for the success of my
research project from the start to the final submission.
Many thanks go to Addis Ababa Housing Development and Construction Bureau for all
Government Construction Agency staffs especially to Ato Dereje Megersa, Ato Adhanom
G/Tsadik and Ms Hirut Ayalew for their support throughout my journey giving me all
supportive documents for my research without saving their golden time. I would also like to
thank all organizations and individuals who contributed directly or indirectly by providing the
necessary materials and support for realization of this research.
I am grateful to my employer, Madawalabu University for the support by way of a study
scholarship. I would like to express my gratitude to my colleagues and friends who
contributed to and supported my research project.
Finally, my parents have always been a real support to achieve my educational goals. I would
like to express my deepest gratitude to them for all their patience, love and support.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University vi Addis Ababa Institute of Technology
TABLE OF CONTENTS
Content Page
DECLARATION ................................................................................................................ iii DEDICATION ................................................................................................................... iv ACKNOWLEDGEMENTS ................................................................................................ v LIST OF TABLES ........................................................................................................... viii LIST OF FIGURES ........................................................................................................... ix ABSTRACT........................................................................................................................ xi
1. INTRODUCTION ........................................................................................................... 1 1.1 Background of the Study ......................................................................................... 1 1.2 Statement of the Problem ........................................................................................ 2 1.3 Aim and Objectives of the Study ............................................................................. 3 1.4 Scope of the Study .................................................................................................. 3 1.5 Significance of the Study ........................................................................................ 4 1.6 Structure of the Research ........................................................................................ 4
2. LITERATURE REVIEW ............................................................................................... 6 2.1 Introduction ............................................................................................................ 6 2.2 Definition of Variation ............................................................................................ 6 2.3 Nature and Types of Variation Orders ..................................................................... 8
2.3.1 Nature of Variation Orders ............................................................................... 8 2.3.2 Types of Variation Orders .............................................................................. 10
2.4 Contractual Provisions Relative to Variation Orders .............................................. 11 2.4.1 General Conditions of Contract for Procurement of Works (PPA, 2006) ........ 11 2.4.2 Standard Condition of Contract for Civil Works Project (MUDC, 1994) ........ 13 2.4.3 General Conditions of Contract for Civil Works (UNDP, 2000) ..................... 13 2.4.4 Conditions of Contract for Construction (FIDIC, 1999) .................................. 14
2.6 Management of Variation Orders .......................................................................... 19 2.6.1 Start Up ......................................................................................................... 20 2.6.2 Identify and Evaluate ..................................................................................... 20 2.6.3 Approval ........................................................................................................ 20 2.6.4 Implement and Review .................................................................................. 20
2.7 Causes of Variation Orders ................................................................................... 22 2.8 Impact of Variation Orders on Building Projects ................................................... 25 2.9 Recommended Strategies to Minimize Variation Orders ....................................... 30 2.10 Variable Identification .......................................................................................... 32
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University vii Addis Ababa Institute of Technology
3. RESEARCH METHODOLOGY ................................................................................. 35 3.1 Introduction .......................................................................................................... 35 3.2 The Study Approach ............................................................................................. 35 3.3 Population and Sampling....................................................................................... 36 3.4 Data Collection ..................................................................................................... 36
3.4.1 Desk Study .................................................................................................... 36 3.4.2 Survey ........................................................................................................... 36
3.5 Method of Data Analysis ....................................................................................... 38
4. DATA ANALYSIS AND DISCUSSION....................................................................... 40 4.1 Introduction .......................................................................................................... 40 4.2 Analysis of Data from the Desk Study ................................................................... 40
4.2.1 Project A ........................................................................................................ 41 4.2.2 Project B ........................................................................................................ 41 4.2.3 Project C ........................................................................................................ 41 4.2.4 Project D ........................................................................................................ 41 4.2.5 Project E ........................................................................................................ 42 4.2.6 Findings from the Desk Study ........................................................................ 43
4.3 Interviews ............................................................................................................. 44 4.3.1 Analysis of Data from the Interview ............................................................... 44 4.3.2 Findings from the Interview ........................................................................... 46
4.4 Analysis of Data from the Questionnaires ............................................................. 46 4.4.1 Rate of Response ........................................................................................... 46 4.4.2 Respondents’ Background .............................................................................. 47 4.4.3 Respondents’ Experience ............................................................................... 48 4.4.4 Findings from the Questionnaires ................................................................... 48
4.5 Discussion of Findings .......................................................................................... 63 4.5.1 Causes of Variation Orders in Public Building Projects .................................. 63 4.5.2 Impact of Variation Orders on Public Building Projects ................................. 64 4.5.3 Recommended Strategies to Minimize Variation Orders ................................ 65
5. CONCLUSION AND RECOMMENDATIONS .......................................................... 67 5.1 Conclusion ............................................................................................................ 67
5.1.1 Causes of variation orders on public building projects in Addis Ababa ........... 67 5.2.2 Impact of variation orders on public building projects in Addis Ababa ........... 68 5.3.3 Recommended strategies to minimize variation orders ................................... 69
Table 4.8 Frequency of causes of variation orders from the clients group ............................ 49
Table 4.9 Frequency of causes of variation orders from the consultants group ..................... 50
Table 4.10 Frequency of causes of variation orders from the contractors group ................... 51
Table 4.11 Summary of correlation test on the ranking of causes of variation orders ........... 52
Table 4.12 Overall frequency of causes of variation orders .................................................. 53
Table 4.13 Frequency of impact of variation orders from the clients group .......................... 54
Table 4.14 Frequency of impact of variation orders from the consultants group................... 55
Table 4.15 Frequency of impact of variation orders from the contractors group ................... 56
Table 4.16 Summary of correlation test on the ranking of impact of variation orders ........... 56
Table 4.17 Overall frequency of impact of variation orders ................................................. 57
Table 4.18 Frequency of recommended strategies from the clients group ............................ 58
Table 4.19 Frequency of recommended strategies from the consultants group ..................... 59
Table 4.20 Frequency of recommended strategies from the contractors group ..................... 60
Table 4.21 Summary of correlation test on the ranking of recommended strategies ............. 60
Table 4.22 Overall frequency of recommended strategies .................................................... 61
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University ix Addis Ababa Institute of Technology
LIST OF FIGURES
Figure Page
Figure 1.1 Structure of the Research ...................................................................................... 5
Figure 2.1 Variation management process ........................................................................... 21
Figure 3.1 Five ordinal measures of agreement by Likert Scale ........................................... 37
Figure 4.1 Position of respondents ....................................................................................... 47
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University x Addis Ababa Institute of Technology
LIST OF ABBREVIATIONS
AAHDCB Addis Ababa Housing Development and Construction Bureau
BoQ Bill of Quantities
CII Construction Industry Institute
DB Design-Build
DBB Design-Bid-Build
FIDIC Federation Internationale des Ingenieurs-Conseils: a French acronym
interpreted in English as International Federation of Consulting Engineers
IPD Integrated Project Delivery
JBCC The Joint Building Contracts Committee
MUDC Ministry of Urban Development and Construction
PPA Public Procurement Agency
UNDP United Nations Development Program
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University xi Addis Ababa Institute of Technology
ABSTRACT
Variation is inevitable in construction projects due to the complex nature of the construction
industry. It is common in all types of construction projects and it determines the time limits
and anticipated budget of the projects. Variation order is observed as one of the most
frequently occurring issues in construction projects in Ethiopia. Like other regions of the
country, construction projects in Addis Ababa are suffering from variation orders. These
variations are known to impact various aspects of the projects. This study assessed the impact
of variation orders on public building projects in Addis Ababa to reduce them. The
objectives of the study were firstly to determine the causes of variation orders; secondly to
identify the impacts of variation orders; and lastly to recommend strategies to minimize
variation orders. Through a comprehensive study of literature review, resulted in
identification of 38 common causes of variation orders, 15 impacts of variation orders and 15
recommended strategies to minimize variation orders and these variables were mapped in
frequency table. A desk study, interview and questionnaire survey were carried out to identify
the causes of variation orders, their impacts on public building projects and to seek
recommendations to reduce them. The desk study conducted on five selected projects and the
causes of variation orders and their impacts on the projects were identified. Interviews were
made with selected experienced public building project participants for expert opinion. The
questionnaire responses were analyzed using the relative index method. A triangulation
method on the desk study, survey and the literatures was done to improve the validity of the
findings from the study. The results indicated that design changes, incomplete contract
documents, and impediment in prompt decision making process were the most causes of
variation orders. The results also showed that completion schedule delay, increase in project
cost, and additional payments for contractor were the most impact of variation orders. The
findings also suggested the most recommended strategies to minimize variation orders. These
strategies were to produce a concluding design and contract document, to complete drawings
at tender stage, and to supervise the works with experienced and dedicated supervisor to
minimize variation orders on public building projects. The study concluded based on the
findings of the research and recommendations for further studies were forwarded to minimize
variation orders.
Key words: Variation order, cause, impact, public projects, Addis Ababa.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 1 Addis Ababa Institute of Technology
CHAPTER ONE
INTRODUCTION
1.1 Background of the Study
The construction industry in Ethiopia has been on fast growing mode which plays an
instrumental role in the country development. Addis Ababa in the last ten years experienced a
huge volume of work in the field of constructions. This resulted in a very rapid growth and
transformation during this period. The city has generated many facilities and government
buildings opportunities. The growth of the city is being accelerated due to the construction of
private and government owned buildings. Large and complex government buildings have
been built, attracting domestic contractors and construction companies from all over the
world. This situation coupled with inexperienced consultants and the client has led to
inadequate design resulting in many changes to plans, specifications, and contract terms
which resulted in variation orders.
With the announcement of the government five years Growth and Transformation Plan (GTP)
in 2010, the construction industry is said to be the most beneficial sector as there lots of
projects being rolled out by the government and to be carried out in the five years plan. The
implementation of government projects are expected to provide further thrust to the
construction sector in the country. Therefore, it is important to ensure these projects are being
implemented successfully without any major problems while minimizing the adverse impacts
of variation orders on the project outcome.
As the number of variation orders on a project increases, so does the possibility of
misunderstanding among the contracting parties. Such a misunderstanding may occur
because one or more of the parties lacks full knowledge of the variation order process itself,
the costs involved in implementing changes, or the delays, conflicts, and interruption of the
construction sequence and schedule which can adversely impact project coordination.
Previous studies on variation orders are mainly focused on the sources and causes of variation
orders. The sources of variations include the performance of construction parties, resources
availability, environmental conditions, involvement of other parties, and contractual relation.
Many times delays, cost overrun and quality defects of a construction can be attributed to
variation at various stages of the project (Burati et al., 1992). Variations and conflicts in
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 2 Addis Ababa Institute of Technology
construction projects, at work, and even in our daily lives are very common (Arain and Low,
2006).
Variation orders involved alteration, addition, omission, and substitution in terms of quality,
quantity and schedule of work (Adnan et al., 2010). Any addition, deletion, or any other
revision to project goals and scope of work are considered to be variation, whether they
increase or decrease the project cost or schedule (Ibbs et al., 2001). The work of Sun and
Meng (2008) mentioned that a variation in construction projects refers to an alteration to
design, building works, project programs or project aspects caused by modifications of
preexisting conditions, assumptions, or requirements. Variation orders have an impact on
overall project performance (Ruben, 2008). This is because variations can cause substantial
adjustment to the contract duration, total direct and indirect cost, or both.
In most cities of the country like Addis Ababa where new infrastructure and buildings are
being built, the occurrence of variation orders on public projects seems usual. Most public
building projects in Addis Ababa were delayed with certain amount of variation orders
increasing from the original value of the contract sum. According to the team leader of Addis
Ababa Housing Development and Construction Bureau, Supervision and Follow-up
department, variation is ordered for most of the projects. The projects were delayed and the
cost of the projects increased. The focus of this study would be on public building projects
being built in Addis Ababa from July 2010G.C to the end of June 2012G.C. Due to general
background of the problem in the construction industry and the specific problem within the
public buildings, there is a cause for a study to be made on assessment of the impact of
variation orders on public building projects in Addis Ababa.
1.2 Statement of the Problem
Nowadays, variation orders have become a common problem in public building projects in
Addis Ababa. Variation orders are issued to correct or modify the original scope of work
because changes during construction of projects are unavoidable. The major causes of delay,
disputes and sometimes generate significant cost and environmental impacts are variation
orders issued during construction of projects. Yet, no unique method is available for
minimizing variation orders effectively. However, their impact can be minimized with an
appropriate study about the causes. Variation orders on public building projects have the
potential to impact public building projects, and the identification of their causes might lead
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 3 Addis Ababa Institute of Technology
to their reduction, possible elimination and subsequent improvement in overall performance
of public building projects.
1.3 Aim and Objectives of the Study
Based on the problem statement above, the aim of this study is to assess the impact of
variation orders on public building projects in Addis Ababa in order to take remedial
measures to minimize them.
The objectives of the study are:
To determine the causes of variation orders;
To identify the impacts of variation orders; and
To recommend strategies to minimize variation orders.
The following research questions pertain to offices consisting of public building project
management teams in Addis Ababa. The overall purpose of this research is to minimize the
impact of variation orders on public building projects, thereby increasing the effectiveness in
both a project and a government. Thus formulating and answering the following research
questions could define the overall purpose:
What are the causes of variation orders?
What are the impacts of variation orders?
How can we minimize variation orders?
1.4 Scope of the Study
There are many projects which are currently under construction in Ethiopia. In order to
achieve the stated objectives of the study, the scope would be too large to tackle. Therefore,
the study will be limited to Addis Ababa city where many public building projects are under
construction. This scope limitation is done due to limitation of budget and schedule of the
research. Data to be used will include only G+3 and above with and without basement of
public building projects which are under construction those issued from the commencement
of work from July 2010 to the end of June 2012 G.C and more than 60% completed projects.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 4 Addis Ababa Institute of Technology
1.5 Significance of the Study
Since variation orders can have numerous negative impacts to projects cost and schedule, it
will be important to identify the major causes those contribute to variation orders and to study
the impacts of variation orders and possible strategies to minimize them during the
implementation of public building projects. The study will be supportive for public building
construction stakeholders in general and for Addis Ababa city government public building
construction stakeholders specifically to take remedial measures to reduce the occurrence of
the problem. The study will also be helpful for the government in general and most technical
departments such as Housing Development and Construction Bureau (HDCB) in assessing
and taking remedial measures for reducing the impact of variation orders.
1.6 Structure of the Research
Research writing is the final step of the study and it contains five main chapters. These are
the introduction, literature review, the research methodology, data analysis and discussions,
and conclusion and recommendations.
Chapter One: Introduction: This chapter comprised the background of the study, problem
statement, aim and objectives, significance and limitations of the study, and structure of the
research.
Chapter Two: Literature Review: The literature review started with literature exploration
of the electronic and hard copy media in answering the research objectives. The causes and
impact of variation orders as well as strategies to minimize variation orders on building
projects were discussed.
Chapter Three: Research Methodology: This chapter discussed the tools and methods used
for data collection.
Chapter Four: Data Analysis and Discussions: This chapter constituted the analysis of data
gathered with the research instruments. It analyzed data from the desk studies, questionnaire
and the interview.
