i Major Causes of Dispute in the Ethiopian Construction Industry A PROJECT REPORT Under the guidance of Prof. D.G.L.Chandra Rao __________________________ Submitted by: KIFLE SEMU SIMA Registration No. 531010358 _________________________ in partial fulfillment o f the requirement for the award of the degree Of MBA IN Project Management February, 2012
93
Embed
Kifle Semu's Project Paper_Thesis_ on Major Causes of Dispute in the Ethiopian Construction Industry_,
This document is posted to help you gain knowledge. Please leave a comment to let me know what you think about it! Share it to your friends and learn new things together.
Transcript
i
Major Causes of Dispute in the Ethiopian
Construction Industry
A PROJECT REPORT
Under the guidance of
Prof. D.G.L.Chandra Rao __________________________
in partial fulfillment o f the requirement for the award of the degree
Of
MBA
IN
Project Management
February, 2012
ii
Acknowledgement: I wish to express my deep appreciation to Prof. D.G.L.Chandra Rao, who
served as my advisor, for all the support and guidance. I also appreciate
his positive comments and advice throughout my research.
Thanks are due also to other members of the thesis committee
Acknowledgement is due to Sikkim Manipal University, Directorate of
Distance Education.
Also, I wish to express my sincere gratitude to all my friends and
colleagues who have participated in this research,sacrificing their
invaluable time.
My thanks and gratitude is due also to my wife,(Alemtsehaye Mamo) for
her encouragement and patience without which this work would not have
been possible.
iii
Bonafide Certificate:
BONAFIDE CERTIFICATE
Certified that this project report titled
……………………………………………..” is the bonafide work of
“…………..<NAME OF THE CANDIDATE(S)>.…………” who carried out
the project work under my supervision.
SIGNATURE SIGNATURE HEAD OF THE DEPARTMENT FACULTY IN CHARGE
<Academic Designation> <Department> <Department> <<Full address of the Dept & College >> <Full address of the Dept & College >
iv
Abstract: Construction projects are becoming increasingly complex, resulting in complex
contract documents. Complex construction can likewise result in complex
disputes. Disputes are inevitable in construction projects which predominantly
arise from Complexity and magnitude of works, multiple prime contracting
parties, poorly Prepared and /or executed contract documents, inadequate
planning, financial issues and communication problems. Any one of these factors
can overturn a project and lead to complicated litigation and arbitration, increased
costs, time overrun, and a breakdown in the parties’ interest and relationship.
Thus, the objectives of this study are to study, identify and review the major
causes of dispute contributed by clients, consultants and contractors in
construction projects and give suggestions and recommendations on how to
minimize or avoid the occurrences of construction disputes.
A questionnaire survey was carried in the various regions of Ethiopia and the
feedbacks were collected and analyzed using important indices (Likert Scale) and
Relative Importance Index (RII) analysis. The results show that Contractors’
Financial Difficulties, Price escalation, inadequate investigation before bidding,
Consultants’ Poor Contract management & Supervision, and other factors
contribute to such disputes. By and large, unresolved construction disputes
will only bring in negative impact on client’s organization like time and cost
overruns, diminution of respect between parties, deterioration of relationship,
breakdown in cooperation and additional expenses.
v
TABLE OF CONTENTS Page Acknowledgement: .................................................................................................................. ii
Bonafide Certificate: ............................................................................................................... iii
Abstract: ................................................................................................................................. iv
TABLE OF CONTENTS ..........................................................................................................v
List of Tables: ......................................................................................................................... ix
List of Figures: .........................................................................................................................x
Abbreviations and Glossary of Important Terms ..................................................................... xi
Abbreviations ..................................................................................................................... xi
Glossary of Important Terms ............................................................................................. xii
Table 4.1: Ranking of causes (based on overall view)
Table 5.1: Summary the top 10 causes of dispute (based on Employers’ point of view)
Table 5.2: Summary the top 10 causes of dispute (based on Consultants’ point of view)
Table 5.3: Summary the top 10 causes of dispute (based on Contractor’ point of view)
Table 5.4: Summary the top 10 causes of dispute (based on overall respondents view)
x
List of Figures:
Figure 1.1 Flowchart of the Research Methodology
Figure 2.1 Disagreement Escalation Diagram
Figure 4.3: The ten most important causes of disputes (based on all
respondents)
xi
Abbreviations and Glossary of Important Terms
Abbreviations
ADR : Alternate Dispute Resolution
CEDR : Centre for Effective Dispute Resolution
DAB : Dispute Adjudication Board
DB : Dispute Board
DRB : Dispute Review Board
EoI : Expression of Interest
FIDIC : The Fédération Internationale des Ingénieurs-Consei
ICC : International Chamber of Commerce
ITT : Invitation to Tender
JCT : Joint Contracts Tribunal
