-1- IMPACTS OF FAST-TRACK PROJECT DELIVERY IN CURRENT CONSTRUCTION INDUSTRY Ahmed Rushdhie (0924137) School of Technology, University of Wolverhampton, Wolverhampton, WV1 1LY, UK ABSTRACT The effort of this research is to identify the impact of construction fast tracking. The benefits and challenges of this procedural method are really to affect a construction project in terms of time and money. Procurement systems play a dynamic role in this procedure. Somehow, fast-tracking a construction have to be conducted with (possible) risks to be taken as they are inevitable in the process. Challenges of fast tracking should be considered at the initial stage of construction and the needs of this method should be clearly defined by the developers. The client has to be made fully aware about tackling any unforeseen situation that may occur during the construction. The online questionnaire was disseminated to only two types of respondents who are contractors and developers. The key part of this research will be identified through rating and weighed rating average of the classified result. This study came with a number of key definitions: Saving money, team building and short schedule are the key benefits of fast track construction. Design and build and partnering are the most suitable procurement system for this procedural method. “Reduced time” is the most valuable benefit of construction fast tracking. This method is more suitable to prepare short scheduling as well because of its overlapping procedure. The main conclusions arrived at from this study were (a) introduction of unexpected variations and availability of flexible budget, (b) project designed for buildability got the most impact of doing a construction fast-tracking and (c) selecting a suitable contractor and schedule overrun respectively. If the challenges are very critical or inevitable, conducting a fast-track will not be a good option. Keywords – fast track construction, procurements, challenges, benefits, construction parties
124
Embed
Academic paper and supporting document on fast track construction (1)
This document is posted to help you gain knowledge. Please leave a comment to let me know what you think about it! Share it to your friends and learn new things together.
Transcript
-1-
IMPACTS OF FAST-TRACK PROJECT DELIVERY IN CURRENT
CONSTRUCTION INDUSTRY
Ahmed Rushdhie (0924137)
School of Technology, University of Wolverhampton, Wolverhampton, WV1 1LY, UK
ABSTRACT
The effort of this research is to identify the impact of construction fast tracking. The benefits and
challenges of this procedural method are really to affect a construction project in terms of time and
money. Procurement systems play a dynamic role in this procedure. Somehow, fast-tracking a
construction have to be conducted with (possible) risks to be taken as they are inevitable in the
process. Challenges of fast tracking should be considered at the initial stage of construction and the
needs of this method should be clearly defined by the developers. The client has to be made fully
aware about tackling any unforeseen situation that may occur during the construction. The online
questionnaire was disseminated to only two types of respondents who are contractors and developers.
The key part of this research will be identified through rating and weighed rating average of the
classified result. This study came with a number of key definitions: Saving money, team building and
short schedule are the key benefits of fast track construction. Design and build and partnering are the
most suitable procurement system for this procedural method. “Reduced time” is the most valuable
benefit of construction fast tracking. This method is more suitable to prepare short scheduling as well
because of its overlapping procedure. The main conclusions arrived at from this study were (a)
introduction of unexpected variations and availability of flexible budget, (b) project designed for
buildability got the most impact of doing a construction fast-tracking and (c) selecting a suitable
contractor and schedule overrun respectively. If the challenges are very critical or inevitable,
conducting a fast-track will not be a good option.
Keywords – fast track construction, procurements, challenges, benefits, construction parties
-2-
1. INTRODUCTION
Introduction of Construction Fast Tracking
Burgmann (1982) defines fast tracking construction as ‘A system of overlapping the normal
sequential phases in design documentation, tendering and construction so that the total time
scale is not significantly larger than the longest of the individual items’. The main purpose of
fast tracking was introduced in the construction to reduce time and cost because it was taken
into account to reduce time rather than phased construction as in the figure 1 (Kwakye, 1991
and Rahemtulla, 1989) and the figure 1 explains the evolution of construction method. Then,
construction professionals had come with an idea of fast tracking construction in the industry
(Fazio et al, 1988) by The Consulting Engineer (1961) who reported on parallel working, a
system in which early involvement of contractor the overlapping of design and construction
to reduce the time frame of construction (Rahemtulla, 1989). In accordance with Kwakye
(1991) and Potts (2008) the success of this construction method is entirely dependent of co-
operation of participant within the organisation because fast tracking is most appropriate for
procurement like design and build, partnering, construction management (Cho et al., 2010).
Amongst them, design and build system gives the single point responsibility to a party to
manage and construction, this is why design and build or similar procurement (prime
contracting) are more appropriate.
-3-
Figure 1 (Alternative procedural techniques)
Source: Rahemtulla (1989: p3)
2. LITERATURE REVIEW
Recently, UK government policy (2000) identified three recommended procurement route
such as design and build, PFI and prime contracting for public sector (Ramus et al, 2006) and
furthermore, proper justification is essential if any project has to be undertaken in traditional
procurement. Procurement systems with construction fast tracking are thoroughly detailed
below.
Traditional procurement – Traditional procurement system was most used in public sector
and is low and costly in old days (Waltz and Montgomery, 2003) before design and build had
become government recommended procurement. Shen and Walker (2001) states that “the
-4-
design team must take the time to complete all building blueprints necessary to construct the
project before any construction begins” and in accordance with the above figure traditional
procurement is not suitable for fast tracking because there is no any overlapping design over
construction. Moreover, the drawings are required to be reviewed so many times before the
construction.
Management procurements – Moreover, Constructionexcellence.com (2004) states
management procurements are more appropriate procurement system for fast tracking (than
design and build) (see figure 2) when consider time factors of the project (time is equivalent
to cost in construction (Knecht, 2012 and Philpott, 2010)) but construction management or
management contracting is less suitable to pass the risks to the contractor because it is based
on traditional procurement system (Constructionexcellence.com, 2004). Scottish Parliament
Building is one of the best examples for failure of this management procurement via
construction fast tracking system (Maxwideman, 2010) and Potts (2008) mentioned not only
construction management but also there are other potential problems occurred in that project.