Chapter Five: Conclusion and Recommendations: This is the final chapter of the research
in which conclusions and recommendations were drawn based upon the analysis data, linking
them to the problem statement and objectives of the study.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 5 Addis Ababa Institute of Technology
Generally, the research was written following a certain structure. Though step order may vary
depending on the subject matter and researcher, the steps outlined in Figure 1.1 below were
followed in this study;
Figure 1.1: Structure of the research
Literature Review
Data Collection
Data Analysis
Conclusion and
Recommendations
Literatures search using electronic and hard copy of books and journals
Identify the variables for the three objectives of the study
Desk Study: Archival records such as monthly reports and payment certificates on selected projects for causes and impacts of variation orders
Survey:-Interview- Interview with selected public building participants -Questionnaire- distribution of questionnaire to the relevant parties
Evaluate the main causes of V.O Evaluate the main impacts of V.O Evaluate recommended strategies to
minimize V.O
Conclude the findings Recommendation for improvements
and suggestions for further research
Introduction Identify the problem Establish objectives Define scope of the study Explain significance of the study
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 6 Addis Ababa Institute of Technology
CHAPTER TWO
LITERATURE REVIEW
2.1 Introduction
Construction project is a mission, undertaken to create a unique facility, product or service
within the specified scope, quality, time and cost. In practice, however, some construction
projects encounter variation, delay on completion time or poor workmanship upon
completion.
The one thing certain on any project is that there will be variations occurring along the way
sometimes even before the signing of the contract. Variations are inevitable in any
construction projects (Ibbs et al., 2001). Nothing is more constant than variation during the
course of a construction project. Despite the best efforts of all concerned during the planning,
implementation and administration of the contract, variation will almost certainly occur. The
variations and variation orders can be detrimental in any project, if not considered
collectively by all participants (Arain and Low, 2005). The most frequent type of variation
met in building projects are variations to the original scope of work or those that arise from
unexpected conditions in the field. Even two buildings of same design, that is very similar,
have differences caused by the terrain, existing utilities, or other factors such as subsurface
conditions. Basically variation orders are acceptable as part of the contract administration
process.
This chapter reviews literatures related to variation orders; including: definition of variation
order; nature and type of variation orders; contractual provisions relative to variation orders;
variation orders and project delivery systems, management of variation orders, causes and
impacts of variation orders; and recommended strategies to minimize variation orders on
public building projects.
2.2 Definition of Variation
There is no single definition of what constitutes a variation. The term ‘variation’ as described
and/or defined by various standard forms of contract differs from one to another but in
principle the definition and/or meaning is more or less similar. Usually, any standard form of
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 7 Addis Ababa Institute of Technology
building contract will contain a definition of a variation in terms of specific actions and
activities.
The building contract dictionary defined variations as alterations, additions or omissions in
work, materials, working hours, work space, etc.
As defined in PPA (2006), “variation” is an instruction given by the engineer, which varies the
works.
According to FIDIC (1999), “variation” means any change to the works, which is instructed
or approved as a variation.
Hayati (2006) described that each standard form of building contract has its own definition
but clearly ‘variation’, in generic sense, refers to any alteration to the basis upon which the
contract was let. This means the term embraces not only changes to the work or matters
pertaining to the work in accordance with the provisions of contract, but also changes to the
contract conditions themselves.
According to Hayati (2006) variation can be taken to be any, a combination of any or all of
the following:
i. Variation in building projects may mean ‘the alteration or modification of the design,
quality or quantity of the works, as shown upon the contract drawings and described
by or referred to in the contract bills, and includes the addition, omission or
substitution of any work, the alteration of the kind or standard of any of the materials
as goods to be used in the works, and the removal from the site of any work materials
or goods executed or brought thereon by the contractor for the purposes of the works
other than work or material or goods which are not in accordance with the contract’.
ii. Variations in building projects with instructions concerning the nature of the works
which are not specifically termed as variation in the contract documents.
iii. Variation of contract in law, i.e. if both parties alter a contract document by
agreement after execution of the original contract this is a variation of the contract
terms or conditions.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 8 Addis Ababa Institute of Technology
iv. Variation of price clause which enables the contract sum to be adjusted for rises and
falls in the cost of labour or materials.
Hibberd (1986) defined variation as any changes in the quality or quantity of the works as
mentioned or spelled out in a contract document. Bin-Ali (2008) defined variation orders as
any deviation i.e., alteration, addition or omission, from the contract with regard to contract
drawings, specifications, and/or bills of quantities. Variation order was also defined as the
alteration or modification of the design, quality of works, as agreed upon the contract
drawings, bill of quantities, and/or specifications (Bin-Ali, 2008).
Popescu (1995) indicated that a contract variation order is when a change is made in the
original contract that will affect the scope of work. Variation order is authorized by the owner
and is often initiated by the contractor. Schexnayder et al. (2004) explained that the variation
order directives issued by the owner to change the contract by adding or subtracting features
within the scope of the work. Variations that are outside the scope of work require a
supplementary agreement. Variation orders change the details or conditions of the work and
they are used to add “extra” or delete work.
In general, the term ‘Variation’ usually means a change, modification, alteration, revision or
amendment to the original intent of the contract and/or its works. A variation order is the
formal document that is used to modify the original contractual agreement and becomes part
of project’s documents (Fisk, 1997). Furthermore, a variation order is a written order issued
to the contractor after the contractual agreement by the owner, which authorize a change in
the work or an adjustment in the contract sum or even the contract time.
2.3 Nature and Types of Variation Orders
2.3.1 Nature of Variation Orders
The research team Ming et al. (2004) reported that project variations can be classified as
“anticipated variations” and “emergent variation”. Anticipated variations are planned in
advance and occur as intended. On the other hand, emergent variation arise spontaneously
and are not originally anticipated or intended. Another way to view project variation is
through its necessity. In this way, project variation can be classified as “elective variations”
and “required variations”. According to Ming et al. (2004) an elective variation is where one
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 9 Addis Ababa Institute of Technology
may choose whether or not to implement; and a required variation is where there is no option
but to make the variation.
No matter how carefully a project is planned and scheduled, it is almost certain that there will
be variations before the project is completed. As sited in the works of Ruben (2008), the type
of variation orders can be determined by referring to both the reasons for their occurrence and
subsequent effects. (Arain & Pheng, 2005) distinguished two types of variation orders,
namely: beneficial and detrimental variation orders.
2.3.1.1 Beneficial variation orders
As Arain & Pheng (2005) described, a beneficial variation order is one issued to improve the
quality standard, reduce cost, schedule, or degree of difficulty in a project. This type of
variation order eliminates unnecessary costs from a project as a result; it optimizes the client's
benefits against the resource input by eliminating unnecessary costs. This means beneficial
variation orders initiated for value analysis purposes to realize a balance between the cost,
functionality and durability aspects of a project to the satisfaction of clients. Value analysis is
an organized approach to the identification and elimination of unnecessary costs which are
defined as costs which provide neither use, nor life, nor quality, nor appearance, nor customer
features (Kelly & Male, 2002). Value analysis describes a value study of a project that is
already built or designed and analyses the product to see if it can be improved (Zimmerman
& Hart, 1982). Therefore, a variation order is beneficial if it is initiated to enhance the client's
value. Among others, the client's value system elements include time, capital cost, operating
cost, environment, exchange or resale, aesthetic/esteem and fitness for the purpose (Kelly &
Duerk, 2002). A beneficial variation order, therefore, seeks to optimize the client's benefits
against the resource input by eliminating unnecessary costs. These benefits are understood to
be the satisfaction of perceived needs for public building projects that include social,
economic and commercial aspects.
Additionally, a beneficial variation is initiated in the spirit of adding value to the project.
However, it should be noted that regardless of how beneficial a variation order might be non
value-adding costs are likely to accrue as a result (Ruben, 2008). For example a variation
order to solve the discrepancies between contract documents involves the abortion of works
that have already been executed. Cost for aborted works should not have been incurred if
discrepancies were not found between contract documents.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 10 Addis Ababa Institute of Technology
2.3.1.2 Detrimental variation orders
According to Arain & Pheng (2005), a detrimental variation order is one that negatively
impacts the client's value or project performance. For example a client who is experiencing
financial problems may require the substitution of quality standard expensive materials to
substandard cheap materials. Arguably, a detrimental variation order compromises the client's
value system. For example, in marine construction, steel window frames result in steel
oxidation if selected instead of timber or aluminum frames.
2.3.2 Types of Variation Orders
Variations in construction projects are very common and likely to occur from different
sources, by various causes, at any stage of a project, and may have considerable negative
impacts on items such as costs and schedule delays. A critical variation may cause
consecutive delays in project schedule, re-estimation of work statement, and extra demands
of equipment, materials, labor, and overtime. Variations, if not resolved through a formalized
variation management process, can become the major source of contract disputes, which is a
severe risk contributing to project failure.
Classifications of variations in general terms apply to changes in construction domain.
Motawa et al. (2007) summarized variations as Table 2.1 below:
Table 2.1: Types of variation (Motawa et al., 2007)
Bases of variation Types of Variation
Time Anticipated or Emergent, Proactive or Reactive, or
Pre-fixity or Post-fixity
Need Elective or Required, Discretionary or Nondiscretionary,
or Preferential or Regulatory
Effect Beneficial, Neutral or Disruptive
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 11 Addis Ababa Institute of Technology
2.4 Contractual Provisions Relative to Variation Orders
Most standard forms of contract include a clause under which the employer or his
representative is able to issue an instruction to the contractor to vary the works which are
described in the contract. A change in shape of the scheme, the introduction of different
materials, revised timing and sequence are all usually provided for by the variations clause. It
will also usually include a mechanism for evaluating the financial effect of the variation and
there is normally provision for adjusting the completion date. In the absence of such a clause
the employer could be in a difficulty should a variation to the works be required. The
contractor could either refuse to carry out the work or undertake the work or insist upon
payment on a quantum merit or fair valuation basis. Calculation of the price for the extra
work applying this method could involve payment in excess of the contract rates.
Among the different conditions of contract, the Federation Internationale Des Ingenieurs
Conseils (FIDIC), Ministry of Urban Development and Construction (MUDC), and Public
Procurement (PPA) are widely used in Ethiopian construction industry. These contract
conditions clearly define the duties and responsibilities of the parties involved in the contract
and it describes the guidelines for contract administration, they consequentially alter variation
of construction works unless and otherwise they are deleted or replaced by other words or
sentences in the specific conditions of contract for a project.
2.4.1 General Conditions of Contract for Procurement of Works (PPA, 2006)
Even though contract conditions include the usual variations clause there may be
circumstances which could lead to additions or changes introduced by the employer which
falls outside the variations clause. Variation related clauses as described under clause 38, 39
and 40 of Public Procurement Agency (PPA, 2006) concerning variations and payment of
variations are as follows:
Clause 38.1: If the final quantity of the work done differs from the quantity in the bill
of quantities for the particular item by more than 25 percent, provided the change
exceeds 5 percent of the initial contract price, the engineer shall adjust the rate to allow
for the change. This clause is applied for admeasurements contract.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 12 Addis Ababa Institute of Technology
Clause 39.1: All variations shall be included in updated programs (or in the case of
lump sum contracts in updated programs and activity schedules) produced by the
contractor.
Clause 40.1: For both admeasurements and lump sum contracts, the contractor shall
provide the engineer with a quotation for carrying out the variation when requested to
do so by the engineer. The engineer shall assess the quotation, which shall be given
within seven days of the request or within any longer period stated by the engineer and
before the variation is ordered.
Clause 40.2: For admeasurements contracts only, if the work in the variation
corresponds with an item description in the bill of quantities and if, in the opinion of the
engineer, the quantity of work above the limit stated in sub-clause 38.1 or the timing of
its execution do not cause the cost per unit of quantity to change, the rate in the bill of
quantities shall be used to calculate the value of the variation. If the cost per unit of
quantity changes, or if the nature or timing of the work in the variation does not
correspond with items in the bill of quantities, the quotation by the contractor shall be in
the form of new rates for the relevant items of work.
Clause 40.3: For both admeasurements and lump sum contracts, if the contractor’s
quotation is unreasonable, the engineer may order the variation and make a change to
the contract price, which shall be based on the engineer’s own forecast of the effects of
the variation on the contractor’s costs.
Clause 40.4: For both admeasurements and lump sum contracts, if the engineer decides
that the urgency of varying the work would prevent a quotation being given and
considered without delaying the work, no quotation shall be given and the variation
shall be treated as a compensation event.
Clause 40.5: For both admeasurements and lump sum contracts, the contractor shall not
be entitled to additional payment for costs that could have been avoided by giving early
warning.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 13 Addis Ababa Institute of Technology
2.4.2 Standard Condition of Contract for Civil Works Project (MUDC, 1994)
According to Ministry of Urban Development and Construction (MUDC, 1994) conditions of
contracts for construction of civil works project, variation related clauses are read as follows:
Clause 51, Variations: The engineer shall make any variation of the form, quality or
quantity of the works or any part thereof that may, in his opinion, be necessary and for
that purpose, or if for any other reason it shall, in his opinion be desirable, he shall
have power to order the contractor to do and the contractor shall do any of the
following:
(a) Increase or decrease the quantity of any work included in the contract,
(b) Omit any such work,
(c) Change the character or quality or kind of any such work,
(d) Change the levels, lines, position and dimensions of any part of the works, and
(e) Execute additional work of any kind necessary for the completion of the works
and no such variation shall in any way vitiate or invalidate the contract, but the
value, if any, of all such variations shall be taken into account in ascertaining
the amount of the counteract price.
Clause 52, Valuation of variations: All extra or additional work done or work omitted
by order of the engineer shall be valued at the rates and prices set out in the contract if,
in the opinion of the engineer, the same shall be applicable. If the contract does not
contain any rates or prices applicable to the extra or additional work then suitable rates
or prices shall be agreed upon between the engineer and the contractor. In the event of
disagreement the engineer shall fix such rates or prices as shall, in his opinion, are
reasonable and proper.
2.4.3 General Conditions of Contract for Civil Works (UNDP, 2000)
A construction contract condition which developed for United Nations Development Program
(UNDP, 2000) projects described variation in the following clauses:
Clause 15a: The engineer may instruct the contractor, with the approval of the
employer and by means of change orders, all variations in quantity or quality of the
works, in whole or in part, that are deemed necessary by the engineer.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 14 Addis Ababa Institute of Technology
Clause 48.1: The engineer may within his powers introduce any variations to the form,
type or quality of the works or any part thereof which he considers necessary and for
that purpose or if for any other reasons it shall, in his opinion be desirable, he shall
have power to order the contractor to do and the contractor shall do any of the
following:
(a) increase or decrease the quantity of any work under the contract;
(b) omit any such work;
(c) change the character or quality or kind of any such work;
(d) change the levels, lines, positions and dimensions of any part of the works;
(e) execute additional work of any kind necessary for the completion of the
works, and no such variation shall in any way vitiate or invalidate the contract.
For an increase cost of contract or altering the works due to variations according to this
condition is stipulated under clause 48.2 as follows.
Clause 48.2: The engineer shall, however, obtain the written approval of the employer
before giving any order for any variations which may result in an increase of the
contract price or in an essential alteration of the quantity, quality or character of the
works.
Clause 48.3: No variations shall be made by the contractor without an order in writing
from the engineer. Variations requiring the written approval of the employer under
clause 48.2 shall be made by the contractor only upon written order from the engineer
accompanied by a copy of the employer's approval. It is provided that, subject to the
provisions of the contract, no order in writing shall be required for any increase or
decrease in the quantity of any work where such increase or decrease is not the result
of an order given under this clause but is the result of the quantities exceeding or being
less than those stated in the bill of quantities.