MDB : Multilateral Development Bank
MoWUD : Ministry Of Works & Urban Development
PASDEP : Plan For Accelerated And Sustained Development To End
Poverty
qv, qvv : quod vide À indicates a term that has a definition of its
own
UNCITRAL : United Nations Commission on International Trade Law
xii
Glossary of Important Terms
Adjudication
The legal process by which an arbiter or judge reviews evidence and
argumentation including legal reasoning set forth by opposing parties or
litigants to come to a decision which determines rights and obligations
between the parties involved. It is The final judgment in a legal
proceeding; the act of pronouncing judgment based on the evidence
presented
Alternate Dispute
Resolution(ADR)
A procedure for settling a dispute by means other than litigation, such
as arbitration or mediation. -
Arbitration
A method of dispute resolution involving one or more neutral third
parties who are usually agreed to by the disputing parties and whose
decision is binding
Claim
1. The aggregate of operative facts giving rise to a right enforceable by
a court 2) The assertion of an existing right; any right to payment or to
an equitable remedy, even if contingent or provisional 3.)A demand for
money, property, or a legal remedy to which one asserts a right
Construction
Construction is a process that consists of the building or assembling of
infrastructure, In general, there are three types of construction: Building
construction , Heavy / civil construction , Industrial construction
(Each type of construction project requires a unique team to plan,
design, construct and maintain the project.)
Dispute Resolution
Agreement
Legal agreement between two parties that lays out the method and
timetable for solving conflict between them, such as between
employers and employees, partners, stockholders (shareholders).
Invitation to
Tender (ITT)
A document that the department will issue to tenderers. The document
will request that the tenderers reply to a precisely defined requirement
in a prescribed format. It is typically comprised of lodging of tender,
terms of tender, conditions of contract, contract schedules, service
specifications, offer to be bound and articles of agreement.
xiii
Likert Scale
A method of ascribing quantitative value to qualitative data, to make it
amenable to statistical analysis. A numerical value is assigned to each
potential choice and a mean figure for all the responses is computed at
the end of the evaluation or survey.
Litigation The process of carrying on a lawsuit
Service levels Service levels are the standards of service with which the service
provider must comply. They must be clear and measurable.
Stakeholders
A stakeholder is anyone who has a vested interest in the project.
Stakeholders are individuals and organizations who are actively
involved in the project, or whose interest may be positively or
negatively affected as a result of project execution or successful project
completion.
Tort
A civil wrong other than a breach of contract or a breach of trust or other merely equitable obligation and which gives rise to an action for un liquidated damages at common law (Sir John Salmond).
Literally the word is French for ‘wrong’. The essential point is that it is a breach of a civil duty imposed by the law generally. The most important tort today is negligence (qv), but other torts include nuisance (qv), trespass (qv) and defamation (qv).
1
CHAPTER One:
1.0 Introduction The role the construction industry plays in socio-economic development is
significant. The industry is a distinct sector of the economy, which makes its
direct contributions to economic growth. It provides the basis upon which
other sectors can grow by constructing the physical facilities required for the
production and distribution of goods and services. The industry has a significant
multiplier effect on the economy as a whole.
Economic growth is one of the most effective ways of reducing poverty, and
infrastructure delivery has been identified as one of its key drivers. The
construction industry has great employment generation potential as labor
intensive technologies are economically viable for most items of construction
work.
The present state of the construction industry falls short of meeting domestic and
international quality standards and the performance demand expected from the
sector. Its percentage of GDP only amounts to 3%, considerably lower than the
sub-Saharan average of 6%. However, in line with the overall economic growth
of 5% in the past 4 years, the Construction Industry has registered an 8.2%
growth. Moreover, Public construction projects consume an average annual rate
of nearly 60% of the Government’s capital budget. 1
1 (MoWUD, Plan for Accelerated and Sustained Development to End Poverty (PASDEP))
2
While construction's direct contributions to development are significant, it also
stimulates a sizeable amount of economic growth through backward and forward
linkages. Construction's requirements for goods and services from other
industries are considerable; the development of the construction industry
therefore stimulates these ancillary industries, thus encouraging further economic
growth. In developing countries the construction of physical facilities makes up
more than one half of gross domestic investment and tends to be concentrated on
basic infrastructure in agriculture, mining, transportation, communication, and
utilities. Infrastructural services make some contribution to GDP, but they also
stimulate the development of other industries which, in turn, contribute more
directly to economic growth. Once the basic infrastructure is created, more effort
can be devoted to construction for manufacturing, commerce, and services and to
the building of dwellings and institutional facilities.