The initial idea was to construct via normal construction and then fast track was introduced
due to time constrains and then it became far worse after fast track was applied
(Maxwideman, 2010). The construction professionals suggest single point responsibility was
not there to give all control to the contractor to look after Scottish parliament building.
Improper planned construction fast tracking is not good for construction it should be well
planned and well executed. On the other hand, many contractors can be appointed to do
construction fast tracking this is the reason why this procurement system is more appropriate.
-5-
Figure 2 Construction fast tracking with procurement (Philpot, 2010)
According to Smith, et al (2006) a management contract is most appropriate for construction
fast tracking as it is in the figure 2.
Design and build system, prime contracting and PFI – In accordance with NEC (2009) the
application of D&B, DBO (design build operate) or DBOM (design build operate and
maintain) shall be applicable in for prime contracting and PFI. Waltz and Montgomery
(2003) explain that the contractor’s participation in the design and build (D&B) system
ensures the project’s ‘buildability.’ Using the traditional construction method the contractor
looks at the architectural plans for the first time after it is complete and Waltz and
Montgomery (2003) added the contractor may have many question when he or she sees the
design for the first time. Changes may need to be made to the design if the contractor is not
part of the design process from the beginning, delaying the start of construction.
-6-
On the other hand, construction fast tracking, the contractor begins construction of the
foundation before design is complete. In accordance with Peña-Mora and Li (2001) the D&B
team completes the building in phases, coordinated with the contractor’s construction
schedules. By overlapping design and construction so they run simultaneously rather than
sequentially, the fast track design and build delivery method can significantly reduce total
project time – up to 50 percent, depending on the job (Waltz and Montgomery).
Additionally, each member of the design and build team have the authority to make decision
in the field. Time saving can be possible by managing buildability problems, to be solved
before a design solution is fixed so challenges in the construction will be predicted and
solved with the design in process during the designing and constructing (Griffiths and
Sidwell, 1997).
Construction fast tracking mechanism in the public sector may vary from its application in
private sector. In accordance with Cho et al. (2010) construction fast tracking is smeared to
project that cannot be accomplished by an instructed finishing date using traditional
procurement methods in the public sector. Cho et al. (2010) adding schools or highways can
be constructed through construction fast tracking design and build delivery to accomplish a
decided completion date cannot be accomplished through traditional procurement or the
design and build approach without fast tracking mechanism. Construction fast tracking is
always applied when time is really important factor and/or to produce additional profit and/or
invisible benefits by increasing the reputation of the owner thus offering further business
opportunities in a competitive market in the private sector. On the other hand, these reasons
also match with public sector as well (USACE, 1999). These are the reasons why fast
tracking can be well executed to large shopping complex, hotels, and other profit-gaining
facilities.
-7-
Figure 3 (Typical design-build and fast-track design-build models adapting Cho et al (2010))
Figure 3 details and gives graphical reasons why design and build system and construction
fast tracking mostly welcome in the public sector. Nowadays, construction companies would
like to adapt design and build method rather using design bid build and it is more widespread
after construction fast tracking method is introduced in the industry because the construction
activities overlapping had become more popular in the industry after realising overlapping is
only best one way to manage time concerns. The concept of fast track construction eases the
design completion and reviewing the work as the construction is on process.
Dung (2009) states single point responsibility is another important factor for conducting fast
track construction. The D&B team who can well manage design and construction activities at
the same time and the D&B team know where construction should be started and finished
according to the drawing prepared and produced. In addition, clients/consultants and
contractors may save time for delivering and understanding about the design and the
contractor do not need to consume an extra time for planning for the construction in
accordance with the drawing (Wilkinson and dale, 1998). The contractor may sketch their
-8-
planning part once design starts and they can develop their construction planning part once
the construction begins. When consider Prime contracting and PFI, which will deliver a better
fast track construction rather than D&B delivery because those procurements’ improved
strategy (Smith et al, 2006). There are many improved characteristics of those procurement
systems has been provided by various authors in their literatures (for example CIOB, 2001,
Potts, 2008, Latham, 1994, Ramus et al, 2006 etc.)
Partnering system – A survey result of relationship between construction fast tracking and
partnering is given in table 1. The table 1 states that linkage between fast track delivery and
partnering system. There are some characteristics which are very supportive to undertake fast
track construction system in partnering. In accordance with partnering and its characters from
the table are integration of construction team, early project arrangements, and the
relationship between the parties. Communication strategy and sharing of resources amongst
the parties will help construction fast-tracking to adapt those three factors in italics.
Table 1 (Affiliation between construction fast tracking and partnering system abstracted from
the research of Hyun (1998))
Item Mean
score
Standard
deviation
Holding of information in common 9.077 1.038
Early involvement of the designer and the contractor 8.923 1.038
Integrated team of all the parties 8.923 1.038
Good communication system 8.769 0.725
Involvement of the participants in the design process 8.692 1.377
Holding of the design information in common 8.615 0.961
Basing of the design team and the supplier at the construction site 8.615 1.044
Win/win motivation 8.000 0.913
Quick decision-making process 7.692 1.251
Effective process of the change orders 7.154 1.345
Establishment of the design criteria at an early stage 6.000 1.78
Experienced project team 5.154 2.267
Selection of items for early procurement 4.231 1.787
-9-
Undertaking fast track construction
Downfalls of fast track construction
Opponent of fast track construction suggest that because design is not complete when
construction commences, several problem arise. The process depends heavily on the balance
among the client, architect and contractor, who must have synchronised understanding of the
intent of the project and solid rapport with one another to make quick decision. Opponents
also suggest that because design is not complete until well into the project, final cost is
unknown at the beginning of the project for an instance some decisions are made in the field
if the foundations are laid and many choices and in construction or designs are fixed,
preventing major changes. The design is controlled by the schedules, which may sacrifice
some aesthetic component of the project.