2.4.4 Conditions of Contract for Construction (FIDIC, 1999)
The FIDIC (1999) under clause 3.3, it stipulates that the engineer may issue to the contractor
instructions and additional or modified drawings which may be necessary for the execution of
the works and the remedying of any defects, all in accordance with the contract. But, not all
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 15 Addis Ababa Institute of Technology
instructions vary the contractual arrangements or the way the works are being undertaken. As
stated under clause 13.1 of FIDIC (1999), variations may be initiated by the engineer at any
time prior to issuing the taking-over certificate for the works, either by an instruction or by a
request for the contractor to submit a proposal.
The contractor shall execute and be bound by each variation, unless the contractor promptly
gives notice to the engineer stating (with supporting particulars) that the contractor cannot
readily obtain the goods required for the variation. Upon receiving this notice, the Engineer
shall cancel, confirm or vary the instruction.
As FIDIC (1999) stipulates, each variation may include:
(a) changes to the quantities of any item of work included in the contract (however,
such changes do not necessarily constitute a variation).
(b) changes to the quality and other characteristics of any item of works.
(c) changes to the levels, positions and/or dimensions of any part of the works.
(d) omission of any work unless it is to be carried out by others.
(e) any additional work, plant, materials or services necessary for the permanent
works, including any associated tests on completion, boreholes and other testing
and exploratory work. or
(f) changes to the sequence or timing of the execution of the works.
The FIDIC (1999), under clause 13.2 states that the contractor may, at any time, submit to the
engineer a written proposal which (in the contractor’s opinion) will, if adopted, (i) accelerate
completion, (ii) reduce the cost to the employer of executing, maintaining or operating the
works, (iii) improve the efficiency or value to the employer of the completed works, or (iv)
otherwise be of benefit to the employer.
Under clause 13.3 of FIDIC (1999), it stipulates that if the engineer requests a proposal, prior
to instructing a variation, the contractor shall respond in writing as soon as practicable, either
by giving reasons why he cannot comply (if this is the case) or by submitting:
(a) a description of the proposed work to be performed and a program for its execution
(b) the contractor’s proposal for any necessary modifications to the program according
to the program stated and to the time for completion, and
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 16 Addis Ababa Institute of Technology
(c) the contractor’s proposal for evaluation of the variation.
The engineer shall, as soon as practicable after receiving such proposal, respond with
approval, disapproval or comments. The contractor shall not delay any work whilst awaiting
a response. Each instruction to execute a variation, with any requirements for the recording of
costs, shall be issued by the engineer to the contractor, who shall acknowledge receipt.
Each instruction to execute a variation, with any requirements for the recording of costs, shall
be issued by the engineer to the contractor, who shall acknowledge receipt. Each variation
shall be evaluated in accordance with clause 12 [Measurement and Evaluation: It states that
the works shall be measured, and valued for payment], unless the engineer instructs or
approves otherwise in accordance with this clause.
Even though the above contract conditions include the usual variations clause, there may be
circumstances which could lead to additions or changes introduced by the employer which
falls outside the variations clause. Contractors who find themselves with unattractive contract
prices would find it to their advantage to be able to argue that a change introduced by the
employer fell outside the variations clause thus leaving the way open to argue that payment
for the change should be on a quantum merit or fair valuation basis. In the above different
contractual provisions, all the contracts have stipulated the various methods by which the
contractor will be reimbursed. The contracts have a specific procedure covering the process
of handling variations to the work.
2.5 Variation Orders and Project Delivery Systems
A project delivery system is a system designed to achieve the satisfactory completion of a
construction project from conception to occupancy. A project delivery method may employ
any one or more contracting formats to achieve the delivery.
Every owner responsible for the implementation of a construction project must make an early
and important decision regarding the method by which the project will be designed and
constructed (Odabasi et al., 2003). Because of financial, organizational and time constraints,
various project delivery methods have evolved to fit particular project and owner needs.
Methods that have gained in popularity include Design-Bid-Build (DBB), Design-Build
(DB), and the latest, Integrated Project Delivery (IPD). Proponents of particular alternative
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 17 Addis Ababa Institute of Technology
methods advocate or promise improvements over the traditional system in terms of project
schedule and cost control, and the number of disputes (Levy, 2006). The Integrated Project
Delivery method, although to date only used on a negligible number of projects, is included
here due to interest in understanding the concept.
2.5.1 Design-Bid-Build (DBB)
The Design-Bid-Build (DBB) approach is the most accepted traditional project delivery
method today, especially for public projects in Addis Ababa. In DBB, the project is separated
into a design phase and construction phase. With two well-defined phases, construction will
start once the design is completed, while the drawings become the basis for the bidding
documents. Because the owner is more certain about the finished product, usually a lump sum
contract is implemented in a DBB project (Odabasi et al., 2003).
The DBB system remains the most frequently used delivery method for construction projects
(Levy, 2006). Using this method, the owner engages a designer to prepare the design of the
project, including construction drawings, and specifications. Once completed, the bid
document, including the design and bidder’s information packet, is presented to interested
contractors who prepare and submit their bids for the work. The owner will select a
contractor, usually based on the lowest responsive and responsible bid (for most public
works), or some hybrid of price and technical merit. The selected general contractor will then
execute contracts with subcontractors to construct various specialty items. The contractor is
responsible for constructing the facility in accordance with the contract documents. The
designer typically maintains limited oversight of the work and responds to questions about
the design on behalf of the owner (Levy, 2006).
2.5.2 Design-Build (DB)
Design-Build (DB) is the oldest approach that is regarded as an alternative project delivery
method. During ancient times in Mesopotamia and Egypt, the master builder was responsible
for the design and construction of the entire project. This continued to be the most commonly
used project delivery method until the late 19th century, when advances in science and
technology allowed the fields of architecture and engineering to become two different
professions (Songer and Molenaar, 1996). The contractor usually has the task of assembling a
group of designers and constructors to perform the job for this type of delivery method.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 18 Addis Ababa Institute of Technology
According to Levy (2006), the owner contracts with a DB team, which can be a joint venture
of a contractor and a designer, a contractor with a designer as a sub-consultant, a designer-led
team with a contractor as a subcontracted entity, or a single firm capable of performing both
design and construction. Since contractors are most comfortable in the role of risking
corporate capital in performing projects, they usually are the lead members of this sort of
team. One variation of the typical DB team structure, known as fee-paid developer, involves
the owner engaging a developer, which then selects its own designer and contractor partners.
However formulated, the DB team performs the complete design of the facility, usually based
on a preliminary scope or design presented by the owner.
At some point early in the process, through a prescribed process, the DB team will establish a
fixed price to complete the design and construction of the facility. Once underway, the DB
team is then responsible for construction of the project, and for all coordination between
design and construction.
2.5.3 Integrated Project Delivery (IPD)
Integrated Project Delivery (IPD) contracts are a relatively new to our marketplace and no
projects have been carried out using these contracts. Pure IPD, in its contractual sense,
requires a multiparty agreement among the prime players in the design and construction
process – at least the owner, the designer and the builder – but this agreement can include
many of the important sub-consultants and subcontractors as well (Levy, 2006).
Regarding project delivery systems and variations, some researchers have examined and
described some points. Ibbs et al. (2003), examines the relationship between impacts on
project change as against the DBB and DB project procurement method. They also found out
that, design, bid and build contracts experienced a higher number of changes and change in
cost against design and build contracts. The results obtained were consistent with studies
carried out earlier by Konchar and Sanvido (1998). Ibbs et al. (2003) also found that changes
to the schedule effects the total project duration and the worst effect if the design, bid and
build delivery system.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 19 Addis Ababa Institute of Technology
2.6 Management of Variation Orders
Construction contracts are complex both in nature and the process required to realize the
finished product. So variation is common on construction projects. Variation orders are
typically issued in the form of contract instructions.
Once a variation order has been instructed and works are carried out, the employer has to
reimburse the contractor for the same. This obligation of the employer involves certain
activities or stages for measurement of works, valuation of the varied works and payment for
the varied works.
According to Ssegawa et al. (2002) contractual clauses state how variation orders should be
initiated. In all cases, variation orders are issued by the consultant and must be given in
writing or oral instruction should be subsequently confirmed in writing (Wainwright &
Wood, 1983; FIDIC, 1999; Finsen, 2005; JBCC, 2005; Ssegawa et al., 2002). Since the
contractor is not bound to comply with the oral instructions, all oral instructions have to be
confirmed in writing by either the consultant or the contractor. Where variation orders are
confirmed in writing by the contractor, the consultant has to confirm by signature. If the
contractor is agreeable with the variation order, the works should proceed. The contractor and
the consultant agree upon which method of valuation of variation orders should be used.
The valuation of variation orders, while seen as an administrative step in the remuneration of
changes effected to the contract, is in reality a rather complex matter involving a thorough
understanding of contractual provisions, costing principles and an exercise of fair judgment
on the part of the evaluators (Wainwright & Wood, 1983; JBCC, 2005).
According to Wainwright et al. (1983), the valuation of variation orders may be in the form
of:
Rates where contracted rates are adopted where the varied works are of similar
character and extent and executed under similar conditions to items in the contract bills;
Day works which consist of the payment of executed works on a basis calculating the
prime cost of works including materials, labour, plant hire and transport plus a
percentage addition as agreed between parties to the contract;
Quotation where contractors submit a quotation to effect the work contained in a
variation order; and
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 20 Addis Ababa Institute of Technology
Quantum meruit is a miscellaneous method where negotiated or agreed rates or
payment are made on a reasonable sum.
Ming et al. (2004) defined a generic variation management process model (Figure 2.1). The
generic model consists of four stages, start up, identify & evaluation, approval, and
implement & review (Ming et al., 2004)
2.6.1 Start Up
This contains the proactive requirements that are essential for effective variation
management. These requirements enable the project team to respond readily to variation, to
manage variation effectively, and to facilitate contingency plans for any anticipated variation.
2.6.2 Identify and Evaluate
During a construction project, some variations can be anticipated while others may occur
unexpectedly. The aim of the project team is to actively seek to identify potential variations at
the earliest opportunity. This can be achieved by considering whether any of the potential
variation causes are likely to be present in a project. Once a potential variation is identified,
evaluation can be carried out in order to assist with the decision making process. Evaluation
steps may include implications assessment and optimum selection of variation options.
2.6.3 Approval
Once the evaluation step has been completed it will need to be approved by appropriate
member of the team (usually the project manager) and may be by the client depending on the
nature of the variation. In order to approve a variation it is necessary for the people involved
to see the impact that the variation will have on the project. There may be several iterations
during the approval process.
2.6.4 Implement and Review
Once a variation is approved, it needs to be communicated to all team members whose work
is affected by the variation. If necessary, schedule of work needs to be adjusted and new
schedule needs to be agreed by the whole team. Finally, the project team should review and
learn lessons from the process of the variation event.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 21 Addis Ababa Institute of Technology
No reconsider other variation options yes, but not sure Yes about estimation
Figure 2.1: Variation management process (Ming et al., 2004)
Start up
Identify variation
Evaluate variation
Criteria
Options
Internal review
Approval for minor variations
Rejection
Client approval
Rejection
Negotiation
Final variation proposal & confirm instructions
Issue information to relevant project team members
Design and project base-line updated & issued to all parties involved
Record decision reached
Finish
Team notified
Dispute resolution (if applicable)
Start Up
Iden
tify & Evalu
ate A
pp
roval
Imp
lement an
d R
eview
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 22 Addis Ababa Institute of Technology
2.7 Causes of Variation Orders
Various authors had identified different causes of variation orders in construction projects
both on the private and public projects. Contractual clauses relating to variation allows parties
involved in the contract to freely initiate variation orders within the ambit of the scope of the
work without alteration of the original contract (Ruben, 2008). But variation orders are
common in construction projects, and improved understanding would require identifying
their causes. The works of many researchers show that that variation has come to stay as part
of the construction projects and it cut across various stakeholders.
The causes of project variation may originate from either external or internal pressures that
are being applied to the project (Ming et al., 2004). External causes may be due to
technological changes, changes in the customer expectations and tastes, changes in
competitor’s activities, changes in government and policies, changes in the economy and
finally demographic changes in the society. Internal causes may result from changes in
management policy, changes in organizational objectives and changes in the long-term
survival strategy of the organizations involved.
According to Sunday (2010), the main causes of variation orders on construction projects are
inadequate working drawing details, design discrepancies, conflicts between contract
documents, the change of plans or scope by owner, impediment in prompt decision making
process, inadequate project objectives, and replacement of materials or procedures, differing
site conditions, shortage of skilled manpower, contractor’s desired profitability and
contractor’s financial difficulties.
Variation orders arise due to different causes. Some are foreseeable, others are not. Some
result from a genuine change of circumstances and others from the design team’s own
inadequacies. Arain and Pheng (2006) categorized causes of variations in to four origin
agents. These are client, consultant, contractor and others related changes. This means the
owner, the consultant, the contractor or other s can directly initiate variations or the variations
are required because one of the parties fails to fulfill certain requirements for carrying out the
project. As Mohammad et al. (2010) identified, change of plan by the owner, substitution of
materials by the owner, change in design by the consultant, errors and omissions in design,
and owner’s financial problems are the main causes of variation orders.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 23 Addis Ababa Institute of Technology
Ming et al. (2004) noted that at a more detailed level, the causes of construction project
variation are usually generated from either design or construction activities. The design
generated causes include design changes, design errors, omissions and operational
improvements. Construction driven causes are often linked to the unsatisfactory site
conditions that hinder good workmanship, material handling and plant operation. The design
and construction issues must be considered in conjunction with how the team is managed,
coordinated and communicated with to reduce problems resulting from insufficient work
separation, insufficient construction planning and disturbance in personnel planning.
Ssegawa et al. (2002) investigated the opinion of project parties regarding the frequency of
occurrence, causes, and originators of variation orders. The study found that additions and
omissions are the most common cause of variations in projects, which represented about
45.7% of all variation orders in building projects. Substitutions were considered the third
most important cause of variations. The study further revealed that restriction on working
conditions (space, access), and replacement of employee were ranked very low occurrence.
The main causes of omission related variations were lack of financial, design changes and
feasibility of construction. The study results indicated that client and architect caused most of
the omission due to financial reasons, design and changes of drawings, and feasibility of
construction. As Ruben (2008) found out, the most frequent causes of variation orders were
change of schedule, specifications and design and errors in design and inadequate working
drawing details.
Lots of studies are conducted to identify the causes of variation orders (Mohammad et al.,
2010; Arain and Pheng, 2006; Sunday, 2010; Ssegawa et al. (2002); Gray and Hughes, 2001;
Ruben, 2008; Al-Hammad and Assaf, 1992; Thomas and Napolitan, 1994; Clough and Sears,
1994; Assaf, et al., 1995; Puddicombe, 1997; Fisk, 1997; O’Brien, 1998; Mokhtar, et al.,
2000; Kumaraswamy, et al., 1998; O’Brien, 1998). List of causes of variation orders
identified from the above discussed sources are shown in Table 2.2 below.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 24 Addis Ababa Institute of Technology
Table 2.2: Causes of variation orders (Ruben, 2008)
S.N Causes of variation orders 1 Change of plans or scope 2 Change of schedule 3 Change in specifications 4 Change in design 5 Errors and omissions in design 6 Inadequate working drawing details 7 Non-compliant design with government regulations 8 Impediment in prompt decision making process 9 Unforeseen problems 10 Replacement of materials or procedures 11 Inadequate shop drawing details 12 Lack of judgment and experience 13 Financial problems 14 Inadequate scope of work for one or more parties to the contract 15 Design complexity 16 Lack of communication 17 Defective workmanship 18 Design discrepancies 19 Inadequate project objectives 20 Long lead procurement 21 Lack of coordination 22 Fast track construction 23 Ambiguous design details 24 Unavailability of skills 25 Weather conditions 26 Lack of strategic planning 27 Lack of knowledge of available materials and equipment 28 Lack of involvement in design of one or more parties to the contract 29 Non-compliant design with owner's requirement 30 Health and safety considerations 31 Lack of a specialized construction management 32 Obstinate nature of one or more of the parties to the contract 33 Differing site conditions 34 Poor procurement process 35 Conflicts between contract documents 36 Value engineering 37 Change in economic conditions 38 Honest wrong beliefs of one or more parties to the contract 39 Lack of required data 40 Unavailability of equipment 41 Unfamiliarity with or unawareness of local conditions 42 Socio-cultural factors 43 Change in government regulations 44 Speculation on desired profitability 45 Technology change
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 25 Addis Ababa Institute of Technology
2.8 Impact of Variation Orders on Building Projects
Impact is defined in electronic Webster dictionary as “the force of impression of one thing on
another”. In construction, variation orders can impact portions of the project directly or
indirectly and result in reduced productivity. This is always a subjective issue as the
contractor feel that the loss due to variation order is the fault of the designers and owners.