Construction's contributions to employment creation are naturally parallel to its
contributions to output generation. A common condition of underdevelopment is
unemployment and underemployment. In the past, the question of employment
was generally neglected because of the apparent conflict between economic
growth and employment creation. The extent to which growth and employment
creation should be balanced in developing countries is a matter of importance and
necessarily depends largely upon local economic, technical, social, and political
conditions. The construction industry could play an important role in resolving
this conflict because it is technologically flexible, implying that many of its
operations can be made more or less labor-intensive depending upon conditions in
the country at the time.
3
1.1 Background of the study The subject of study is identified after more than 20years of local & international
work experience in infrastructure development and related projects. This was
initiated to study the underlying reasons for construction contract disputes in
Ethiopian construction industry and to identify methods used for dispute
avoidance and resolution. The objectives of the subject are identified through the
observations of construction conflicts and disputes which were encountered by
clients, consultants and contractors.
1.2 Statement of Problem The construction industry has become very complicated such that political
and economic trends are increasing the economic pressure resulting in disputes.
Complex construction has brought about complex disputes in the industry. There
are so many different types of sources that may lead to disputes, the most
common of these: Contracts, Defective work, Variations or ‘extra works’, Delays
and extensions of time, Failure to adequately document the works & daily events,
etc, and this eventually becomes a burden to the industry in terms of production.
Great concern has been expressed in the recent years regarding the dramatic
conflicts and disputes in the construction industry in the whole world and this has
resulted in:
a) Time delays and cost overruns.
b) Deterioration of relationship and breakdown in cooperation.
4
c) Additional expenses in management and administration
d) Possibility of escalation to litigation.
Often seen stakeholders(employers, consultants & contractors) blaming each
other because of problems they come across during the construction process,
because of poorly done designs, claims, and poor administration and delays and
these have been overlooked. There are questions which arise on what is it that is
actually causing disputes in the industry? And why disputes have become a nature
of event in the industry?
Disputes and conflicts have gained frequent rise during construction of projects
and this needs an involvement of a neutral body to resolve disputes as early as
possible.
1.3 Research Objectives The goal of this study is to identify the major causes of construction disputes in
the Ethiopian construction industry, contributed by clients, consultants and
contractors and eventually identify the occurrences of the construction disputes
during the process of construction.
The objectives of this study can be summarized as follows:
1.3.1 To identify the root/major causes of construction2 disputes
2 Building construction, Heavy / civil construction, Industrial construction
5
1.3.2 To identify the perceptions of clients, consultants, and contractors on
the relative importance of causes and effects of dispute
1.3.3 To identify contribution of clients, consultants, and contractors to the
causes and effects of dispute
1.4 Scope and Limitation of Research
1.4.1 Scope The research has been carried out with a careful study on data collected mainly on
questionnaire survey, literature review and observations (personal experience).
The research will focus on all kinds of project i.e. private and government
projects which are faced with the problem of construction disputes.
The questionnaire survey was designed based on factors identified from literature
review that contributed to causes of disputes, effects of disputes and methods to
minimize disputes.
1.4.2 Limitations The shortcomings/ limitations are unavailability of adequate documented
information in the field of the study, and the reluctance of some stakeholders in
the construction industry to provide information related to the subject
issues/dispute/.
1.5 Research Methodology and Design The research methodology is the essential stages to determine the success of
achieving the aim and objectives. The major processes involved in this study
includes: Questionnaire survey, literature review, data collection, data analysis
and conclusion.
6
A questionnaire was developed to assess the perceptions of clients, consultants,
and contractors on the relative importance of causes and effects of dispute in
Ethiopian construction industry. The questionnaire will be divided into two parts.
The first part requested background information about the respondents.
The second part of the questionnaire focused on causes of construction disputes.
The respondents will be asked to indicate their response category on Six (6) &
well-recognized major categories of construction dispute factors
Category 1: Employer Related Factors;
Category 2: Contractor Related Factors;
Category 3: Consultant Related Factors
Category 4: Material, Labor & Equipment Related Factors
Category 5: Contract & Contract Relationship Related Factors
Category 6: External Factors
The data collected from the questionnaire survey will be analyzed using the five-
point Likert scales and the Likert scale taking the following format: 1. Very
Insignificant, 2. Insignificant, 3.Average, 4.Significant, And 5.Very Significant.
Finally, results of the questionnaires surveys will be analyzed. The findings and
conclusion will be elaborated based on the analysis.