Challenges in fast track construction
Design and procurement
Design normally starts ten days or a week ahead of construction begins, and some design
decision can also be made in the field (Knecht, 2012). Therefore, all activities should be done
through previous project’s experience, when it fails the contractor is entitled to do either
additional work or rework or change with the client’s representative’s advice according to the
procurement route (Smith et al, 2006). In this case, the architect may get blames promptly
when an activity is required rework. If it is design and build the architecture of the
organisation will get blames and sort out within the organisation but if it is construction
management, disputes may arise when a contractor accuses the architect. As the single point
responsibility is special feature of design and build, it is best procurement to avoid disputes
between the parties and the disputes are another reason for delay construction.
-10-
Selecting a contractor
Waltz and Montgomery (2003) states the risks normally start from selecting a contractor who
should be able to carry out fast tracking on whatever the procurement has been selected to the
construction. If the client wants to do the construction fast tracking the contractor should be
selected at the early stage of designing stage (Fazio et al, 1988). The contractor should know
what is this construction and designs are all about, if it is traditional based procurement such
as construction management, partnering (if consultant team available), etc. On the other hand,
the contractor cannot be appointed until 60 or 70 percent (O’leary, 1993) completed drawing
and specification has been completed and if that construction is traditional based
procurement. In order to manage this problem, the importance of single point responsibility
has become as design and build or procurement based on design and build. This is why early
appointment of the contractor and design with construction and fast track construction
introduced.
Save time or money
Of course, well managed fast track construction may save a huge amount of time and there is
an opportunity to save money as well (Knecht, 2012). When the cost of the project is decided
from preliminary estimating it can be well managed according to the contract has been
defined (Fazio et al, 1988). A maximum guaranteed price has usually given by construction
manager in order to control the cost, if construction fast tracking is going to be used in that
construction having the thought of architectural and design impediments. As stated, fast
tracking a construction can hasten the programme but that needs extra risks to be taken.
When the risks turn up in reality, there will be huge loss in end date or expensive rework will
be required (PMI, 2008) and to supplement this statement Kerzner (2010) stated “Almost all
project-driven companies fast-track projects, but there is danger when fast-tracking becomes
a way of life.” (P: 475). According to PMI (2008) and Kerzner (2010) “fast-tracking a job can
-11-
accelerate the schedule but requires that additional risks be taken. If the risks materialize,
then either the end date will slip or expensive rework will be needed. Almost all project-
driven companies fast-track projects, but there is danger when fast tracking becomes a way of
life”.
Material procuring
Advanced purchasing of essential material will become inevitable norm when a project is fast
tracked Kwayke (1991) and “certain materials or equipment must be pre-ordered before the
final plans and specifications can be incorporated into a fully executed contract” (Levy, 2010:
p68). A letter of intent will permit the contractor to procure needed material for long-time-
utilisation but the problem may arise when particular material or equipment is not available
during the material finding in the market for instance special equipment like piling rigs.
Project designed for buildability and speed
In accordance with Kwayke (1991) the project should be designed to fully adapt buildability
aspects of a construction and then the maintenance during the design cum construction period
is very significant to avoid negative factors which affect the productivity of the job. The
construction scheduling should be planned to let continuous or sequence and decrease of site
material and labour wastes with less problems, unproductive time (regular late starts and
early finishes of the work).
Flexible budget and make them available
The client should require sufficient facility for flexible budget to make sudden decision to
cover extra cost. If any risk appears which may require additional and costly solution, for an
instance when a material is not available at that time but expensive material only available
instead, the client should be able to procure and consume the sufficient material to make fast
track more effective.
-12-
Poorly planned fast track construction may cost too much for the client compares to
conventional construction system because there are more risks to be taken by the contractor
that even more when D&B type procurement system (Kwayke, 1991 and Fazio et al, 1998).
In addition, the client should have to pay more in order to make the contractor more calibre.
Kwayke (1991) adds that the client entitles to pay for double preliminaries to the contractor
who is borne by the client. On the other hand, the client may control extra expenditure by
selecting D&B because he/she does not need to pay much professional fees such as fees for
management contractor and consultants. All he/she is entitled to pay is the D&B contractor.
Schedule overrun
According to Miles (1995) ultra-speed fast tracking has been implemented in the construction
industry just after the identification of fast tracking and the communication difficulties,
omissions and design errors may lead to improper fast track execution and it may lead to
schedule overrun.
Quality
Quality is a doubtful factor in D&B procedure but it is subject to be improved in management
procurement systems (Potts, 2008). On the other hand, construction fast tracking along D&B
is much riskiest procedure when considering quality. Therefore, achieving maximum quality
in fast tracking is very important because the accelerated nature of fast tracking and
insufficient time will not let to get expected quality (Alhomadi et al., 2011). On the other
hand, Kerzner (2010) and PMI (2008) states if a construction have to be accomplished on
time but the starting date is passed without affecting quality there is only option to be taken is
fast tracking the project. In addition to this he added this is another benefit of fast tracking a
project (PMI, 2008). Pressure on construction schedule performance has been identified as
the reason for quality dropping in fast track construction (Nepal et al, 2006) and added this
may be the “result of working out of sequence, generating work defects, cutting corners, and
-13-
losing the motivation to work” (Alhomadi et al, 2011: P.1970). Nepal et al (2006) underlined
that accelerated schedule is main reason for project’s lower quality and the more pressure in
scheduling is another reason to keep the quality on track.
Fazio et al, (1988) indicated that the fast track construction needs additional work or rework
due to its incomplete design before the construction unlike traditional construction and also
affects the quality of the project or it is because the construction schedule is disturbed to be
maintained on track. According to Alhomadi et al (2011) explained this case through as
example that one incident occurred in structural package awarding, the tender closing date of
package was rescheduled three times, 190 drawings were added with old documents and 109
drawings were revised due to failed to achieve good quality along construction fast tracking.