Conversely, owners typically claim that the loss in productivity is due to poor management
on the part of the contractors. However, not every variation order will impact the productivity
of the project.
Variations in any planned activity will cause a disturbance and will require the rearrangement
or review of the existing plan under the recent developments. Given the complex, multi-party
and multi resource nature of the construction industry, it is not difficult to perceive the
impacts of changes on projects.
Impacts of variations were observed by many researchers and its occurrence has an adverse
impact on project performance. Ruben (2008) found that variation orders had an impact on
overall project performance and the major adverse impact of variation orders are time and
cost overruns and disputes between the parties to the contract. Thomas et al. (2002) suggest
that variability generally impedes project performance. Ibbs (1997) concluded that variation
orders affect project performance as they adversely affect productivity and project costs.
According to Arain and Pheng (2005b) variation orders are an unwanted but inevitable reality
of any construction project. Further, Hanna et al. (2002) found that projects with many
variation orders cause the contractor to achieve lower productivity levels than planned.
Variation orders adversely impact project performance in terms of cost overruns, time
overruns, quality degradation, health and safety issues and professional relations. Numerous
studies have been done to identify the impacts of variations, relationships between variation
and its impacts (Hanna et al., 2002; Hester et al., 1991; Thomas and Napolitan, 1994; Osman
et al., 2009; Ibbs, 1997; Arain and Pheng, 2005b; Haldun, 1998; CII, 1990; Ibbs, 1995).
The 16 impacts identified from the literature review, as shown in Table 2.3: are discussed
below.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 26 Addis Ababa Institute of Technology
Table 2.3: Impacts of variation orders (Hanna et al., 2002)
S. N Impacts of Variation Orders
1 Increase in project cost 2 Progress is affected but without any delay 3 Increase in overhead expenses 4 Delay in payment 5 Quality degradation 6 Productivity degradation 7 Procurement delay 8 Rework and demolition 9 Logistics delays 10 Blemish firm’s reputation 11 Poor safety conditions 12 Poor professional relations 13 Additional payments for contractor 14 Disputes among professionals 15 Completion schedule delay
a. Increase in project cost
Construction projects involve recognized phases of which two are particularly important,
namely the pre-construction and construction phases. The most common impact of variations
during the construction phase is the increase in project cost (CII, 1990). However, all
variation orders do not increase the costs of construction. Omissions in most cases reduce
costs while additions increase costs (Ssegawa et al., 2002). As Ruben (2008) found in his
study variation orders adversely impact costs. In every construction project, a contingency
sum is usually allocated to cater for possible variations in the project, while keeping the
overall project cost intact. Arguably, the more the number of variation orders, the more they
are likely to affect the overall construction delivery cost. In fact, variation orders have both a
direct and indirect effect on cost. Direct costs constitute the additional costs incurred to
perform the activities of the current variation orders. As Bower (2000) identified, the direct
costs associated with variation orders are as follows:
Time and material charges related to immediately affected tasks;
Recalculation of network, increased time-related charges and overheads;
Reworks and standing time;
Timing effects for example winter time;
Inflation, change to cash flow and loss of earnings; and
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 27 Addis Ababa Institute of Technology
Management time, head office and site charges.
Bower (2000) also pointed out that indirect costs are costs incurred as a result of variation
orders, whether they are apparently linked to them or not. These include:
Loss of productivity due to interruption where the gang has to familiarize with new
working condition, tools and material;
Rework and making good on affected trades other than the actual variation order
Change in cash flow due to effect on inflation and financial charges;
Cost for redesign and administration of the variation order; and
Litigation-related costs in case disputes arise due to the variation order.
b. Progress is affected
Project progress may be impacted by variations (Assaf et al., 1995). During execution of the
project, time has an equivalent monetary value even if the professional team tries its best to
keep the project completion schedule intact. However, only major variations during the
project may affect the project completion time according to Arain and Pheng (2005). This
means the contractor would usually try to accommodate the variations by utilizing the free
floats in the construction schedules. Hence, the variations affect the progress but without any
delay in the project completion if the free floats are utilized.
c. Increase in overhead expenses
Variations need to go through a few stages of processing procedures as mentioned earlier and
require to be evaluated before they can even be implemented (O’Brien, 1998). The process
and implementation of variations in construction projects would increase the overhead
expenses for all the participants concerned. Normally these overhead charges are provided for
from the contingency fund allocated for the construction project.
d. Delay in payment
Delay in payment occurred frequently due to variations in construction projects (CII, 1990).
Variations may hinder the project progress, leading to delays in achieving the targeted
milestones during construction (CII, 1995). Eventually, this may affect payment to the
contractors. Occasionally this delay may cause severe problems that end up in delays in
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 28 Addis Ababa Institute of Technology
payment to the subcontractors; this is because main contractors may not be able to pay the
subcontractors unless they get paid by the owner first.
e. Quality degradation
Variations, if frequent, may impact the quality of work adversely (Fisk, 1997). Contracts with
a significant degree of risk for unknown variables such for example, lump sum, contractors may
cut corners on quality and quantity to maximize profits. According to CII (1995), the quality of
work was usually poor because of frequent variations since contractors tended to compensate
for the losses.
f. Productivity degradation
Interruption, delays and redirection of work that are associated with variation orders have a
negative impact on labour productivity. These in turn can be translated into labour cost or
monetary value (Ibbs, 1997b). Hester et al. (1991) argued that the productivity of workers
was expected to be greatly affected in cases where they were required to work overtime for
prolonged periods to compensate for schedule delays. Thomas and Napolitan (1995)
concluded that variations normally led to disruptions and these disruptions were responsible
for labour productivity degradation. The most significant types of disruptions were due to the
lack of materials and information as well as the work out of sequence. Lack of material was
reported as the most serious disruption. Hence, to manage variation, one needed to manage
these disruptions. However, the disruptive effects could not be avoided in many instances.
g. Procurement delay
Variations which are imposed when construction is underway may require revised
procurement requests (O’Brien, 1998). Procurement delays can be frequent due to variations
that require new materials and specialized equipment. Hester et al. (1991) observed that
procurement delays were common effects of variations related to new resources for
construction projects.
h. Rework and demolition
Rework and demolition are frequent occurrences due to variations in construction projects
(Clough and Sears, 1994). Variations which are imposed when construction is underway or
even completed, usually lead to reworks and delays in project completion (CII, 1990a).
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 29 Addis Ababa Institute of Technology
Rework and demolition are potential effects of variations in construction, depending on the
timing of the occurrence of the variations. These effects are to be expected due to variations
during the construction phase. This is because the variations during the design phase do not
require any rework or demolition on construction sites.
i. Logistics delays
Logistics delays may occur due to variations requiring new materials and equipment (Fisk,
1997). Hester et al. (1991) observed that logistics delays were significant effects of variations
in construction projects. Logistics delays were experienced in construction projects where
variations in the construction phase required new materials, tools and equipments.
j. Blemish firm’s reputation
Variations are referred to as a major source of construction claims and disputes (Fisk, 1997;
Kumaraswamy et al., 1998). The claims and disputes may affect the firm’s reputation
adversely, leading to insolvency in severe cases. Variations also increase the possibility of
professional disputes. Conventionally, variations present problems to all the parties involved
in the construction process.
k. Poor safety conditions
Variations may impact the safety conditions in construction projects (O’Brien, 1998; Arain et
al., 2004). This is because change in construction methods, materials and equipment may
require additional health and safety measures (Arain & Pheng, 2005).
l. Poor professional relations
Construction changes are a major source of construction dispute (Fisk, 1997). Eventually,
variations may impact professional relations, leading to disputes.
Clear procedures that are presented in the contract and fair allocation of risks can help in
resolving disputes through negotiation rather than litigation (CII, 1995).
m. Additional payments for contractor
Additional payments for the contractor can be an impact of variations in construction
projects. Variations are considered to be a common source of additional works for the
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 30 Addis Ababa Institute of Technology
contractor (O’Brien, 1998). Due to additional payments, the contractor looks forward to
variations in the project.
n. Disputes among professionals
Like poor professional relations, disputes among professionals are also impacts of frequent
variations in construction projects. The disputes over variation orders and claims are
inevitable and the variation clauses are often the source of project disputes (CII, 1995). Clear
procedures presented in the contract and fair allocation of risks can help in resolving disputes
through negotiation rather than litigation (CII, 1995). Frequent communication and strong
coordination can assist in eliminating the disputes between professionals.
o. Completion schedule delay
Clients require their construction projects to be completed within minimum time limits. It is
anticipated that projects finished within the shortest possible time achieve some monetary
savings. Completion schedule delay is a frequent result of variations in construction projects
(Ibbs, 1997). According to Koushki (2005) variation orders issued during various phases of
construction projects impacted both the completion time and costs of projects. Hanna et al.
(2002) stated that as the number of variation orders increases the more significant
productivity losses become. Productivity is the amount of output over a unit of time.
Therefore, loss in productivity implies loss of time and subsequent delays.
2.9 Recommended Strategies to Minimize Variation Orders
The potential impact of variation orders can be minimized if possible strategies are clearly
suggested. As Arain (2005) suggested, variations can be reduced with due diligence during
the design stages. Furthermore, it would assist professionals in taking proactive measures for
reducing variation orders for building projects if strategies are suggested. In order to
minimize variation orders control system should be established for the ultimate benefit of
owners. Baharuddin (2005) concluded variation orders can be minimized if all the parties
involved in projects are aware that preliminary work before tendering must be carried out, for
example detailed site and soil investigations. While design errors and omissions cannot be
completely avoided, they can be reduced especially if designers assessed their workloads
before committing themselves to new contracts (Ruben, 2008). In another way, the designers
should ensure enough time and experienced human resources to deliver a sound design within
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 31 Addis Ababa Institute of Technology
the proposed time frames. Ruben (2008) identified recommendations to reduce the
occurrence of variation orders. Among other recommendations, Baharuddin (2005) identified
the following recommended strategies and suggestions to reduce the occurrences of variation
orders. Many studies were conducted to find out possible strategies to minimize variation
orders.
List of strategies that suggested by different researchers are identified as follows (Bower,
di: the difference in ranking between each pair of factors; and
N: number of factors (variables).
The value of the Spearman (rho) rank correlation coefficient varies between -1 and +1. A
correlation coefficient of +1 implies perfect positive correlation, 0 implies no correlation and
-1 implies perfect negative correlation.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 40 Addis Ababa Institute of Technology
CHAPTER FOUR
DATA ANALYSIS AND DISCUSSION
4.1 Introduction
This chapter analyses the data collected using questionnaires, desk study and interviews. The
method used is discussed in Chapter 3. The collected data from the questionnaires were
tabulated and analyzed according to their ranking on Relative Index (RI). Interviews from
selected respondents are presented, together with observations from desk study. The objective
of this chapter is to identify the highest ranked factors for discussion and to find correlation
with findings from the interviews and desk study.
4.2 Analysis of Data from the Desk Study
During the study period, there were a total of thirty-eight (38) public building projects which
were under execution in Addis Ababa and twenty-eight (28) project samples are taken for the
study. From this number five (5) completed projects in which variation orders (VO) approved
were selected for desk study in order to fully understand the causes and impacts of variation
orders and to determine what recommendations or strategies could be taken to minimize
variation orders on public building projects. These projects were 100% completed and
selected as a representative to the occurrences of variation orders of each of the public
building projects. The list of selected projects is as shown in Table 4.1.
Table 4.1: List of selected building projects
Project Code
Project Name Contract Amount (Birr)
V.O (Birr)
Percent of V.O (%)
Project A Sport Commission 51,931,227.89 8,284,485.09 15.95
Project B Education Bureau 60,343,438.45 4,091,699.06 6.78
Project C Police Commission 99,444,398.79 8,152,255.70 8.20
Project D Credit & Savings Institution 36,914,578.87 7,234,368.3 19.60
Project E Fire and Emergency Service 58,076,253.18 5,150,610.80 8.87
(Source: Addis Ababa Housing Development & Construction Bureau (2012))
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 41 Addis Ababa Institute of Technology
4.2.1 Project A
The tender sum for Project A was 51,931,227.89Birr and the original planned works duration
was 540 days. There were numerous additional works associated with design changes due to
owner’s requirement. During the observation of the project it was observed that additional
partition walls were provided between the rooms. Items were missed on contract document
for sanitary and electrical works. Due to these changes a variation of 8,284,485.09Birr was
ordered. As the contractor could not finish on agreed time, the extension of time of 255 days
was granted which was a time overrun of 47.22% over the schedule of works. No penalties
were levied against the contractor.
4.2.2 Project B
Project B was awarded with a tender sum of 60,343,438.45Birr and the original planned works
duration was 720 days. The project was exposed to variation due to design changes for the
error made by the consultant. It was observed that civil site works were redesigned which
incurred an extra cost. Items were missed on contract document for sanitary and electrical
works. Due to these changes a variation of 4,091,699.06Birr was ordered. Due to lack of
communication between the client and the consultant, dispute occurred between the client
and consultant. Then the payment is delayed and the contractor was granted an extension
time of 300 days which was a time overrun of 41.67% over the planned works duration.
4.2.3 Project C
The tender sum for Project C was 99,444,398.79Birr and the original planned works duration
was 800 days. The project was exposed to variation order of 8,152,255.70Birr due to missed
items on contract document, design modifications on civil site works, and design changes for
roofing works. Modification of the civil site works took about five months to make decisions
and submit the modified documents to the contractor. Due to this lack of decision making
process by the client, the contractor was granted an extension time of 285 days which was a
time overrun of 35.63% over the schedule of works.
4.2.4 Project D
Project D was awarded with a tender sum of 36,914,578.87Birr and the original planned
works duration was 600 days. The project was exposed to variation order of 7,234,368.30Birr
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 42 Addis Ababa Institute of Technology
due to additional works on civil site, missed items on contract document and design
modifications on door and window works which caused by design errors made by the
consultant. The client ordered the contractor to execute the additional works, the missed
items and the works to be modified. Due to lack of decision making process, the client did
not submit the modified deign at the right time to the contractor. The interim payment to the
contractor is also delayed due to the additional works which totally affected payment for the
other activities. Due to this reason the project was delayed which caused by the client and the
contractor was granted an extension time of 245 days which was a time overrun of 40.83%
over the schedule of works.
4.2.5 Project E
The tender sum for Project E was 58,076,253.18Birr and the original planned works duration
was 540 days. A variation of 5,150,610.80Birr was ordered due to missed items on contract
document. The client did not approve the variation at their earliest with the right decision.