7
Figure 1.1 Flowchart of the research Methodology
Specify objective(Problem-Statement)
Select method of data collection
Questionnaire Design
Data Collection, processing and
analysis
Reporting Findings
1.6 Significance of the Study This study will identify the root causes of construction dispute caused by the
client, consultants and contractors. It also covers the impact of construction
disputes in a client’s organization and methods of disputes resolutions. These
factors had been seen as the major factors in affecting production in the industry,
thus it is a necessity to manage them or rather to avoid them for the better part of
the performance of the industry.
1.7 Thesis Organization This thesis is divided into five chapters. The first chapter introduces the subject,
background and justification for this study. This chapter also specifies the aim
8
and objectives, the methodology of conducting this study and a brief summary on
the structure of the research.
Chapter two highlights the related issues on causes of construction disputes from
available literature which include the following: Definition of disputes; Disputes
Occurrence; Research related to construction Disputes; The causes of
construction dispute; Impact of disputes on client organization;
Chapter three describes in details the process of data collection that involved in
the study which included introduction, data on the causes of construction disputes
questionnaire development, sampling, data summary, and summary and
conclusion.
Chapter four discusses the process of the data analysis to achieve the aim and
objectives of this study which included introduction, analysis of data, important
index, findings and discussion, and conclusion.
Finally, the last chapter summarizes the conclusion from the research findings of the study and recommendation.
9
1.8 Summary This chapter covered the introduction to the problem of disputes in the
construction industry that has prompted to this study. Moreover it states the aim
and objectives, scope, methodology used and the significance of the findings.
This project is based on identifying construction disputes that have been seen to
be affecting the industry’s performance. The results to be obtained from the study
will help in improving the production of the industry by means of implementing
the decisions obtained from the results of the study.
10
CHAPTER Two: Literature Review
2.1 Introduction Construction contracts entered into by various agencies are frequently attended by
significant risk of exposure to change order requests and claims. These claims
involve numerous issues, such as contract ambiguities, changes and additions to
the contract, differing site conditions, schedule delays, stop work orders, errors
and omissions in the contract plans and specifications, acceleration of the contract
by the agency, defective work by the contractor seeking indemnification from
third parties, warranty/guaranty clauses, recovery of liquidated damages. As the
volume of unresolved disputes grows, relationships with the contracting
community can deteriorate. This may lead to higher bid costs and the actual
withdrawal from the bidding of some otherwise capable contractors. The early
recognition, identification, and resolution of disputes can lessen management
costs and administrative efforts and lower overall program costs, benefiting the
public, the agency, and the contractor.
2.2 Key Terms and Concepts The two particular definitions that are important to this report are the key terms
“dispute” and “claim” As used in this thesis, a dispute refers to a contract related
issue that has not yet become a matter of formal process; a claim develops from a
dispute and has reached the stage where formal proceedings or legal actions are
underway.
The definitions are as follows:3
1. Dispute-- Strictly, a calling into question. In the context of construction
contracts it is usually associated with adjudication (qv) or arbitration (qv) 3 Building Contract Dictionary
11
when it refers to a disagreement between two parties. Usually, that will
take the form of a proposition by one party which the other has rejected,
although sometimes long silence or delay in responding on the part of the
other party may also be considered a rejection. A dispute may exist for the
purpose of adjudication or arbitration even though it may be obvious which
party is correct.
Adjudication and arbitration clauses usually refer to ‘dispute or difference’,
but they probably have essentially the same meaning in this context. The
Arbitration Act 1996 s. 82 (1) says that ‘dispute’ includes ‘difference’. No
adjudication or arbitration can take place unless a dispute or difference
exists
2. Claim-- The dictionary defines ‘claim’ as ‘an assertion of a right’ and,
under standard building contracts, the word conveys the concept of
additional payment which the contractor seeks to assert outside the
contractual machinery for valuing the work itself. The word is also used in
respect of the contractor’s applications for an award of extensions of time
(qv). The main types of claim which may be made by a contractor are:
3. Contractual claims: which are those made under specific provisions of the
Contract, e.g. one for ‘direct loss and/or expense’ under JCT 98, clause 26,
or for ‘expense’ under GC/Works/1 (1998), clause 46. This type of claim is
also occasionally described as being ex contractu, i.e. arising from the
contract. Under JCT terms À and most other forms of contract À it is only
claims of this type which the architect has authority under the contract to
settle.
12
4. Common law claims: which are those which arise apart from the express
provisions of the contract. They include claims in tort (qv), claims for a
quantum meruit (qv), claims for a quantum valebat (qv), claims for breach
of express or implied terms of the contract or warranty (qv). All the current
standard forms allow additional or alternative claims for breach of contract,
based on the same facts. Usually they are based on implied terms relating
to non-interference with the contractor’s progress (see: Hindrance or
prevention). They are sometimes called ex contractual or extra contractual
claims.