According to Park (2002) the variation and rework can be possible following either actions
such as adding, deleting or replacement of a construction. The variation is in fast tracking
may be occurred due to improper planning execution of a construction project. Nonetheless,
the variation would be the reason to consequent changes adding more construction activities
and lower quality (Park, 2002).
Failed to manage health and safety procedures due to its speedy process
According to Pye et al, (2007) the workers who should be assessed the Experienced Worker
Practical Assessment (EWPA) with a minimum of five year experience. Pye et al, (2011)
states as health and safety is one of the risky factors in conventional method of construction
but in this case it is more risky factor when a fast tracking is considered because of the
speedy process. Additionally, it is always failed to achieve in fast-tracking therefore health
and safety criteria should be included in programming and it should be executed according to
particular project health and safety manual.
-14-
The benefits of fast track project
Reduced time
Benefits of fast tracking a construction project are highly appropriate in construction in order
to save time and cost (Knecht, 2012 and Kwayke, 1991). It is very appropriate method for
time saving and helps the project to be completed in least amount of time if it is well planned
and executed. The WiseGeek.com (2003) added that will surely help to save the number of
days, week or months required to complete the project on or before its due. Additionally, this
can save significant amount of time as well as money (Wisegeek.com, 2003). The
overlapping strategy would only be making the construction practitioners to achieve their
aim.
In reality, construction fast tracking is a helpful tool to meet precise cut-off date. If a building
is urgently needed to complete it, a fast track strategy is an ideal method of construction to be
occupied as quickly as it could, the fast track construction only make this condition possible
(Knecht, 2012 and Kwayke, 1991). Many construction delays interconnected with standard
method of construction can be well eliminated through fast track construction
(Wisegeek.com, 2003). In accordance with Kwayke (1991) “For a business that may be in a
difficult position without the new building, it can make the difference between success and
failure” (P: 8)
Lower cost
Behm, et al (2007) states that the smart construction professionals found out a most
economical construction method to save both time and money is construction fast tracking
and they recommend this method for future construction era for the sake of the clients. In
addition, a smart construction can end up with saving potentially millions of pounds (Behm et
al, 2007). In construction, time extension is considered as an expensive procedure therefore
-15-
the client would not like take the construction any longer apart from its deadline. Reducing
the construction period from its original deadline is not normally possible in conventional
linear building process so overlapping the design and construction should be introduced to
make it happened. The construction team can revise the deadline from traditional
construction to fast tracking and advice the benefits of fast tracking to the client if he/she
feels that fast tracking is a risky business (Behm et al, 2007). Behm et al (2007) states that
the contractor can supply the salaries and wages at same time and utilising the time for
preparing the contract documents (drawings, bills of quantities (BOQs) etc. according to the
procurement route selected) and construction.
By proper planned fast track construction may help the construction to shrink the
construction a 24 month programme to 18 month will possibly produce substantial time and
cost savings and again “time is money” is worked in construction (Rahemtulla, 1989 and
Behm, et al, 2007). Apart from fast tracking, construction can be expedited through some
other tactics such as multiple shifts, overtime and hire sub-contractors for special work
parallel with main contractors work. Those tactics will work perfectly with the construction
fast tracking and complexion of those strategies will assist to make considerable time saving.
Team building
In accordance with the Knecht (2012) fast tracking is a good source to maintain team spirit
within the company and there are a lot of successful project was conducted through fast
tracking. Whitehall-Robins Pharmaceutical Research and Design Facility Richmond USA is
one of the good examples for achieving high benefits via construction fast tracking.
Moreover, “the overall project team was organised into four subproject teams, one of which
was responsible for the laboratories, in order to manage the fast-track project” (Knecht,
2012).
-16-
Short schedule
According to Pena-Mora and Park (2001) defined that there are strategies along with the fast
tracking to short schedule which can be possible through design and build rather than
conventional method. Additionally, the fast tracking with the design and construction would
make a better environment for the construction project. According to Alhomadi (2011) and
Park (1999) states overlapping only the reason why the construction period is shrunk with
saving the programmed period and “which increase the ripple effects leading to more design
changes and longer activities duration and total delays” (Alhomadi et al, 2011: p1969).
Eastham (2002) suggests that the schedule can be shrunk at least 10% of the overall process
due to fast tracking method but according to Rahemtulla (1989) and Behm et al (2007) the
schedule can be reduced by 25%. Even more percentage can be reduced when a proper fast
tracking is executed with short schedule.
Single point responsibility
Dung (2009) states the construction fast tracking can be accomplished without further delay
through single point responsibility. The single point responsibility delivers a smooth
construction and that factor can be taken through design and construct type procurement
neither traditional type procurements nor management type procurement. The management
procurements can shrink the duration of the project rather than design and build does but
there is more chance for disputes. Calibre construction parties only will do a successful fast
track construction through management procurement as mentioned reasons of failure of
Scottish Parliament building and under challenges of fast track construction.
-17-
3. METHODOLOGY
The quantitative method was selected to continue this research according to the advantages
and disadvantages of quantitative and qualitative method. The benefits of quantitative method
give the idea to the researcher to put his step into the analysis part by analysing stages.
Moreover, any researcher can go along with quantitative method to complete any research
and without any ability of conducting interviews or case studies at very less cost and time and
it is easy method for analysing the issues. The population was organised from all construction
practitioners and the questionnaire sent out only to the client/consultant and contractors. The
representative samples used in this survey because it is associated with the quantitative data
and larger scaled survey. From the 100 online questionnaires, 21 companies had only
responded in this survey. It was sent out to UK and Middle East. Middle East participant who
had the experience in UK (English) and they are the respondents whom personally known.