The contractor was granted an extension of time of 285 days which was a time overrun of
52.78% over the planned works duration. The client's records were silent relative to the
reason for such an extension except the missed items on the contract document.
Table 4.2: Summary of causes and impact of variation orders data from the desk study
Project Causes of V.O Impact of V.O
Project A Design changes Incomplete contract document
Increase in project cost Completion schedule delay
Project B Modification of design Incomplete contract document and
drawings Lack of communication between parties
Increase in project cost Completion schedule delay Disputes among the parties Payment delay to the contractor
Project C Design changes Incomplete contract document Modification of design Lack of decision making by the client
Increase in project cost Completion schedule delay
Project D Additional works Incomplete contract document Modification of design
Increase in project cost Completion schedule delay Payment delay to the contractor
Project E Incomplete contract document Lack of decision making by the client
Increase in project cost Completion schedule delay
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 43 Addis Ababa Institute of Technology
4.2.6 Findings from the Desk Study
The desk study was applied to five selected documents of public building projects contract
documents. The contract documents were massive with data, information, contract, bill of
quantities and drawings. The studied documents were signed, stamped and legal documents at
law.
4.2.6.1 Causes of Variation Orders
The desk study findings showed that fourteen (14) causes of variation orders in answering the
first objective. Due to the repetition, it was further syntheses to eight (8) from the most to the
least repetitive causes of variation orders to be used in questionnaire for the verification and
validation process to evaluate their degree of important. But all the eight causes were already
the domain of the variables which identified from the literatures review. Below is the
document study finding of summary of causes of variation orders from the five projects
contract documents as shown in Table 4.3.
Table 4.3: Causes of variation orders from the desk study
S.N Causes of Variation Orders 1 Design changes 2 Incomplete contract documents 3 Incomplete working drawings 4 Errors in design by the consultant 5 Design modification 6 Non-compliant design with owner’s requirement 7 Lack of communication between the parties 8 Lack of decision making process by the client
4.2.6.2 Impact of Variation Orders
From the document study findings, the following are summary of the impacts of variation
orders shown in Table 4.4. Thirteen (13) impacts were identified in answering the second
objective. And these variables were further syntheses to four (4) in ascending order of their
prepetition which were be used in the questionnaire for the verification and validation process
to evaluate their degree of important. But all the variables were in the literatures review.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 44 Addis Ababa Institute of Technology
Table 4.4: Impacts of variation from the desk study
S.N Impacts of Variation Orders
1 Increase in project cost 2 Completion schedule delay 3 Payment delay to the contractor 4 Disputes among the involved parties
4.3 Interviews
4.3.1 Analysis of Data from the Interview
These interviews were made between selected construction industry practitioners who are
currently involved in public building projects focusing on their perceptions on variations
orders. In total three interviews were conducted, namely with a senior project supervision and
follow up team leader (A) from the clients’ group, a senior contract administrator (B) from
the consultants’, and a senior project manager (C) from the contractors’ group as shown in
Table 4.5 below. The interview aimed at discovering the causes of variation orders and their
impacts on public building projects and to seek recommendations to minimize their
occurrence.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 45 Addis Ababa Institute of Technology
Table 4.5: Interview results Questions Interviewee A Interviewee B Interviewee C
From
you
r exp
erie
nce,
wha
t are
the
caus
es o
f var
iatio
n or
ders
on
publ
ic
build
ing
proj
ects
?
Incomplete BoQ
Design changes and
modification
Errors in design
Change in
specifications
Lack of
communication
between parties
Design Changes
Change in
specification
Incomplete BoQ
Unforeseen conditions
on site
Lack of coordination
Discrepancy between
drawing and BoQ
Non-compliant design
with client’s
requirement
Lack of experience
Errors in design
Design complexity
Lack of judgment
Wha
t are
the
vario
us im
pact
s of
var
iatio
n or
ders
on
publ
ic
build
ing
proj
ects
?
Increase in project
cost
Completion
schedule delay
Degrades quality
Disputes among the
professionals
Increase in project cost
Completion schedule
delay
Rework and
demolition
Increase in contract and
over head costs
Disputes among parties
Completion schedule
delay
Wha
t do
you
sugg
est t
o m
inim
ize
the
varia
tion
orde
rs o
n pu
blic
bui
ldin
g pr
ojec
ts?
Produce a complete
design and contract
document
Prepare a completed
detail drawings
There should be
communication
between parties
Designs should be
complete at tender
stage
Carry out detail site
investigation before
tendering stage
Forecast unforeseen
situations before
tendering
Prepare a complete
drawing and contract
document before
tendering stage
Completed detail
drawings should be
submitted on time
Works should be
supervised with
experienced supervisors
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 46 Addis Ababa Institute of Technology
4.3.2 Findings from the Interview
From the interview sixteen (16) causes of variation orders in answering the first question, ten
(10) impacts of variation orders for the second question and nine (9) strategies to minimize
variation orders in answering the third question were identified. These variables were merged
and checked if they were out of the literatures in order to include them in the questionnaire.
But more of them with the same meaning were the domain of the variables identified from
the literatures.
The findings from the interview revealed that incomplete contract document, design changes,
change in specifications, errors in design, unforeseen conditions, design complexity, lack of
communication and coordination between the parties, lack of experience and of judgment
were the causes which contribute to the occurrence of variation orders.
As identified from the interview, the impacts of variation orders which frequently occur on
public building projects were increase in project cost, most of the time which termed as cost
overrun, completion schedule delay termed as time overrun, disputes among the parties, it
degrades quality and it results in rework and demolition.
The interviewee suggested that it is possible to minimize the occurrence variation orders with
the most common strategies which always pointed out by experienced construction
practitioners. According to the interviewee, a complete design and contract documents should
be produced, complete detail drawings should be submitted on time, a detail site investigation
should be carried out and unforeseen conditions should be forecasted before the tendering
stage and supervising the works with experienced supervisors can minimize variation orders
on public building projects.
4.4 Analysis of Data from the Questionnaires
4.4.1 Rate of Response
The respondents were grouped into three major groups namely client, consultant and
contractor. The returns from the three groups are tabulated in Table 4.6 below which shows
an average response rate. Out of 45 targeted responses, only 32 (71%) of them completed and
returned the questionnaire. Thirty one questionnaires from 9 clients, 4 consultants and 19
contractors were received.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 47 Addis Ababa Institute of Technology
Among the nine responses received from clients, seven (78%) of them were construction
supervisors and follow-up engineers while two (22%) were contract administrators.
Among the four responses received from consultants, three (75%) of them were resident
engineers and one (25%) was contract administrator. And among the nineteen responses
received from contractors, eight (42%) of them were project managers, eight (42%) of them
were office engineers, three (16%) were quantity surveyors. Figure 4.1 below shows the
composition of respondents by their position in their organization.
Figure 4.1: Position of respondents
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 48 Addis Ababa Institute of Technology
4.4.3 Respondents’ Experience
All the respondents have different levels of work experience in building projects. Proportions of
the respondents in terms of number of years of involvement in building projects are tabulated in
Table 4.7. It was observed that the majority of the respondents from the clients have between five
to ten years of experience. Majority of the respondents from the consultants have also between
five to ten years of experience. And about one half of the respondents from the contractors have
less than five years of experience.
Table 4.7: Respondents’ experience
Experience in
Building Projects Client Consultant Contractor Total
Less than 5 years 3 1 12 16
5 to 10 years 4 2 3 9
10 years and above 2 1 4 7
4.4.4 Findings from the Questionnaires
In the structured part of the questionnaire, the respondents were asked to rate the degree of
contribution of the variables drawn from the literature review. Furthermore, the respondents
were also asked to add other variables or factors that contributed to the causes and impacts as
well as recommendations that they perceived as being necessary. The responses were
analyzed using the Microsoft Excel software package.
From the forty five (45) causes of variation identified from the literatures, only thirty-eight
(38) mutually exclusive causes of variation orders, fifteen (15) impacts of variation orders
and fifteen (15) strategies to minimize variation orders on building projects were used in
questionnaire survey. All the impacts of variation orders and the suggested strategies to
minimize them were used as identified from the literatures. The analysis was divided in to
three groups the clients’ point of view, the consultants’ point of view and the contractors’
point of view and a correlation test was done between the groups. A ranking system using the
Relative Index (RI) method was calculated to find the most significant factor for each section.
The value of RI ranges from 0.2 to 1. The value 0.2 represents the lowest strength and the
value 1 representing the maximum strength.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 49 Addis Ababa Institute of Technology
4.4.4.1 Causes of Variation Orders on Public Building Projects
The frequency of the causes of variation orders were identified by using a 5 point Likert
scale, namely Never = 1; Seldom = 2; Sometimes = 3, Often = 4; and Always = 5. The causes
of variation orders were ranked by comparing their relative index.
I. Clients Group
From Table 4.8 below, it was possible to rank the causes of variation orders by comparing
their RI. According to the clients, impediment in prompt decision making process, change in
design by the consultant, errors and omissions in design, inadequate working drawing details,
and unforeseen problems were the most ranking causes of variation which dominate with
equal value (RI=0.667) followed by change in specifications, conflicts between contract
documents, and design discrepancies (RI=0.644). And health and safety consideration was
the least ranked cause of variation orders.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 50 Addis Ababa Institute of Technology
Table 4.8: Frequency of causes of variation orders from the clients group
Causes of Variation Orders RI of Client
Ranking
Impediment in prompt decision making process 0.667 1 Change in design by the consultant 0.667 2 Errors and omissions in design 0.667 3 Inadequate working drawing details 0.667 4 Unforeseen problems 0.667 5 Change in specifications 0.644 6 Conflicts between contract documents 0.644 7 Design discrepancies 0.644 8 Unavailability of skills 0.622 9 Contractor's desired profitability 0.622 10 Non-compliant design with owner's requirement 0.600 11 Lack of strategic planning 0.600 12 Change of schedule 0.578 13 Lack of coordination 0.578 14 Lack of consultant's knowledge of available materials and equipment 0.578
15
Lack of contractor's involvement in design 0.578 16 Poor procurement process 0.578 17 Consultant's lack of judgment and experience 0.556 18 Change of plans or scope 0.533 19 Technology change 0.533 20 Design complexity 0.533 21 Consultant's lack of required data 0.533 22 Honest wrong beliefs of contractor 0.533 23 Differing site conditions 0.511 24 Defective workmanship 0.511 25 Unfamiliarity with local conditions 0.511 26 Contractor's lack of required data 0.511 27 Non-compliant design with government regulations 0.489 28 Lack of communication 0.489 29 Inadequate project objectives 0.467 30 Lack of a specialized construction manager 0.467 31 Change in government regulations 0.467 32 Change in economic conditions 0.444 33 Fast track construction 0.422 34 Weather conditions 0.422 35 Honest wrong beliefs of consultant 0.400 36 Socio-cultural factors 0.400 37 Health and safety considerations 0.378 38
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 51 Addis Ababa Institute of Technology
II. Consultants Group
As shown in Table 4.9, respondents of this group equally believed that change in economic
conditions and unforeseen problems were the most ranking causes of variation orders
(RI=0.800). Change of plans, change in specifications, and poor procurement process
followed with equal value (RI=0.750) and then change of schedule (RI=0.700). According to
the respondents of this category the least ranked cause of variation orders was honest wrong
beliefs of consultant.
Table 4.9: Frequency of causes of variation orders from the consultants group
Causes of Variation Orders RI of
Consultant Ranking
Change in economic conditions 0.800 1 Unforeseen problems 0.800 2 Change of plans or scope 0.750 3 Change in specifications 0.750 4 Poor procurement process 0.750 5 Change of schedule 0.700 6 Design discrepancies 0.700 7 Lack of contractor's involvement in design 0.700 8 Lack of communication 0.700 9 Honest wrong beliefs of contractor 0.700 10 Lack of strategic planning 0.700 11 Change in design by the consultant 0.650 12 Errors and omissions in design 0.650 13 Contractor's desired profitability 0.650 14 Differing site conditions 0.650 15 Unfamiliarity with local conditions 0.650 16 Contractor's lack of required data 0.650 17 Impediment in prompt decision making process 0.600 18 Design complexity 0.600 19 Unavailability of skills 0.600 20 Lack of a specialized construction manager 0.600 21 Weather conditions 0.600 22 Health and safety considerations 0.600 23 Inadequate project objectives 0.550 24 Conflicts between contract documents 0.550 25 Inadequate working drawing details 0.550 26 Consultant's lack of judgment and experience 0.550 27 Non-compliant design with government regulations 0.550 28 Non-compliant design with owner's requirement 0.550 29 Defective workmanship 0.550 30 Fast track construction 0.550 31 Socio-cultural factors 0.550 32 Technology change 0.500 33 Lack of coordination 0.500 34 Consultant's lack of required data 0.500 35 Change in government regulations 0.500 36 Lack of consultant's knowledge of available materials 0.450 37 Honest wrong beliefs of consultant 0.400 38
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 52 Addis Ababa Institute of Technology
III. Contractors Group
From Table: 4.10 below, the most cause of variation according to these respondents lack of
communication (RI=0.726). The second ranked cause was inadequate working drawing
details (RI=0.695), followed by impediment in prompt decision making process and poor
procurement process (RI=0.684) and then change in design by the consultant (RI=0.674).
Health and safety consideration was the least ranked cause of variation orders.
Table 4.10: Frequency of causes of variation orders from the contractors group
Causes of Variation Orders RI of
Contractor Ranking
Lack of communication 0.726 1 Inadequate working drawing details 0.695 2 Impediment in prompt decision making process 0.684 3 Poor procurement process 0.684 4 Change in design by the consultant 0.674 5 Change of plans or scope 0.663 6 Lack of contractor's involvement in design 0.663 7 Contractor's desired profitability 0.663 8 Change in specifications 0.653 9 Errors and omissions in design 0.653 10 Contractor's lack of required data 0.653 11 Change of schedule 0.642 12 Consultant's lack of judgment and experience 0.642 13 Lack of consultant's knowledge of available materials 0.642 14 Consultant's lack of required data 0.642 15 Design discrepancies 0.642 16 Lack of a specialized construction manager 0.642 17 Lack of strategic planning 0.632 18 Unforeseen problems 0.621 19 Lack of coordination 0.611 20 Differing site conditions 0.600 21 Defective workmanship 0.600 22 Unfamiliarity with local conditions 0.600 23 Conflicts between contract documents 0.589 24 Change in economic conditions 0.579 25 Design complexity 0.568 26 Non-compliant design with owner's requirement 0.568 27 Honest wrong beliefs of contractor 0.547 28 Unavailability of skills 0.537 29 Weather conditions 0.526 30 Technology change 0.516 31 Honest wrong beliefs of consultant 0.516 32 Non-compliant design with government regulations 0.516 33 Inadequate project objectives 0.495 34 Socio-cultural factors 0.484 35 Fast track construction 0.474 36 Change in government regulations 0.442 37 Health and safety considerations 0.411 38
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 53 Addis Ababa Institute of Technology
The spearman correlation coefficient is calculated using Equation 3.2 and tabulated as
shown below in Table 4.11.
Table 4.11: Summary of correlation test on the ranking of causes of variation orders
Respondents Rho(cal) = 1 – 6x(∑di2)
N x (N2 –1)
Relation of the respondents
Client Vs Consultant 0.999 strong
Consultant Vs Contractor 1.000 strong
Client Vs Contractor 1.000 strong
From the correlation table above, it can be concluded that there is a strong correlation
between the attitudes of the respondents in all the three groups. This means that most of the
respondents have the same perception about the causes of variation orders.