5. Ex gratia claims: are those without legal foundation and are usually made
on moral or hardship grounds. Very rarely, there may be an advantage to
meeting such a claim as a matter of grace, e.g. if the contractor is on the
brink of insolvency (qv) and, as a result, the employer would face greater
expense if the contractor could not carry on and completion contractors had
to be employed.
13
Disagreement
Argument
Dispute
When two parties express difference of opinion. The mater is usually resolved to the mutual satisfaction of all Parties
Where the disagreement can not be so readily resolved and discussion become heated
Major disagreements, often over contracts that can not be resolved by the parties without recourse to a formal process
Figure 2.1 Disagreement Escalation Diagram (Source: (IAN M Elenberg), Dispute Resolution in Construction Management)
2.3 Occurrence and Causes of Construction Dispute 4 Numerous construction disputes that arise largely through miscommunication
between the various parties in a design/construction effort. Usually, these disputes
occur even though the parties involved all are well intended. This often happens
because someone “drops the ball” by failing to communicate effectively with
another concerning design issues, compensation and payment issues, scope
change issues and the like, leading to legal disputes.
The occurrence of some of the common causes of dispute are discussed below
A review of these disputes shows that many, if not all, can be avoided through
better communication — whether through more effective contract writing, oral
4 Ineffective Communication: Common Cause of Construction Disputes (Jeffery M. Hall, Esq. Folk & Associates, P.C. Vol.13, No.2, May/June 2002 )
14
presentation and/or people communication skills
2.3.1 During the Design Phase
1. Design and specification oversights, and errors or omissions resulting from
uncoordinated civil, structural, architectural, mechanical and electrical
designs can result in unexpected change orders, wholesale scope changes,
and project delays. They may ultimately lead to inadvertently ill-
constructed projects filled with construction defects due to bad project
documentation.
2. The design professional’s failure to remain within an owner’s project
budget and design objectives, leads to dissatisfied owners and to design
professional liability.
3. A similar dispute may occur when an owner’s design vision of a project is
not communicated effectively to the design team. Perhaps due to an
owner’s inexperience, this breakdown may result in an unrealistic project
square footage, unnecessary architectural features, and/or finishes that
cannot be achieved within budget. Over-design is a predictable cause of
disputes, particularly when an owner turns to third-party consultants for
input that is not coordinated effectively with the design team while the
overall design is evolving and maturing.
4. The owner’s failure to contract with the consultants for construction
administration/construction observation services can lead to poor
coordination of the project, especially in cases involving absentee or
inexperienced owners. The owner should make a determination at the
15
outset whether this service will be provided by the design team or a third
party such as a construction manager, and then engage this party for those
services.
Design phase issues like these can be avoided by addressing them up front and
providing for them in properly drawn construction documents.
2.3.2 During the Bid and Contract Award Phase Lack of understanding and agreement between the owner and contractor as to
whether the contract is a lump-sum, cost-reimbursable (time and materials),
cost-plus fixed fee, or guaranteed maximum price contract arrangement.
Other issues that arise during contract formation include (1) defining what
costs are allowable and reimbursable; (2) the budget breakdown and schedule
of values for pay items that are essential in controlling billed costs, progress
and earned revenue; and (3) the allocation of change orders to budget or pay
items relative to billing practices and progress measurement.
2.3.3 During the Construction Phase 1. Starting construction of a project prior to design completion is a recipe for
trouble. A complete, fully coordinated set of project documents is critical to
realizing a successful project from all parties’ perspectives. Without fully
coordinated drawings and specifications, the project will most assuredly be
faced with budget issues, disputes arising from bid allowances due to
undefined scopes, and ultimately in changes and cost increases.
16
2. Construction disputes due to lack of access to utilities, unanticipated site
conditions and/or inclement weather impacts on working conditions can result
in claims for inefficiency and delay-related costs.
3. The contractor’s failure to coordinate its subcontractors’ work through
effective and timely exchange of shop drawings, failure to provide timely
responses to the consultant and client, and purchasing and schedule
mismanagement that may impact the work of others, are all factors that also
result in delays, inefficiency, rework, defects and cost overruns that lead to
claims and disputes.
4. Contractor over-billings often are the result of a fundamental
misunderstanding of what is allowable under the terms of the contract. This
includes unsupported costs, disallowed costs under the construction contract,
or costs for non-compensable delays, inefficiency, rework and
mismanagement.