Rating and weighed rating (Mean)
This technique is performance measuring that use of supply of answers as the basis to control
the scale of rate. In addition to this, the rating and weighed rating average used for
categorising the challenges, benefits inevitable factors of fast track construction rest of them
analysed through pie chart, bar chart and tables. Mean mechanism was done through agreeing
occurrence can be defined from
1. 1 – Strongly disagree
2. 2 – Disagree
3. 3 – Undecided
4. 4 – Agree
5. 5 – Strongly agree.
The Weighed Rating (Mean) = ∑ (Ri × Fi)/r
-18-
Where Ri - Rating of each factor, Fi - Frequency of responses and r – total numbers of
respondents.
The rating and weighed rating average helps to calculate where a challenge of fast-tracking
falls and to consider how that challenge impact the construction industry.
4. ANALYSIS
This survey mainly focused on the view point of client/consultant and contractor only.
Twenty-one respondents from 100 questionnaire distributed shared their comments and views
on fast tracking, however, only ten practitioners from client/consultants and eleven
practitioners from the contractor participated in this survey of this research.
Role of the respondents
The viewpoint of the respondents is the one which is directly affect to the construction fast
tracking because project managers (PMs), quantity surveyors (QSs) and architects will
directly participating in selecting procurement system and deciding the importance of
construction fast tracking within the construction.
This is why those three sectors have been selected to send out the questionnaire. However,
only PMs and QSs only responded to this questionnaire so viewpoint of architects was unable
to include in this research. The analysis process is shown in table 2 and table 3.
Table 2 role of the respondents in consultants (N=10)
Role of the participant Nos. Percentage
Quantity surveyor 5 50%
Project manager 5 50%
Total 10 100%
-19-
The same amount of participants (5 QSs and 5 PMs) had undertaken this survey. The 50% of
each person’s responses were analysed in the detailed analysis part. The participation of
contractors QSs and PMs in this survey has been discussed below.
Table 3 the role of the respondents in contractors (N=11)
Role of the participant Nos. percentage
Quantity surveyor 5 45%
Project manager 6 55%
Total 11 100%
Form the above table and figure, 5 or 45% of the QSs are participated in this survey and 6 or
55% of the PMs are participated. Therefore, the mixture of PMs and QSs perspective will be
analysed briefly.
Risk level of carrying out a fast track construction
Carrying out fast tracking a project is very risky thing in the construction as it is mentioned
throughout literature review. Client would like to choose this method and D&B or D&B type
to shift all risks to the contractor and would like to be in a safe place as construction is in
process. On the other hand, there are some tactics will assist to defeat all risk factor.
Managing a risk in fast tracking is entirely dependent on the procurement system and the
challenges in the fast tracking are very important those two entities will be evaluated later. In
accordance with table 4 and figure 5 the degree of risk in fast tracking is explained.
Table 4 level of risk in construction fast tracking from the consultants viewpoint
Level of risk Nos. Percentage
Higher 8 80%
Average 2 20%
Lower 0 0%
Total 10 100%
-20-
All consultants accepted that fast tracking is no longer lower risky method to do a project.
Twenty percent of consultant only mentioned that is an average risk method and rest of them
(80%) declared that it is a highly dangerous method as far as a smooth construction is
concerned. They might have faced so many problems during the construction and because of
not having a proper risk management system; they might have failed to accomplish a task.
From the figures in table 10 construction fast tracking is a risky method of construction. The
need of contractors also considered in this research and that is provided below.
Table 5 level of risk in construction fast tracking from the consultants viewpoint
Level of risk Nos. Percentage
Higher 7 64%
average 4 36%
lower 0 0%
Total 11 100%
All contractors also agreed that this method is not a lower risky way of construction
mechanism for a construction. On the other hand, 36% of the answered respondents approved
that this is an average level risky method of construction. Rest of them confirmed that this is
a highly risk to be considered a smooth construction. Overall, the analysis considered the
level of risk is high in construction fast tracking.
The benefits of construction fast tracking
The benefits of construction fast tracking is one of the key finding in this research, because
giving a full idea of construction fast tracking seemed important at the initial stage of
construction. Time is very important factor in construction because time is money (Behm et
al, 2007). Time and money are interconnected all risk factors in the construction inclusive
quality, safety, environmental etc. A good margin of money will look after mentioned
properly otherwise, insufficient fund will not let to do smooth construction.
-21-
The viewpoint of the consultant is going to be analysed through the table 5 and figure 4
below.
Table 6 benefits of construction fast tracking from the viewpoint of client and consultants
Benefits of fast tracking Consultant
Rank contractor Ran
k Nos. Percentage Nos. Percentage
Reduced time 10 100% 1 8 73% 1
Short schedule 5 50% 2 7 64% 2
Lower cost 3 30% 3 5 45% 3
Team building 2 20% 4 3 27% 4
Single point responsibility to
the contractor 0 0% 5 3 27% 4
Figure 4 benefits of construction fast tracking from the viewpoint of client and contractors
Consultant’s point of view
Hundred percent of consultants who responded were agreed that very important advantage of
the fast tracking is reduced time. Therefore, there is no second word to discuss form the point
of view of client/consultant. The half of the respondents (50%) declared that this takes next
priority to choose the construction fast tracking. Short schedule has been taken place right
0%
20%
40%
60%
80%
100%
Reduced time Short schedule Lower cost Team building Single point
responsibility
to the
contractor
Consultant Contractor
-22-
next to reduced time. Form this data of the question, half of the construction practitioners
would not practise short schedule in the construction which mean that there is no strategic
way of shortening schedule in the programme. Shortening the time through better
programming is a good practice to make not to fail in any circumstance. However, this is a
good finding of this research. Construction professionals are partially practising it but this
will fully apply to the construction to get full advantage of construction fast tracking.
Lower cost is one of the main benefits of construction fast tracking but thirty percent of the
respondents only confirmed that this is benefit of construction fast tracking. They may not
have precise idea of construction fast tracking or as consultant declared that this is risky
method of construction they might have finalised that this is not a benefits as much as
reduced time is concerned. The actual case is different here time and cost are Siamese twins.