IV. Overall Responses
As sown in Table: 4.12 below, it was possible to rank the causes of variation orders
combining the responses of all respondents. The most raked causes of variation orders by all
respondents were impediment in prompt decision making process, change in design by the
consultant, and inadequate working drawing details dominate with the same value
(RI=0.669). Change in specifications and poor procurement process came next with equal
value (RI=0.663). Errors and omissions in design, lack of communication and unforeseen
problems followed with the same value (RI=0.656) and then design discrepancies and
contractor's desired profitability (RI=0.650). Change in government regulations (RI=0.456)
and health and safety considerations (RI=0.425) were the least ranked causes of variation
orders.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 54 Addis Ababa Institute of Technology
Table 4.12: Overall frequency of causes of variation orders
Causes of Variation Orders Overall RI Ranking
Impediment in prompt decision making process 0.669 1 Change in design by the consultant 0.669 2 Inadequate working drawing details 0.669 3 Change in specifications 0.663 4 Poor procurement process 0.663 5 Errors and omissions in design 0.656 6 Lack of communication 0.656 7 Unforeseen problems 0.656 8 Design discrepancies 0.650 9 Contractor's desired profitability 0.650 10 Lack of contractor's involvement in design 0.644 11 Change of plans or scope 0.638 12 Change of schedule 0.631 13 Lack of strategic planning 0.631 14 Contractor's lack of required data 0.613 15 Consultant's lack of judgment and experience 0.606 16 Conflicts between contract documents 0.600 17 Lack of consultant's knowledge of available materials 0.600 18 Consultant's lack of required data 0.594 19 Lack of coordination 0.588 20 Lack of a specialized construction manager 0.588 21 Differing site conditions 0.581 22 Unfamiliarity with local conditions 0.581 23 Non-compliant design with owner's requirement 0.575 24 Unavailability of skills 0.569 25 Defective workmanship 0.569 26 Change in economic conditions 0.569 27 Design complexity 0.563 28 Honest wrong beliefs of contractor 0.563 29 Technology change 0.519 30 Non-compliant design with government regulations 0.513 31 Weather conditions 0.506 32 Inadequate project objectives 0.494 33 Honest wrong beliefs of consultant 0.469 34 Fast track construction 0.469 35 Socio-cultural factors 0.469 36 Change in government regulations 0.456 37 Health and safety considerations 0.425 38
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 55 Addis Ababa Institute of Technology
4.4.4.2 Impact of Variation Orders on Public Building Projects
The impact of variation orders on building projects was determined using a 5 point Likert
scale, namely No impact = 1; Low impact = 2; Medium impact = 3; High impact = 4; and
Very high impact = 5. The impact of variation orders were ranked by comparing their relative
index.
I. Clients Group
From Table: 4.13 below, the respondents of this group responded that the most impact of
variation order was completion schedule delay (RI=0.822) followed by increase in project
cost (RI=0.778).Additional payments for contractor was the third ranked impact (RI=0.733)
and disputes among the parties was the forth. Fifthly progress is affected according to the
clients followed by delay in payment and logistics delays with equal value (RI = 0.622).
Productivity degradation and blemish firm’s reputation were the least impact of variation
orders on building projects with equal value (RI = 0.422).
Table 4.13: Frequency of impact of variation orders from the clients group
Impact of variation orders RI of Client
Ranking
Completion schedule delay 0.822 1
Increase in project cost 0.778 2
Additional payments for contractor 0.733 3
Disputes among professionals 0.667 4
Progress is affected 0.644 5
Delay in payment 0.622 6
Logistics delays 0.622 7
Increase in overhead expenses 0.600 8
Procurement delay 0.578 9
Rework and demolition 0.556 10
Poor professional relations 0.511 11
Quality degradation 0.489 12
Poor safety conditions 0.444 13
Productivity degradation 0.422 14
Blemish firm’s reputation 0.422 15
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 56 Addis Ababa Institute of Technology
II. Consultants Group
As it can be seen Table: 4.14 below, it was possible to rank the impacts of variation orders.
The most raked impacts of variation orders by the consultants were increase in project cost,
delay in payment, and completion schedule delay with equal value (RI=0.850). Progress
affection came next (RI=0.800) and then increase in overhead expenses, rework and
demolition, and logistics delays followed the rank (RI=0.700). Poor safety conditions and
disputes among professionals with equal value (RI=0.600) were the least impacts of variation
orders on public building projects.
Table 4.14: Frequency of impact of variation orders from the consultants group
Impact of variation orders RI of
Consultant
Ranking
Increase in project cost 0.850 1 Delay in payment 0.850 2 Completion schedule delay 0.850 3 Progress is affected 0.800 4 Increase in overhead expenses 0.750 5 Rework and demolition 0.750 6 Logistics delays 0.750 7 Procurement delay 0.700 8 Additional payments for contractor 0.700 9 Quality degradation 0.650 10 Productivity degradation 0.650 11 Blemish firm’s reputation 0.650 12 Poor professional relations 0.650 13 Poor safety conditions 0.600 14 Disputes among professionals 0.600 15
III. Contractors Group
From the following Table 4.15, it was possible to rank the impacts of variation orders by
comparing their RI. According to the contractors, completion schedule delay (RI=0.800) was
the most ranked impact followed by increase in project cost (0.789). Progress affection
(RI=0.768) and additional payments for contractor (RI=0.737) were the next most ranked
impact (RI=0.768) and then increase in overhead expenses (RI=0.716). According to the
contractors, poor safety conditions and poor professional relations were the least ranked
impacts of variation orders with equal value (RI=0.579).
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 57 Addis Ababa Institute of Technology
Table 4.15: Frequency of impact of variation orders from the contractors group
Impact of variation orders RI of
Contractor
Ranking
Completion schedule delay 0.800 1
Increase in project cost 0.789 2
Progress is affected 0.768 3
Additional payments for contractor 0.737 4
Increase in overhead expenses 0.716 5
Delay in payment 0.705 6
Procurement delay 0.705 7
Productivity degradation 0.674 8
Logistics delays 0.653 9
Disputes among professionals 0.653 10
Rework and demolition 0.642 11
Blemish firm’s reputation 0.611 12
Quality degradation 0.600 13
Poor safety conditions 0.579 14
Poor professional relations 0.579 15
The spearman’s correlation coefficient is calculated using Equation 3.2 and tabulated as
shown below in Table 4.16.
The summarized spearman correlation coefficient indicates that there is a strong correlation
between all the three groups. This implies that most of the respondents have the same
perception about the impact of variation orders.
Table 4.16: Summary of correlation test on the ranking of impact of variation orders
Respondents Rho(cal) = 1 – 6x(∑di2)
N x (N2 –1)
Relation of the respondents
Client Vs Consultant 0.994 strong
Consultant Vs Contractor 0.999 strong
Client Vs Contractor 0.997 strong
IV. Overall Responses
As it can be seen in Table: 4.17 below, the most raked impacts of variation orders from the
combined responses of all respondents were completion schedule delay (RI=0.794) followed
by increase in project cost (RI=0.793). Additional payments for contractor (RI=0.742) and
progress affection (RI=0.731) were the next and then increase in overhead expenses
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 58 Addis Ababa Institute of Technology
(RI=0.697). Poor safety condition (RI=0.537) were the least ranked impact of variation orders
as responded by all participants.
Table 4.17: Overall frequency of impact of variation orders
Impact of variation orders Overall
RI Ranking
Completion schedule delay 0.794 1 Increase in project cost 0.793 2 Additional payments for contractor 0.742 3 Progress is affected 0.731 4 Increase in overhead expenses 0.697 5 Delay in payment 0.694 6 Procurement delay 0.679 7 Logistics delays 0.667 8 Disputes among professionals 0.661 9 Rework and demolition 0.642 10 Productivity degradation 0.594 11 Blemish firm’s reputation 0.576 12 Quality degradation 0.566 13 Poor professional relations 0.560 14 Poor safety conditions 0.537 15
4.4.4.3 Recommended Strategies to Minimize Variation Orders
The frequency of recommended strategies to minimize variation orders on building projects
was identified using a 5 point Likert scale, namely Unimportant = 1; Less important = 2;
Important = 3; Very important = 4; and Very high important = 5.The impact of variation
orders were ranked by comparing their relative index.
I. Clients Group
From Table 4.18, it was possible to rank the recommended strategies to minimize variation
by comparing their RI. According to the client, the most ranked recommended strategy was
drawings should be complete at tender stage (RI=0.933) followed by carry out detail site
investigation including detail soil investigations and consider it during tendering stage
(RI=0.867). Adequate planning in advance is required by all involved parties before works
start on site come next (RI=0.844). The recommended strategy to have the land application or
land purchase completed and finalized before awarding contracts and once the tender is
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 59 Addis Ababa Institute of Technology
awarded, make no changes to the specifications with equal value (RI=0.667) were the least
ranked recommendation to minimize variation orders.
Table 4.18: Frequency of recommended strategies from the clients group
Recommended Strategies to Minimize V.O RI of Client
Ranking
Complete the drawings at tender stage 0.933 1
Carry out detail site investigation including detail soil investigations and consider it during tendering stage 0.867
2
All involved parties should plan adequately before works start on site 0.844
3
The consultant should produce a concluding design and contract documents 0.822
4
Spend adequate time on pre-tender planning phase 0.822 5
The consultant should co-ordinate closely at design stage 0.822 6
Supervise the works with an experienced and dedicated supervisor 0.822
7
Place experienced and knowledgeable executives in the engineering and design department 0.822
8
Consultants should ensure that the design/specifications fall within the approved budget 0.800
9
Clients should provide a clear brief of the scope of works 0.756 10
All parties should forecast unforeseen situations 0.756 11
Enhance communication between all parties 0.756 12
Get accurate information and research with regard to procurement procedure, material and plant 0.733
13
Once the tender is awarded, make no changes to the specifications 0.667
14
Have the land application or land purchase completed before awarding contracts 0.667
15
II. Consultants Group
From Table: 4.19 below, the most ranked recommended strategy to minimize variation
according to respondents of this category is adequate planning in advance is required by all
involved parties before works start on site (RI=1.00). The next recommendations were to
enhance communication between all parties, works should be supervised with an experienced
and dedicated supervisor and carry out detail site investigation including detail soil
investigations and consider it during tendering stage came next with equal value (RI=0.950).
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 60 Addis Ababa Institute of Technology
Once the tender is awarded, there should be no changes to the specifications was the least
ranked recommendation to minimize variation orders according to the consultants (0.650).
Table 4.19: Frequency of recommendations from the consultants group
Recommended Strategies to Minimize V.O RI of
Consultant
Ranking All involved parties should plan adequately before works start on site 1.000
1
Enhance communication between all parties 0.950 2 Supervise the works with an experienced and dedicated supervisor 0.950
3
Carry out detail site investigation including detail soil investigations and consider it during tendering stage 0.950
4
The consultant should produce a concluding design and contract documents 0.900
5
Complete the drawings at tender stage 0.900 6
Spend adequate time on pre-tender planning phase 0.900 7
The consultant co-ordinate closely at design stage 0.900 8
Consultants should ensure that the design/specifications fall within the approved budget 0.900
9
Place experienced and knowledgeable executives in the engineering and design department 0.900
10
Clients should provide a clear brief of the scope of works 0.850 11 Get accurate information and research with regard to procurement procedure, material and plant 0.850
12
Have the land application or land purchase completed before awarding contracts 0.800
13
All parties should forecast unforeseen situations 0.750 14 Once the tender is awarded, make no changes to the specifications 0.650
15
III. Contractors Group
As shown in Table: 4.20 below, the most ranked recommendation to minimize variation
according to the contractors was adequate planning in advance is required by all involved
parties before works start on site (RI=0.905) followed by the consultant should produce a
concluding design and contract documents (RI=0.863) and then enhance communication
between all parties (RI=0.842). According to these respondents, once the tender is awarded,
there should be no changes to the specifications (RI=0.621) was the least ranked
recommendation to minimize variation orders.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 61 Addis Ababa Institute of Technology
Table 4.20: Frequency of recommendations from the contractors group
Recommended Strategies to Minimize V.O RI of Contractor
Ranking
All involved parties should plan adequately before works start on site 0.905
1
The consultant should produce a concluding design and contract documents 0.863
2
Enhance communication between all parties 0.842 3
The consultant should co-ordinate closely at design stage 0.832 4
Supervise the works with an experienced and dedicated supervisor 0.821
5
Consultants should ensure that the design/specifications fall within the approved budget 0.821
6
Place experienced and knowledgeable executives in the engineering and design department 0.821
7
All parties should forecast unforeseen situations 0.811 8
Get accurate information and research with regard to procurement procedure, material and plant 0.811
9
Complete the drawings at tender stage 0.789 10
Clients should provide a clear brief of the scope of works 0.789 11
Spend adequate time on pre-tender planning phase 0.779 12
Carry out detail site investigation including detail soil investigations and consider it during tendering stage 0.779
13
Have the land application or land purchase completed before awarding contracts 0.747
14
Once the tender is awarded, make no changes to the specifications 0.621
15
The spearman’s correlation coefficient is calculated using Equation 3.2 and tabulated as
shown below in Table 4.21. The summarized spearman correlation coefficient indicates that
there is a strong correlation between all the three groups. This means that most of the
respondents have the same perception on the recommended strategies to minimize variation
orders.
Table 4.21: Summary of correlation test on the ranking of recommendations
Respondents Rho(cal) = 1 – 6x(∑di2)
N x (N2 –1)
Relation of the respondents
Client Vs Consultant 0.997 strong
Consultant Vs Contractor 0.998 strong
Client Vs Contractor 1.000 strong
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 62 Addis Ababa Institute of Technology
IV. Overall Responses
From Table: 4.22, it was possible to rank the recommended strategy to minimize variation
orders. The most raked strategy by all respondents were adequate planning in advance is
required by all involved parties before works start on site (RI=0.900) followed by the
consultant should produce a concluding design and contract documents (RI=0.856).
Drawings should be complete at tender stage (RI=0.844) was the next. According to all the
respondents, the least ranked strategy was once the tender is awarded, there should be no
changes to the specifications (RI=0.638).
Table 4.22: Overall frequency of recommendations to minimize variation orders
Recommended Strategies to Minimize V.O Overall
RI
Ranking All involved parties should plan adequately before works start on site 0.900
1
The consultant should produce a concluding design and contract documents 0.856
2
Complete the drawings at tender stage 0.844 3
The consultant should co-ordinate closely at design stage 0.838 4
Supervise the works with an experienced and dedicated supervisor 0.838
5
Enhance communication between all parties 0.831 6 Place experienced and knowledgeable executives in the engineering and design department 0.831
7
Consultants should ensure that the design/specifications fall within the approved budget 0.825
8
Carry out detail site investigation including detail soil investigations and consider it during tendering stage 0.825
9
Spend adequate time on pre-tender planning phase 0.806 10
Get accurate information and research with regard to procurement procedure, material and plant 0.794
11
Clients should provide a clear brief of the scope of works 0.788 12
All parties should forecast unforeseen situations 0.788 13
Have the land application or land purchase completed before awarding contracts 0.731
14
Once the tender is awarded, make no changes to the specifications 0.638
15
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 63 Addis Ababa Institute of Technology
4.6 Discussion of Findings
This section presents the discussion of the study findings from the questionnaires, the desk
study and the interview. The cause of variation orders, impact of variation orders and
recommendations to minimize variation orders are discussed.
4.6.1 Causes of Variation Orders in Public Building Projects
From the questionnaires, the desk study and interview, the common causes of variation orders
on public building projects were design changes and incomplete contract documents, which
resulted from numerous additional works. The causes of variation orders were ranked in
ascending order and the most frequent were identified.