5. Consultant’s failure in its contractual administrative duties for such things as
field observations and reporting with regard to construction defects, quality,
progress, and conformance of the work with the contract documents; and the
evaluation of contractor change orders and pay applications.
6. Cost overruns often lead to disputes because of an owner’s unwillingness or
inability to pay, even when they are the result of legitimate scope changes
and/or project upgrades. The owner’s contribution to these cost overruns also
typically causes contractor delays, acceleration and inefficiency.
17
2.4 summary This chapter highlights issues related to causes of construction disputes from
available literature which including: Definition of disputes; Occurrence & The
causes of construction dispute, etc.
18
CHAPTER Three: Data Collection and Preliminary Analysis
3.1 Introduction Data Collection is an important aspect of any type of research study. Inaccurate
data collection can impact the results of a study and ultimately lead to invalid
results.
The purpose of data collection is to obtain information to keep on record, to make
decisions about important issues, to pass information on to others. Primarily, data
is collected to provide information regarding a specific topic
3.2 Sampling Methods One of the most important decisions that any researcher makes is how to obtain
the type of participants needed for the study.
In most situations, it is impossible to study an entire population. Typically a
subset of people drawn from a larger population will be studied and use
inferential statistics to make an inference from the sample back to the population.
The validity of that inference depends on how representative the sample or subset
is of the population from which it is drawn. Given the time constraint, the prime
goal of this paper, is to obtain the most representative sample using the
appropriate type of non probability sampling strategies.
3.3 Non-probability Sampling Strategies There are three types of non-probability sampling strategies: Haphazard,
Convenience and Purposive
19
3.3.1Haphazard Sampling Haphazard sampling is a strategy that is almost guaranteed to introduce bias into
your study. It should be avoided at all costs. A typical haphazard strategy uses a
"man-on-the-street" technique to recruit those who wander by or selects a
sampling frame that does not accurately reflect the population.
3.3.2 Purposive Sampling Purposive sampling targets a particular group of people. When the desired
population for the study is rare or very difficult to locate and recruit for a study,
purposive sampling may be the only option. For example, you are interested in
studying cognitive processing speed of young adults who have suffered closed
head brain injuries in automobile accidents. This would be a difficult population
to find.
3.3.3 Convenience Sampling Convenience sampling selects a particular group of people but it does not come
close to sampling all of a population. Researchers want to study the effectiveness
of a diversion program for preventing further criminal activity among first-time
juvenile offenders. Many cities across the nation have such programs but the
researchers study the program in their city. The sample would generalize only to
similar programs in similar cities. Convenience sampling is widely used in
student research projects. Students contact professors that they know and ask if
they can use their classes to recruit research subjects.5
3.5.1 Summary of Respondents Profile The respondents’ data profile with respect Positional distribution includes
General Managers, project managers, department heads, resident engineers and
supervisors
With respect to years of experience 14.49% of the sample are less than or equal to
5years of experience, 31.88% of the sample between 6 to 10 years of experience,
17.39% of the sample between 11 to 15 years of experience, 55% of the sample
between 16 to 20 years of experience 20.29 % of the sample are more than 20
years of experience,
With respect to Type of Organization 34.78% of the sample are from Employer
(client) Organization), 28.99% of the sample are from Consultant Organization,
and 36.23% of the sample is from Consultant Organization (please refer Table 3.2,
below) Table 3.2: Summary of Respondents Profile
Item No
Characteristics No. of response
Percent
I Number of Years of Experience Less than 5 years 10 14.49% 6 to 10 years 22 31.88% 11 to 15 years 12 17.39% 16 to 20years 11 15.94%
23
More Than 20 years 14 20.29% Total 69 100.00% II Type of Organization Employer(client) 24 34.78% Consultant 20 28.99% Contractor 25 36.23% Total 69 100.00%
3.5.2 Response to Category 1: Employer Related Factors: Table 3.3: Overall respondents’’ view (Category 1)
Sr. No.
Description Indicator Total 1 2 3 4 5
1 Failure to finance and payments of completed work 13 12 15 16 13 69 2 Owner Interference 7 16 23 15 8 69 3 Slow decision making 2 5 15 34 13 69
10 Consultants’ delay in Preparation and approval of drawings
75.20 8th, Consultant
The Contractors’ point of view, shows that among the top ten major causes,
Contractor & Consultant related factors, score three each, Equipment & Material
Related factors one each, and Employer and External related factors one each.