This concept is mandatory to understand.
Twenty percent of the consultant only stated team building is a benefit of fast track a project.
Normally, the integrated team should have formed during the design brief period (RIBA,
2012) and that good team will help the construction to kick start the design and construction
at the minimum of one week ahead (Knecht, 2012). Therefore, a good team is important
factor.
Finally, no one chose the single point responsibility; Waltz and Montgomery (2003) stated
that D&B and construction tracking can make a huge change in the construction. The
consultant would not like to continue through D&B to gain maximum concept of construction
fast tracking. The viewpoint of the contractors will be given below.
Contractor’s point of view
Seventy-three percent of the contractor agreed that reduced time is one of the main
advantages of fast tracking as the consultants agreed at first place but twenty-seven percent
-23-
did not find the importance of reduced time in fast track process. Sixty-four percent of the
consultant declared that short schedule is next benefit to the reduced time. The contractors
also felt that the importance of short schedule. Forty-five percent of contractors agreed that
lower cost is partially benefited factor of construction fast tracking. Twenty-seven percent of
contractors only accepted that team building and single point responsibility are another
benefits of fast tracking a construction.
However, both the construction parties accept that the importance of reduced cost in the
construction fast tracking and it is one of the key characteristics of fast construction. They are
affirmative in their decision. The entire construction industry may choose fast tracking when
the time is very important factor and client is willing to spend any money to accomplish the
construction on or before the deadline of the construction. Money does automatically stick
with the time so the client will be benefited in both ways. The entire construction industry
accepts (in second place) the importance of short scheduling as far as the fast tracking
concerned. In addition, the fast tracking is the only option to shorten a construction period
because of its overlapping procedure. An extended team building is the one which can lead
any construction to success and if it is well planned and executed, team building is a good
practise.
Single point responsibility is really a good advantage of fast track construction but maximum
advantage of fast tracking will be fulfilled through using all five method is in the
construction.
Procurement system and construction fast tracking
As exposed in the literature review, procurement system plays a vital role in the selection of
construction fast tracking. Procurement is normally selected during the preparation period
(stage 1) of the construction process (RIBA, 2012). Then, the construction method is selected
-24-
whether the conventional method of construction or any alternative methods of construction.
Procurement method and construction fast tracking will lead better construction project.
Therefore, identifying an appropriate procurement to select fast tracking is essential factor to
find and finalise the proper method for a construction. Finding a best method for construction
fast tracking is going to be defined through figure 16 and figure 17.
Figure 5 procurement method and developers viewpoint
The viewpoint of consultant (10%) is rather different from what was reviewed the literatures
because traditional procurement has been selected suitable fast tracking. The literature says
that traditional procurement system is not an appropriate method for fast tracking. This
research can come to a conclusion that consultants may not have proper knowledge about
construction fast tracking or they really adapt conventional procurement with some
reasonable adjustment. Normally, procurement is selected in the preparation period (RIBA,
2012) and programming will be done in just before the construction begins it cannot wait
until detail design finishes.
0% 5% 10% 15% 20% 25% 30%
Traditional
Design and Build
Partnering
Contruction Management
Management Contracting
Prime contracting
PFI
-25-
Twenty percent of the respondents from the consultant chose D&B and management
contracting and partnering are suitable method for the fast track construction. It does partially
support what reviewed in the literatures because management contracting is the most suitable
method for fast tracking rather than any method. Partnering was chosen by thirty percent of
the consultants which says there are more companies adapting partnering method for fast
tracking. The characteristics of partnering is really good practise to make a better
construction refer table 1. Team building and an extensive communication system single
point responsibility are very important factors in fast tracking as fast track construction is
concerned.
PFI and construction management is not selected by anyone. Construction management is the
same concept of management contracting but this is widely used in USA so UK practitioners
did not select this method. PFI seemed unsuitable procurement method for construction fast
tracking. The viewpoint of contractors will be discussed below.
Figure 6 (Procurement method and contractors viewpoint)
0% 10% 20% 30% 40% 50% 60% 70% 80%
Traditional
Design and build
Partnering
Contruction Management
Management contracting
Prime contracting
PFI
-26-
One respondent (9%) selected traditional system, management contracting and prime
contracting. As literature reviewed the traditional method is not suitable method for
construction but management contracting is a best method for construction prime contracting
is suitable too. Seventy-three percent of contractor picked design and build that the most
suitable method for construction fast tracking as the literature reviewed thoroughly. Overall
construction industry accepts D&B is the most appropriate method for fast track construction.
The contractors only understand the benefits of construction fast tracking through D&B.
Partnering, PFI and construction management have not been chosen by any construction
practitioners in the contractors. However, the characteristic of partnering is not really
understood by the contractor as the consultant does. The analyses of challenges of fast
tracking are discussed in detailed below.
The challenges construction fast tracking
The main findings of this research are to identify the impacts of fast tracking construction and
to outline the methods of overcoming the challenges. On the other hand, the benefits of this
method will give idea to adapt a construction fast tracking in the construction. Identifying the
challenges of this method will assist to overcome and draw some strategies against its
challenges. A detailed analysis with the table 7, table 8 and mean will help to find out where
it falls between the strongly agree to strongly disagree.