As ranked on questionnaires response previously in Table 4.12 it is clear that the first most
causes of variation orders were impediment in prompt decision making process, change in
design by the consultant, inadequate working drawing details, change in specifications, and
poor procurement process.
The first major cause of variation orders was change in design by the consultant. This could
also be caused due to the client change of mind. Design change is indeed one of the most
causes of variation orders and this fact is supported by the interviewees and the observations
in the desk study. This similarly confirms with the literature review that design change was
one of the major causes of variation orders. As Ming et al. (2004) identified design change
was the major causes of variation orders. The works of Ruben (2008) also listed that design
change was one of the most causes of variation orders.
Incomplete contract document was the second major cause of variation orders. This occurs
due to the client or the consultant work before tendering and it increases the project cost or
schedule. Contract documents of most public projects done by the clients and it could be
difficult to prepare a complete document because they are busy of work.
The third major cause of variation order was impediment in prompt decision making process,
which is due to lack of judgment by the client or the consultant. There is no doubt that lack o
decisions delay the project and causes the contractors to re-design the requirements,
reschedule, their works and material procurement which would have an adverse impact on the
project.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 64 Addis Ababa Institute of Technology
Inadequate working drawing details was the fourth major cause of variation order which is
the out-come of the consultant. A well detailed working drawing is believed to decrease
variation orders. Most professionals argue that a detailed working drawing should be
prepared before the tender stage.
The fifth major cause of variation order was change in specifications which confirms with the
literature review and the interview. In a design stage, it could be a failure to change the
specification due to change of mind of the client or the consultant which results in variation
orders. Consequently change in specifications can be the major cause. As reviewed in the
literature part of this research Ruben (2008) listed that change in specifications among the
major causes. Contrarily this was not the major causes in the desk study.
4.6.2 Impact of Variation Orders on Public Building Projects
According to the findings from the desk studies, completion schedule delay and increase in
project cost are the most common impacts of variation orders. It was not unexpected for the
project cost to increase due to frequent variations in the project. These impacts are also
repeated on the questionnaire responses as shown and ranked previously in Table 4.17.
As it was found from the interview, completion schedule delay, increase in project cost, and
disputes among parties were the most predominant impacts of variation orders.
From the responses of the questionnaire, completion schedule delay, increase in project cost,
additional payments for contractor, progress is affected and increase in overhead expense were the
most impacts of variation orders.
Completion schedule delay was the first major impact of variation orders in public building
projects. According to the findings from the desk studies and the interview, completion
schedule is the common impact on public building projects that increases the consistency of
the response to conclude. Previously (Ibbs, 1997a) pointed out that completion schedule
delay was a frequent result of variations in construction projects. This confirmed that
variations impact the project adversely, leading to delays in the project completion.
The second major impact of variation orders was increase in project cost on public building
projects which similarly confirms with the findings from the desk study and interview.
Completion schedule delay and increase in project cost are also the major impacts as
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 65 Addis Ababa Institute of Technology
reviewed in the literature part. For example Koushki (2005) found that variation orders
impacted both the completion time and costs of projects. These impacts were due to
detrimental variation orders since they negatively impacted the client’s value. Any major
additions or alterations in the design may eventually increase the project cost. It was not
unexpected for the project cost to increase due to frequent variations in the project. This was
because the variation orders may impact the project's total direct and indirect costs.
Therefore, any major addition or alteration in the design may eventually increase the project
cost. The findings from the respondents were also consistent with the observations from the
desk study and interviews.
As the responses found from the questionnaire, additional payments for the contractor was
the third major impact of variation orders. Additional payment for the contractor is the
common impact when variation is ordered. As O’Brien (1998) described, variations are
considered to be a common source of additional works for the contractor. This is because as
the volume of work increases, payment to the contractor increases when the varied items are
measured. This adds value to the contractor.
The fourth major impact was the effect on the progress. This impact was not uncommon that
project progress can be affected due to variations. Since variation management passes
through different processes, most clients do not approve variation orders on time and the
contractor refuses to continue the work. The contractor can also need new materials, new
equipments and specialized man power. These affect the project progress.
The fifth major impact of variation orders on public building projects was the increase in
overhead expenses. This cost can be incurred directly or indirectly during the process and
implementation of variation orders. Because the overhead expenses for all involved parities
will increase as lots of professional and paper works need to be done. Arguably, the more the
variation orders, the more likely they increase the overhead expenses especially to the
contractor that impact public building projects.
4.6.3 Recommended Strategies to Minimize Variation Orders
According to the findings from the interview, the suggested recommendations by the
interviewee were to carry out detail site investigation before tendering, to produce a complete
design and contract documents, there should be communication between the parties, and
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 66 Addis Ababa Institute of Technology
works should be supervised with a dedicated supervisor. These recommendations were also
mostly ranked on the questionnaires response. As the interviewee pointed out, preparing
complete detail drawings can reduce the risk of variation. Open communication among all
parties involved in the project is the key to reduce variations. Experienced and dedicated
supervisors can also reduce variation orders since they are not careless on the works they are
assigned.
According to the findings from the questionnaires ranked previously in Table 4.22 and the
interview conducted, the first most recommended strategy was consultants should produce a
concluding design and contract documents. The controls for the frequent change in design by
consultant, and inadequate working drawing details would be through systematic detailing of
design. This would provide an opportunity for the consultant to review and finalize the design
during the design phase.
Completing drawings at tender stage was the second most recommended strategy to minimize
variation orders. Any change or modification made later will result in an additional works
which leads to variations. The design team should submit complete design for tendering. This
would assist in reducing the occurrence of variations during the construction phase where the
impact of variations can be severe on the project.
The third most recommended strategy was works should be supervised with an experienced
and dedicated supervisor. This was because experienced supervisors can forecast what will
happen on site through their past experience. They are also decision makers comparing the
design and the actual site condition on the right time. Experienced supervisors are also
responsible for their job and this surely helps to minimize variation orders on site.
Enhancing communication between all involved parties was the fourth most recommended
strategy to minimize variation orders. Different parties involved in a project work differently,
so a clear communication between the parties is necessary. This was because communication
can increase project performance during the execution of a project.
The fifth most recommended strategy was to carry out detail site investigation including
detail soil investigation and considering it during tendering. This was because the design and
construction methodology varies from one site to the other. Even the same type of projects
cannot be executed with the same cost and schedule due to difference in site conditions.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 67 Addis Ababa Institute of Technology
CHAPTER FIVE
CONCLUSION AND RECOMMENDATIONS
5.1 Conclusion
5.1.1 Causes of variation orders on public building projects in Addis Ababa
The first objective of the study was to analyze the causes of variation orders on public
building projects in Addis Ababa. The desk study of the five projects confirmed that the most
frequent causes of variation orders on public building projects was design changes.
According to the interview made between three selected construction practitioners involved
in public building projects they pointed out that the main cause of variation orders was design
changes.
Among 38 causes of variation orders, the responses received from the clients’ showed that
impediment in prompt decision making process, change in design by the consultant, errors
and omissions in design, inadequate working drawing details, and unforeseen problems were
the top five most frequent causes of variation orders on public building projects.
According to the consultants’, the top five most frequent causes of variation orders on public
building projects were change in economic conditions, unforeseen problems, change of plans
or scope, change in specifications, and poor procurement process.
Regarding the contractors’, the top five most frequent causes of variation orders on public
building projects were lack of communication, inadequate working drawing details,
impediment in prompt decision making process, poor procurement process, and change in
design by the consultant.
From the overall responses, it was concluded that impediment in prompt decision making
process, change in design by the consultant, inadequate working drawing details, change in
specifications, and poor procurement process were the most important causes of variation
orders on public building projects. And there was a strong correlation between ranking by
client and consultant, client and contractor as well as consultant and contractor. This
confirmed that most of the respondents have the same perception about the causes of
variation orders on public building projects.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 68 Addis Ababa Institute of Technology
From the findings of the desk study, interview and questionnaire, change in design,
incomplete contract documents, impediment in prompt decision making process, inadequate
working drawing details, and change in specifications were the major causes of variations.
5.1.2 Impact of variation orders on public building projects in Addis Ababa
The second objective was to identify the various impacts of variation orders on public
building projects in Addis Ababa. The study found that variation orders had an impact on
public building projects. From the desk study of five projects, project A, project B, project C,
project D and project E were exposed to variation orders amounting to 15.95%, 6.78%,
8.20%, 19.60% and 8.87% of the contract amount respectively. According to the data from
the desk study, increase in project cost was the major impact on public building projects. The
interviewee indicated that variation orders adversely impacted costs.
As it was analyzed from the desk study, project A, project B, project C, project D and project
E experienced time overruns to 47.22%, 41.67%, 35.63%, 40.83% and 52.78% of the
contract schedule respectively. The interviewee also pointed out that variation order also
impacts the completion schedule of public building projects. It was argued that variation
orders contributed to time overruns.
From the 15 impacts of variation orders, completion schedule delay, increase in project cost,
additional payments for contractor, disputes among professionals, and effect on progress
were the top five most frequent impacts of variation orders according to the responses of the
clients’.
As consultants’ responded, the top five most frequent impacts of variation orders were
increase in project cost, delay in payment, completion schedule delay, effect on progress, and
increase in overhead expenses.
According to the responses of the contractors’, completion schedule delay, increase in project
cost, effect on progress, additional payments for contractor, and increase in overhead
expenses were the top five most frequent impacts of variation orders on public building
projects.
From the overall responses received, it was concluded that the top most impacts of variation
orders on public building projects were completion schedule delay, increase in project cost,
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 69 Addis Ababa Institute of Technology
additional payments for contractor, effect on progress, and increase in overhead expenses.
The correlation between ranking by client and consultant, client and contractor as well as
consultant and contractor was strong. This indicated that most of the respondents have the
same perception about the impact of variation orders on public building projects.
From the findings of the desk study, interview and the questionnaires, the major impacts of
variation orders on public building projects were completion schedule delay, increase in
project cost, additional payments for the contractor, effect on progress, and increase in
overhead expenses.
5.1.3 Recommended strategies to minimize variation orders
The third objective was to suggest recommendations to minimize variation orders on public
building projects in Addis Ababa. From the literatures, fifteen (15) strategies to minimize
variation orders on building projects were identified. No recommended strategies were found
from the document study and conclusion was based on the questionnaire survey and the
interview to be able to suggest recommendations to minimize variation orders.
From the interview, it was repetitively suggested that designs and contract documents should
be complete at the tender stage to minimize the occurrence of variation orders on public
building projects.
The clients’ responded that drawings should be complete at tender stage to minimize
variation orders on building projects. Eventually, this may aid in eliminating the occurrence
of variations, arising from errors and design discrepancies, during the construction stage
where the impact of the variations can be severe.
The consultants’ and the contractors’ response argued on the strategy that states adequate
planning in advance is required by all involved parties before works start on site to minimize
variation orders. This was because a well planned project can eliminate variations that may
arise due to lack of pre-project planning.
From the interview and overall responses received, it was therefore concluded that the
following best five strategies were recommended to minimize variation orders on public
building projects:
The consultant should produce a concluding design and contract documents
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 70 Addis Ababa Institute of Technology
Drawings should be complete at tender stage
Works should be supervised with an experienced and dedicated supervisor
Enhance communication between all parties
Carry out detail site investigation including detail soil investigations and consider it
during tendering stage
5.2 Recommendations
This research focused on the assessment of variation orders in a few contracts of public
building projects undertaken by city government of Addis Ababa. Based on the focused
sector and how variation is minimized, the recommendations of this thesis are as follows:
An understanding of the causes of variation orders would be helpful for building
professionals in assessing variation orders.
The client should allow sufficient time to prepare an elaborately detailed project brief.
This will eliminate frequent variations to the original plan of the project due to client
change of mind.
Variations can be minimized if consultants produce a complete design as change of
design was the major cause of variations in public building projects.
Direct communication among the project team is a key to eliminate variations occur
due to communication gap during design and execution phase.
Consultants should give sufficient time for planning and design phase, this will assist
in minimizing variation orders due design changes at construction stage.
A detailed design would be able to exert control to unnecessary interference from
consultants or other external influences.
The consultants should prepare completed contract document before the tendering
stage. This minimizes variation orders occur due to change of specifications.
Contractors should identify and inform the varied item of work to the client before the
activity starts to reduce variations. Because the client will have sufficient time to
check the varied item in different perspectives to give work order at minimum
variations.
There should be improvement in project management, and improved decision making
process on the part of the client during project execution stage so as to minimize the
occurrence of variation orders.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 71 Addis Ababa Institute of Technology
The study would assist professionals in taking proactive measures for minimizing
variation orders in building projects.
The results of this research should help construction practitioners, policy makers and
researchers in the field of construction management.
Further areas of research recommended are as follows;
Since this study focused on public building projects, it would be interesting to study
the impact of variation orders in other building projects and compare the results.
A more elaborative investigation into the contract conditions is needed with the view
to minimizing impact of variation orders in public building projects.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 72 Addis Ababa Institute of Technology
REFERENCES
Acharya, K., Lee, D., & Im, M. 2006, ‘Design Errors: Tragic for the Clients’, Journal of
Construction Research, vol. 7, no.1/2, pp. 177-190
Al-Hakim, L. 2005a, 'Identification of Waste Zones Associated with Supply Chain
Integration', Annual Conference and Exhibition, ISNB vol. 1, no. 5, pp. 1-13, Sun City, South
Africa
Al-Hakim, L. 2005b, 'Waste Identification: A Supply Chain Strategy Perspective',
International Conference on Business and Information, Hong Kong
Al-Hammad, M. and Assaf, S.A. (1992) Design-Construction interface problems in Saudi
Arabia, Journal of Building Research and Information, vol.20, no.1, pp. 60-63.
American Institute of Architects, (1987), General conditions of the contract for construction,
AIA Document A 201, Washington DC.
Arain F.M. and Pheng L.S. (2005): The Potential Effects of Variation Orders on Institutional
Building Projects, Journal of Facilities, Vol 23 No 11/12, 2005, pp 496-510
Or AAiT, Civil and Environmental Engineering Department: Tell: +251-111 23 24 37 Fax: +251-111 23 94 80 E-mail: [email protected]
Supervisor: Associate Professor Wubishet Jekale Mengesha (Dr.-Ing) E-mail: [email protected]
This research study titled “Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa” is undertaken by Andualem Endris at the Addis Ababa Institute of Technology, Civil and Environmental Engineering Department to assess the impact of variation orders on public building projects. Please answer all questions.
Thanks in advance for your co-operation and help! Sincerely,
Andualem Endris
August 2013
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 78 Addis Ababa Institute of Technology
SECTION A: ORGANIZATION AND RESPONDENT’S PROFILE
1. Which of the following best describes your company?
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 79 Addis Ababa Institute of Technology
SECTION B: CAUSES OF VARIATION ORDERS
Please indicate your level of agreement with the following questions on a scale 1 to 5.
Never Always
1 2 3 4 5
Indicator: 1 = Never
2 = Seldom
3 = Sometimes
4 = Often
5 = Always
2. The following are examples of causes of variation orders. Based on your experience,
indicate how frequently each of them occurs on public building projects.