5.2.4 Overall respondents point of view Based on overall respondents view, the analysis reveals that the most significant
causes of construction dispute is(i) “Financial Difficulties” of the contractor with
55
Relative Importance Index (RII), value of 87.25%, followed by (ii) “Price
escalation” with Relative Importance Index (RII), value of 82.03%, and (iii)
contractors’ “Inadequate investigation before bidding,” with Relative Importance
Index (RII), value of 80.00%,
Moreover, Poor Contract management & Supervision, of the consultant, with
Relative Importance Index (RII), value of 77.68%,Shortage in material, with
Relative Importance Index (RII), value of 76.23%,Exceptionally Low Bid of the
contractor, with Relative Importance Index (RII), value of 75.94%,Employers’
Slow decision making, with Relative Importance Index (RII), value of 74.78%,
and Failure & unavailability of Equipment, with Relative Importance Index (RII),
value of 73.62%, are ranked 4th, 5th, 6th,7th,and 8th, respectively and also
Consultants’ delay in Preparation and approval of drawings and contractors’ poor
site management with equal Relative Importance Index (RII), value of 72.75%,
are ranked 9th, Table 5.4: Summary the top 10 causes of dispute (based on overall respondents view)
No Cause of Dispute RII (%) Rank Category
1 Financial Difficulties” of the contractor 87.25 1st, Contractor
2 Price escalation 82.03 2nd, External
3 Contractors’ “Inadequate investigation before bidding
80.00 3rd, Contractor
4 Poor Contract management & Supervision, of the consultant
77.68 4th, Consultant
56
5 Shortage in material 76.23 5th, Material related
6 Exceptionally Low Bid of the contractor 75.94 6th, Contractor
7 Employers’ Slow decision making 74.78 7th, Employer
8 Failure & unavailability of Equipment 73.62 8th, Equipment Related
9 Consultants’ delay in Preparation and approval of drawings
72.75 9th, Consultant
10 contractors’ poor site management 72.75 9th, Contractor
Finally, the combined overall point of view, demonstrates that among the top ten
major causes,
i. Contractors’ related factors, score four ;
ii. Consultants’ related factors, score two;
iii. Material &Equipment Related Factor Score One each;
iv. Employers’ related factors, score one; and
v. External related factors, score one;
Depending on the grouping of respondents, point of view the ranking of the major
causes of disputes is slightly different from each other. However, the results of
this study can be helpful to the parties (Clients, Contractors and Consultants) to
visualize and better understand the characteristic or manner of an interaction of
disputes in the construction industry and make efforts to reduce the incidences of
disputes.
57
5.3 Recommendations The recommendations to adopt can be divided into three groups: (1)
recommendations for the clients, (2) recommendations for the consultants, and (3)
recommendations for the contractors.
5.3.1 Recommendations for the Employers/ Clients 1. While selecting the contractors, clients have to make sure that the contractors
are not selected based only on the lowest bid. The selected contractor must
have sufficient experience, technical capability, financial capability, and
sufficient manpower to execute the project,
2. Clients should not interfere frequently during the execution and keep making
major changes to the requirements. This can cause excessive delays in the
project,
3. Clients should have the finances in time to pay the contractors after
completion of a work. Therefore, clients should work closely with the
financing bodies and institutions to release the payment on schedule, and
4. Clients must make quick decisions to solve any problem that arise during the
execution.
5.3.2 Recommendations for the Consultants 1. While drawing the contract between the client and contractor, the consultant
must include items such as duration of contract, mechanism to solve disputes,
mechanism to assess the causes of delay, if there are any and risk management
plans,
2. consultants should prepare and approve drawings on time, and
58
3. Consultants should monitor the work closely by making inspections at
appropriate times.
4. Confirm all oral agreements/changes in writing and maintain daily records of
the project.
5.3.3 Recommendations for the Contractors 1. Contractors should not take up the job in which they do not have sufficient
expertise,
2. Contractors should have able site-managers for the smooth execution of work,
3. Contractors must plan their work properly and provide the entire schedule to
the clients, and
4. Contractors must make sure they have a sound financial backing and financial
management system
5.3.4 General Recommendations Some disputes may not be prevented by prior action, but many can. Ensuring that
a formal contract agreement is executed between parties to a contract is a first
step towards avoiding disputes.
Contractual precautions that provide some safeguard against disputes include:
Ensuring that the parties enter into a finalised contract before work
commences;
Ensuring that the scope of works is clearly defined prior to tender;
Ensuring that the quality constraints are fully defined prior to tender;
Ensuring that the conditions of the contract are fair and clear, using
standard forms unless non standard provisions are essential;
59
Ensuring that the contract provides for early notification of potential
disputes and that dispute resolution procedures are stipulated and not
restricted to arbitration or litigation; and
Ensuring that contract management is effective.