Developers’ viewpoint
Table 7 challenges of construction fast tracking form the viewpoint of consultants (N=10)
Challenges of construction fast
tracking
Weighed rating
average (Mean)
The degree of
acceptance Ranking
Introduction of unexpected variations
during the construction 4.0 Agreed 1
Flexible budget and make them
available 3.7 Agreed 2
-27-
Requiring strong and experienced
manpower resources, especially in
project management
3.7 Agreed 2
Schedule overrun 3.7 Agreed 3
Design and procurement 3.6 Agreed 5
Material procuring 3.2 Undecided 6
Quality 3.2 Undecided 6
Selecting a contractor 3.1 Undecided 8
Project designed for buildability and
speed 3.1 Undecided 8
Save time or money 2.8 Undecided 10
The factors will be analysed according to the ranking of the challenges respectively. From the
above table the Introduction of unexpected variation during the construction has got the
maximum impact of construction fast tracking and every construction practitioners agree that
this is a challenge of construction fast tracking. Moreover, this is an obvious challenge of fast
tracking a project if the client requires any extra work during the design cum construction
period that attitude will definitely affect to the construction (Fazio et al, 1988). This is the
reason why the client must be advised to revise and complete his brief before the design and
construction begins. In accordance with Audit Scotland (2000) and Maxwideman (2010) a
huge change was proposed that Tower Buildings, with Queensberry House and the MSP
building to the Scottish parliament and the designing team found difficulties to incorporate
the change designs to apply into construction fast tracking.
Developers agreed flexible budget and make them available as a challenge of fast track
construction. If the client has not got the flexible investment in order to manage the
construction business so this method will be very risk. Sometimes construction fast tracking
requires instant capital because the risks are little high in this method as analysed. Therefore,
flexible budget is very important (Fazio et al, 1988). If a construction needs a fast track
project the client will have to arrange to keep certain amount of money throughout the
-28-
construction period. In this case the client has to make the budget available if any necessities
occur during the design and construction phase as revealed in the literature review.
Requiring strong and experienced manpower resources is an inevitable factor form the
agreeing of developers. When it comes to construction fast tracking it should be considered
so special. The construction team can solve this problem through an effective project
management. A specialist can be appointed to manage this problem and experienced workers
should be employed to this construction. The PMs, QSs and engineers should be able to read
and execute the construction through unfinished drawings so an integrated team is essential.
The construction practitioners should be trained to do this type of construction.
Schedule overrun is considered an important challenge of this construction style because the
good construction programming is essential to make this method work that has been agreed
by the client as well. Short schedule is one of the main benefits of this method but a poor
planned programme will fail this mechanism completely and this is a main finding of this
research. Therefore, properly planned construction programme is very important in
construction fast tracking.
Design and procurement is also a challenging factor of construction and it is agreed by the
consultant/clients. The literature states that this is very important challenge of fast track
construction. However, the consultants of the construction industry declared that this is not
much important factor in the fast track mechanism. Design and construction should be
considered with the procurement system because the parties who does the design and
construction will decided through the procurement route selected. Consultants who responded
to this question might not have considered the design and construction system separately. If
they considered those two factors together they might have come to a different degree of
acceptance. That might have support what is reviewed in the literature.
-29-
Material procuring falls into the undecided category whether it is not agreed or disagreed in
the sense material procuring will be considered in both ways in accordance with the situation
where the project in. Material procurement can be occurred as an advance purchasing or just-
in-time purchasing. If a material should be purchased in advance a proper warehouse system
is important to make them safety that will cost extra money. On the other hand, some
materials should be purchased on time because it cannot be stored for a long time; in that case
just-in-time purchasing system is to be done. Nevertheless, the fast track construction may
need some important material just the design is started so proper storage management and
procuring management is mandatory in order to maintain a smooth fast track construction.
Quality level of construction affects because of speedy process of construction this is why
this is in undecided category. If management contracting selected for this construction the
quality level will be maintain at good level because the client or project management
involvement is there but design and build will fail to give good level of quality which is
dependent on procurement system as in the literature review. Construction fast tracking will
look after both the time and cost very much. Somehow, that will be subject to be improved
other D&B based procurement such as prime contracting.
Selecting a contractor is really an important factor because suitable contractor will only do
this kind of project. Special experience is very crucial entity to undertake this kind of project.
However, the consultants could not decide whether this method is a challenge or not. In
addition, the respondents did not feel much that this is a challenge when the fast tracking is
concerned. On the other hand, the literature states that selecting a contractor is one of the key
challenges in construction fast tracking in common construction is concerned.
Project designed for buildability and speed – project buildability is one of the inevitable
factors for a construction project because it will lead a good construction and the buildability
-30-
will guide the construction parties to the aim. However, the consultants declared that project
designing is not very essential factor for buildability and speed. A planned construction
design will direct the fast track construction to the smooth finish.
Save time or money is not actually a challenge but it is the main benefit of the fast tracking.
When these two factors become as a challenge there is no point to undertake fast track
construction or if a fast track construction fails to achieve reduced time and lower cost that
project would have undertaken a conventional construction and finished it on time. The view
point of contractors will be discussed with following table 14.
Contractors’ viewpoint
Table 8 challenges of construction fast tracking form the viewpoint of contractor (N=11)
Challenges of construction fast
tracking
Weighed rating
average (Mean)
The degree of
acceptance Ranking
Project designed for buildability and
speed 4.3 Agreed 1
Selecting a contractor 4.1 Agreed 2
Schedule overrun 4.1 Agreed 2
Design and procurement 3.9 Agreed 4
Introduction of unexpected variations
during the construction 3.8 Agreed 5
Save time or money 3.7 Agreed 6
Flexible budget and make them
available 3.7 Agreed 6
Material procuring 3.6 Agreed 8
Requiring strong and experienced
manpower resources, especially in
project management
3.4 Undecided 9
Quality 3.0 Undecided 10
The importance of project designed for buildability and speed is realised by the contractors
because it is really a challenging factor to the contractor and they are about to strongly agree
this problem. The consultants may develop the design to adapt the buildability but the
contractor only is going to use that drawing provided by the developers. If the design fails to
-31-
achieve buildability and cannot catch the speed the contractor suffers with the project design.
Revision of the project drawing to adapt those factors may take time therefore the period of
construction will be affected and the key benefit of fast tracking is hard to gain. Hence, a
D&B procurement system and single point responsibility will solve all the difficulties which
can arise in the construction fast tracking method.