S.N Causes of Variation Orders Never Always 1 2 3 4 5
1 Change of plans or scope 2 Change of schedule 3 Inadequate project objectives 4 Impediment in prompt decision making process 5 Change in specifications 6 Change in design by the consultant 7 Errors and omissions in design 8 Conflicts between contract documents 9 Technology change 10 Lack of coordination 11 Design complexity 12 Inadequate working drawing details 13 Consultant's lack of judgment and experience 14 Lack of consultant's knowledge of available materials
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 80 Addis Ababa Institute of Technology
S.N Causes of Variation Orders (continued) Never Always 1 2 3 4 5
15 Honest wrong beliefs of consultant 16 Consultant's lack of required data 17 Design discrepancies 18 Non-compliant design with government regulations 19 Non-compliant design with owner's requirement 20 Lack of contractor's involvement in design 21 Unavailability of skills 22 Contractor's desired profitability 23 Differing site conditions 24 Defective workmanship 25 Unfamiliarity with local conditions 26 Lack of a specialized construction manager 27 Fast track construction 28 Poor procurement process 29 Lack of communication 30 Honest wrong beliefs of contractor 31 Lack of strategic planning 32 Contractor's lack of required data 33 Weather conditions 34 Health and safety considerations 35 Change in government regulations 36 Change in economic conditions 37 Socio-cultural factors 38 Unforeseen problems If any other causes of variation orders, please
specify Never Always 1 2 3 4 5
41 42 43 44 45 46 47 48 49 50
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 81 Addis Ababa Institute of Technology
SECTION C: IMPACT OF VARIATION ORDERS
Please indicate your level of agreement with the following questions on a scale 1 to 5.
No impact Very high impact
1 2 3 4 5
Indicator: 1 = No impact
2 = Low impact
3 = Medium impact
4 = High impact
5 = Very high impact
3. Following are list of impact variation orders. From your experience, what is the impact of
variation orders on building projects?
S.N Impact of Variation Orders No Very high impact impact 1 2 3 4 5
1 Increase in project cost 2 Progress is affected 3 Increase in overhead expenses 4 Delay in payment 5 Quality degradation 6 Productivity degradation 7 Procurement delay 8 Rework and demolition 9 Logistics delays
10 Blemish firm’s reputation 11 Poor safety conditions 12 Poor professional relations 13 Additional payments for contractor 14 Disputes among professionals 15 Completion schedule delay
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 82 Addis Ababa Institute of Technology
If any other impact of variation orders, please specify
No Very high impact impact 1 2 3 4 5
16 17 18 19 20 21 22 23 24 25
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 83 Addis Ababa Institute of Technology
SECTION D: RECOMMENDATIONS TO MINIMIZE VARIATION ORDERS
Please indicate your level of agreement with the following questions on a scale 1 to 5.
Unimportant Very important
1 2 3 4 5
Indicator: 1 = Unimportant
2 = Less important
3 = Important
4 = Very important
5 = Very high important
4. Following are suggested strategies or recommendations used to minimize variation
orders. From your experience, what is the best strategy action can be taken to minimize
variation orders on building projects?
S.N Recommendations to minimize variation orders Un important Very High
important 1 2 3 4 5
1 All involved parties should plan adequately before works start on site
2 The consultant should produce a concluding design and contract documents
3 Complete the drawings at tender stage 4 Spend adequate time on pre-tender planning phase 5 Clients should provide a clear brief of the scope of works 6 All parties should forecast unforeseen situations 7 The consultant should co-ordinate closely at design stage 8 Enhance communication between all parties 9 Supervise the works with an experienced and dedicated
supervisor
10 Consultants should ensure that the design/specifications fall within the approved budget
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 84 Addis Ababa Institute of Technology
S.N Recommendations to minimize variation orders (continued) Un important Very high
important 1 2 3 4 5
11 Get accurate information and research with regard to procurement procedure, material and plant
12 Carry out detail site investigation including detail soil investigations and consider it during tendering stage
13 Have the land application or land purchase completed before awarding contracts
14 Once the tender is awarded, make no changes to the specifications
15 Place experienced and knowledgeable executives in the engineering and design department
If you have any other recommendations to minimize variation orders, please specify
Un important Very high important
1 2 3 4 5 16 17 18 19 20 21 22 23 24 25
Thank You!
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 85 Addis Ababa Institute of Technology
APPERNDIX B: List of Public Building Projects for the Study (Taken from Addis Ababa Housing Development and Construction Bureau (2012))
S.N Projects Building Height
Client Consultant Contractor Remarks
1 Addis Ababa City Administration Education bureau
G+12 AAHDCB MGM PLC AMB Con. PLC Selected for desk study
2 Addis Credit and Savings institution, HQ G+7 AAHDCB AAHDCB AMB Con. PLC Selected for desk study
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 92 Addis Ababa Institute of Technology
APPERNDIX I: Clients’ responses for strategies to minimize variation orders
Factor Description
Frequency Analysis (FA)
Un
impo
rtan
t
Les
s Im
port
ant
Impo
rtan
t
Ver
y im
port
ant
Ver
y h
igh
impo
rtan
t
Complete the drawings at tender stage 0 0 0 3 6
Carry out detail site investigation including detail soil investigations and consider it during tendering stage 0 0 1 4 4
All involved parties should plan adequately before works start on site 0 0 1 5 3 The consultant should produce a concluding design and contract documents 0 0 3 2 4 Spend adequate time on pre-tender planning phase 0 1 1 3 4 The consultant should co-ordinate closely at design stage 0 0 2 4 3 Supervise the works with an experienced and dedicated supervisor 0 0 1 6 2
Place experienced and knowledgeable executives in the engineering and design department 0 0 1 6 2 Consultants should ensure that the design/specifications fall within the approved budget 0 1 0 6 2 Clients should provide a clear brief of the scope of works 0 1 3 2 3 All parties should forecast unforeseen situations 0 0 3 5 1 Enhance communication between all parties 0 0 4 3 2 Get accurate information and research with regard to procurement procedure, material and plant 0 0 6 0 3 Once the tender is awarded, make no changes to the specifications 0 1 4 4 0 Have the land application or land purchase completed before awarding contracts 0 3 3 0 3
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 93 Addis Ababa Institute of Technology
APPERNDIX J: Consultants’ responses for strategies to minimize variation orders
Factor Description
Frequency Analysis (FA)
Un
impo
rtan
t
Les
s Im
port
ant
Impo
rtan
t
Ver
y im
port
ant
Ver
y h
igh
impo
rtan
t
All involved parties should plan adequately before works start on site 0 0 0 0 4 Enhance communication between all parties 0 0 0 1 3 Supervise the works with an experienced and dedicated supervisor 0 0 0 1 3 Carry out detail site investigation including detail soil investigations and consider it during tendering stage 0 0 0 1 3 The consultant should produce a concluding design and contract documents 0 0 0 2 2 Complete the drawings at tender stage 0 0 0 2 2 Spend adequate time on pre-tender planning phase 0 0 1 0 3 The consultant co-ordinate closely at design stage 0 0 0 2 2 Consultants should ensure that the design/specifications fall within the approved budget 0 0 1 0 3 Place experienced and knowledgeable executives in the engineering and design department 0 0 0 2 2 Clients should provide a clear brief of the scope of works 0 0 1 1 2 Get accurate information and research with regard to procurement procedure, material and plant 0 0 0 3 1 Have the land application or land purchase completed before awarding contracts 0 0 1 2 1
All parties should forecast unforeseen situations 0 0 2 1 1 Once the tender is awarded, make no changes to the specifications 0 0 3 1 0
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 94 Addis Ababa Institute of Technology
APPERNDIX K: Contractors’ responses for strategies to minimize variation orders
Factor Description
Frequency Analysis (FA)
Un
impo
rtan
t
Les
s Im
port
ant
Impo
rtan
t
Ver
y im
port
ant
Ver
y h
igh
impo
rtan
t
All involved parties should plan adequately before works start on site 0 1 2 2 14 The consultant should produce a concluding design and contract documents 0 1 3 4 11 Enhance communication between all parties 0 2 1 7 9
The consultant should co-ordinate closely at design stage 1 0 1 10 7 Supervise the works with an experienced and dedicated supervisor 2 1 1 4 11 Consultants should ensure that the design/specifications fall within the approved budget 0 1 4 6 8 Place experienced and knowledgeable executives in the engineering and design department 1 1 1 8 8 All parties should forecast unforeseen situations 0 1 3 9 6 Get accurate information and research with regard to procurement procedure, material and plant 0 1 5 5 8 Complete the drawings at tender stage 0 2 5 4 8 Clients should provide a clear brief of the scope of works 1 0 6 4 8 Spend adequate time on pre-tender planning phase 1 1 5 4 8 Carry out detail site investigation including detail soil investigations and consider it during tendering stage 1 2 3 5 8 Have the land application or land purchase completed before awarding contracts 1 2 6 2 8 Once the tender is awarded, make no changes to the specifications 3 5 3 3 5
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 95 Addis Ababa Institute of Technology
APPERNDIX L: Thesis Proposal
ASSESSING THE IMPACT OF VARIATION ORDERS
ON PUBLIC BUILDING PROJECTS IN ADDIS ABABA
by
Andualem Endris Yadeta
Thesis Proposal submitted to Addis Ababa University, Addis Ababa Institute
of Technology in partial fulfillment of the requirements for the degree
Of
Master of Science
In
Civil Engineering
(Construction Technology & Management)
Under the Supervision of Dr.-Ing Wubishet Jekale
JANUARY 2012
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 96 Addis Ababa Institute of Technology
A B S T R A C T
Many building projects are exposed to variations. This study will investigate the impact of
variation orders on public building projects in Addis Ababa in order to take proactive
measure to minimize or appropriately manage it. The study will have the following
objectives, namely (1) to determine the causes of variation orders; (2) to determine the
impacts of variation orders; and (3) to recommend strategies to minimize variation orders.
Literatures relative to the research area will be extensively reviewed. The data gathering
approaches will include desk study, interviews and questionnaire to collect both qualitative
and quantitative data. Statistical data analysis and interpretations will be used and finally the
result will be concluded and recommended to all stakeholders.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 97 Addis Ababa Institute of Technology
Background of the Study
Construction contract is a business agreement that is subjected to variability. Contractual
clauses relating to changes allow parties involved in the contract to freely initiate variation
orders within the ambit of the scope of the work without alteration the original contract
(Adnan et al., 2010) sited in Harbans (2003). Even if carefully planned, it is likely that there
will be changes to the scope of the contract as the work progresses (Adnan et al., 2010).
Variations and conflicts in a construction projects, at work, and even in our daily lives are
very common. Any addition, deletion, or any other revision to project goals and scope of
work are considered to be variation, whether they increase or decrease the project cost or
schedule (Adnan, 2010). A change in construction projects refers to an alteration to design,
building works, project programs or project aspects caused by modifications of preexisting
conditions, assumptions, or requirements (Adnan, 2010).
Various studies have revealed that variation orders contribute to cost overruns. A study of the
effects of variation orders on institutional building projects revealed that variation orders
contributed substantially to increase in construction project costs (Ruben and Theo, 2008). It
was found that variation orders issued during various phases of construction projects
negatively affected both the completion time and costs of projects (Ruben and Theo, 2008).
In developing countries like Ethiopia, its potential impact leads to unnecessarily increase the
cost of construction without adding value to the project. The construction sector in Ethiopia is
considered one of the crucial economical sectors. This sector is subjected to a very difficult
situation since the increase of the sector. There are many public building projects in Addis
Ababa and they have been constructing now. Many of the projects are either on hold or
subjected to major variations due to shortage of construction materials, increase in
construction materials cost, shortage of modern construction equipment, lack of skilled
manpower. So this thesis aims to assess the impact of variation orders on Addis Ababa public
building projects.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 98 Addis Ababa Institute of Technology
Statement of the Problem
Nowadays, variation orders have become a common problem in public building projects in
Addis Ababa. Variation orders are issued to correct or modify the original scope of work
because changes during construction of projects are unavoidable. The major causes of delay,
disputes and sometimes generate significant cost and environmental impacts are variation
orders issued during construction of projects. Yet, no unique method is available for
minimizing variation orders effectively. However, their impact can be minimized with an
appropriate study about the causes. Variation orders on public building projects have the
potential to impact public building projects, and the identification of their causes might lead
to their reduction, possible elimination and subsequent improvement in overall performance
of public building projects.
Review of Literatures
Construction project is a mission, undertaken to create a unique facility, product or service
within the specified scope, quality, time and cost. In practice, however, some construction
projects encounter variation, delay on completion time or poor workmanship upon
completion.
The one thing certain on any project is that there will be variations occurring along the way
sometimes even before the signing of the contract. Variations are inevitable in any
construction projects (Ibbs et al., 2001). Nothing is more constant than variation during the
course of a construction project. Despite the best efforts of all concerned during the planning,
implementation and administration of the contract, variation will almost certainly occur. The
variations and variation orders can be deleterious in any project, if not considered collectively
by all participants (Arain and Low, 2005). The most frequent type of variation met in
building projects are variations to the original scope of work or those that arise from
unexpected conditions in the field. Even two buildings of same design, that is very similar,
have differences caused by the terrain, existing utilities, or other factors such as subsurface
conditions. Basically variation orders are acceptable as part of the contract administration
process.
Further, the human behavior of parties to the contract cannot be predicted. Variation orders
may arise from changes in the minds of parties involved in the contract. Variation orders may
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 99 Addis Ababa Institute of Technology
be initiated either by clients or by contractors (Adnan, et al., 2010). A study that focused on
the points of view of developers of potential causes of variation orders suggested four main
root agents of variation orders (Arain and Pheng, 2006). These agents included clients,
consultants, contractors and unspecified “others”.
If variation orders are frequent, they may potentially affect the quality of works. Hanna et al.
(2002) indicated that contracts with a significant degree of risk for unknown variables such
for example lump sum, contractors may cut corners on quality and quantity to maximize
profits. Quality of works may be compromised as contractor may try to compensate for the
losses as they are not optimistic at about cost recovery. Moreover; variation order occurrence
can lead to revision of health and safety considerations.
Ruben and Theo (2008) remarked that disputes between the client and the contractor can
occur if variation orders are not managed carefully. Harbans (2003) warned that unless a
mutually acceptable solution is agreed by the parties, valuation of variations in the form of
variation orders will continue to remain at the forefront of disputes and claims making their
way ultimately to arbitral tribunals or the corridors of justice. Ssegawa et al. (2002) found
that a large proportion of current arbitrations were on claims for additional time and
additional expenses. He reported that more than one-third of disputes pertained to how to
determine losses that stem from variation orders.
Research Objectives
The objectives of the study will be:
To determine the causes of variation orders;
To identify the impacts of variation orders; and
To recommend strategies to minimize variation orders.
Research Questions
From the objectives of the study, formulating and answering the following research questions
will define the overall purpose:
What are the causes of variation orders?
What are the impacts of variation orders?
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 100 Addis Ababa Institute of Technology
How can we minimize variation orders?
Research Methodology
The research methodology is structured as follows:
Literature and previous studies related to the area of research will be extensively
reviewed.
The research design is based on a purposive sampling selection process in terms of which
a representative sample of stakeholders/participants in the construction process of public
building will be surveyed and a selection of similar public building projects from which
to derive further data on variation orders. In particular, case studies, interviews with
relevant parties such as site and head office management of public institutions, self-
administered surveys and examination of public project documentation and records will
form the basis of the research methodology.
The gathered data will be analyzed using the appropriate statistical analysis tools. Both
quantitative and qualitative methods will be used.
Then conclusions will be drawn from the analyzed data and recommendations for improvement
and future study will be formulated.
Assessing the Impact of Variation Orders on Public Building Projects in Addis Ababa: M.Sc Thesis
Addis Ababa University 101 Addis Ababa Institute of Technology
Work Schedule
No
Task
Duration (in weeks): February- July
Feb 2012 Mar 2012 April 2012 May 2012 June 2012 July 2012