60
References:
1. A Thomson Reuters business, Black’s Law Dictionary 9th edition, page 127, 244
2. (David Chappell, Derek Marshall, Vincent Powell-Smith, Simon Cavender)Building
Contract Dictionary Third Edition , page 70, 71, 134, 135
3. (IAN M Elenberg),Dispute Resolution In Construction Management, Page 9-12
4. Federal Democratic Republic of Ethiopia , Ministry of Works and Urban Development
,PLAN FOR ACCELERATED AND SUSTAINED DEVELOPMENT TO END
POVERTY(PASDEP) (2005/06-2009/10) Page 11
5. Ethiopian Business Development Services Network (EBDSN)
6. FIDIC-A Guide for Practitioners , page 418-423
7. Alberto De Marco Project Management for Facility Constructions( A Guide for
Engineers and Architects) page 50-52
8. (Fred Moavenzadeh ,Professor of Civil Engineering & Janet Ann Koch Rossow
Graduate Research Assistant)The Construction Industry In Developing Countries,
page 3-5
9. Ineffective Communication: Common Cause of Construction Disputes (Jeffery M. Hall,
Esq. Folk & Associates, P.C. Vol.13, No.2, May/June 2002
10. Wikipedia, the free encyclopedia ;
61
Appendices:
62
Appendix 1: Cover letter for questionnaire Dear Mr. _________________ Good Day!
As you already know, I am working on a research paper on the subject issue of
“Construction Disputes”. Accordingly, I have developed a questionnaire to assess
the perceptions of engineers on the relative importance of causes and effects of
dispute in Ethiopian construction industry.
Enclosed you will find the questionnaire (3pages, pdf. file). Hence, I kindly
request you to respond to the simple questions. I shall be very grateful if you will
also use your influence to include your colleagues & friends to fill the
questionnaire survey.
Thanks and Regards,
Kifle Semu
63
Appendix 2; Questionnaire Survey SECTION A: RESPONDENT PROFILE Please fill in the blank
1 Respondent Name:
2 Company Name:
3 Type of Job/Position:
4 Year of Experience
5 Type of Organization [Employer/ Contractor/Consultant]
64
Please indicate your best opinion for the following cause of Construction Disputes
1 Very Insignificant 2 Insignificant 3 Average 4 Significant 5 Very Significant
Item No. Question
Indicator
1 2 3 4 5
CATEGORY 1: Employer Related Factors
1 Failure to Finance and payments of completed work
2 Owner Interference
3 Slow decision making
4 Unrealistic contract duration and requirements imposed
5 Other (if any)
CATEGORY 2: Contractor Related Factors
1 Inadequate investigation before bidding
2 Site management
3 Construction methods
4 Poor planning and use of wrong equipment
5 Mistakes during construction stage
6 Inexperienced contractor
7 Financial Difficulties
8 Exceptionally Low Bid
9 Other (if any)
CATEGORY 3: Consultant Related Factors
65
Item No. Question
Indicator
1 2 3 4 5
1 Poor Contract management & Supervision
2 Preparation and approval of drawings
3 Frequent Changes in orders & Designs
4 Waiting time for approval of tests and inspection
5 Other (if any)
CATEGORY 4: Material, Labor & Equipment Related Factors
1 Quality of material
2 Shortage in material
3 Shortage of Labor supply
4 Labor productivity
5 Equipment availability and failure
6 Other (if any)
CATEGORY 5: Contract & Contract Relationship Related Factors
1 Change orders
2 Mistakes and discrepancies in contract document
3 Inappropriate overall organizational structure linking to the project
4 Lack of communication between the parties
CATEGORY 6: External Factors
1 Inclement Weather condition
2 Regulatory changes
3 Unforeseen site condition
4 Price escalation
5 Other (if any)
66
Appendix 3: Calculation of Relative Importance of Index (RII) (based on overall view) Item No Description n1 n2 n3 n4 n5 N a1=1 a2=2 a3=3 a4=4 a5=5 W A=5 RII=
Appendix 4: Calculation of Relative Importance of Index (RII) (based on Employers view) Item No Description n1 n2 n3 n4 n5 N a1=1 a2=2 a3=3 a4=4 a5=5 W A=5 RII=
Appendix 5: Calculation of Relative Importance of Index (RII) (based on Contractors view) Item No Description n1 n2 n3 n4 n5 N a1=1 a2=2 a3=3 a4=4 a5=5 W A=5 RII=
Appendix 6: Calculation of Relative Importance of Index (RII) (based on Consultants view) Item No Description n1 n2 n3 n4 n5 N a1=1 a2=2 a3=3 a4=4 a5=5 W A=5 RII=