Selection of the contractor is itself a problem to the construction fast tracking because they
realise capability themself to undertake this method and responded it. A well experienced
contractor only does a good fast track construction but the developers should select suitable
contractor for this method.
Schedule overrun has been agreed by the contractor because the contractor will always get
all blames for the time overrun from the developers. Therefore, better programming is very
important in order to undertake a construction fast tracking without any delay. The
developers should always prepare a good construction programme.
Design and procurement has been accepted by the contractor as a challenge of fast tracking.
The delivery of the drawing is normally being given to the contractor in phase of the activity.
The contractor has to learn the drawing very quickly and construction accordingly. However,
this is not the case in D&B delivery; integrated team building will look after each and every
challenge incurs to the contractor. Single point responsibility will not give any nuisance to
the developers D&B contractor manage all the risk in the fast tracking.
Some contractors welcome the variation during the construction phase because they can re-
estimate that particular item and add new profit. The contractors who participated in this
survey accepted that this is a challenge because it is a challenge when fast track is concerned.
If the design provided by the developers is considered to be changed after the construction
has begun; they may find this as a serious problem and they cannot finish it on time.
-32-
Save time and money has been agreed by the contractors as a challenge of fast tracking. If a
fast track construction does not save time and money that should have selected as a prime
challenge of this construction method. From the consultant view this is considered in
undecided category and it has the minimum impact. Normally, the consultants do not execute
this method to get failure but the contractors always think to save money and time
considering current condition of construction.
Flexible budget is related to the client but the contractors should also have sufficient fund to
execute particular construction activity. Therefore, arrangement on spending money is very
important.
Material procuring has been slightly accepted by the contractor from undecided category.
The contractors are practising good material management for an instance good storage. This
is the reason why material procuring appears to be vulnerable challenge of construction fast
tracking.
Gathering the man powers is simply given to the contractor by entire construction industry.
From the contractors point of view they always try to get skilled persons for work so that they
did not consider as a hard factor to do it.
The contractors always affirm that they are smart in construction so quality is considered as
undecided category; they cannot either state this is a challenge. Whatever the construction
method is selected for a construction quality is guaranteed from their response.
Inevitable impact of fast tracking
There are factors which are foreseeable in fast track construction. The factors always affect
the construction procedure and those factors can also be referred as its challenges but those
-33-
are not exactly the challenges. A brief analysis with the table 15 will help to find out where it
falls between the strongly agree to strongly disagree.
Fast track delivery advises to the client about the limitation of the design changes not to
change once construction is started and it is the main characteristic of this method. The client
must finalise his scopes before the construction started. According table 15 both the parties
very much accepted but the contractors nearly strongly agreed this statement.
As another inevitable factor of fast tracking is the starting the construction before the design
is completed. The designer and project manager should be very specific about it. Changing
the design is very dangerous practise once the construction is begun. Therefore, an
experienced team only will do a better fast track construction delivery.
Table 9 inevitable impact of fast tracking from both sector’s visions
Challenges of construction
fast tracking
Developers Contractors
Ran
king Weighed
rating
average
The degree
of
acceptance
Weighed
rating
average
The degree
of
acceptance
Fast track delivery gives a
limitation to the project
owner's ability to make
design changes once
construction has started
4.2 Agreed 4.5 Agreed 1
Starting construction before
design works are completed
can lead to a large number
of change orders
4.1 Agreed 3.7 Agreed 2
Inability to achieve quality
products as expected 3.8 Agreed 3.4 Undecided 3
Failed to manage health and
safety procedures due to its
speedy process
2.1 Disagreed 2.7 Undecided 4
The developers agreed that fast track construction fails to achieve quality products because of
its speedy process. On the other hand, the contractor could not decide whether it is challenge
-34-
or inevitable factor of fast tracking a construction. From this statement the contractors are
very careful to tackle this factor where it needs.
The developers declared that health and safety practice can be on track there is no problem
in following health and safety procedure. On the other hand, the contractors found this is as
undecided factor in construction.
5. CONCLUSION
Sufficient safety measures should be taken into account with respect to the pre-identified
trouble areas, which are fundamentally related to design as the precision of the design is very
essential to reduce significant amount of the project durations. Issues which are identified
from this research are; the experience of management team and team’s scale priorities. The
team should be proactive to manage the risks on the incomplete design process and the
construction process when it is overlapping. Initial stage of this construction, may need a
substantial amount of money but when fast-track construction successfully completes the
client/project can save significant amount money. In order to achieve single point
responsibility and team building the design and build is suitable procurement and quality
factors can be gained through management contracting. Management procurements are
suitable for high-rise and/or infrastructure building. The project duration can be shrunk
between the minimum of 10% and maximum 50% and it can be materialised when a proper
fast-tracking is executed with short schedule.
REFERENCE
Alhomadi, A. A., Dehghan, R. and Ruwanpura, J. Y. (2011) The Predictability of Fast-Track
Projects. Procedia Engineering, 14 (1).
Audit Scotland (2000) The new Scottish Parliament building: An examination of the
management of the Holyrood project. Edinburgh: Audit Scotland.
-35-
Behm, M., Cowart, P., Smith, S and Thinen, R. (2007) Smart Construction: Economical
Building Solutions to Save Time and Money. [report] Chicago.
Burgmann, J. B. (1982) Fast-track and structural design of Westmed Hospital. Institution of
Engineers Australia. 1(2)
Chartered Institute Of Building (CIOB) (2010) Code of practice for project management for
construction and development. 4th
ed. Chichester, Wiley-Blackwell.
Cho, K., Koo, K., Hong, T. and Hyun, C. (2012) Partnering Process Model for Public-Sector
Fast-Track Design-Build Projects in Korea. Journal of management in engineering,
26 (1), p.19-29.
Constructionexcellence.com (2004) Procurement. [online] Available at: